Excuse or Postponement. Club Owner may excuse or postpone Club Charges in its sole and absolute discretion.
Excuse or Postponement Sample Clauses
Related to Excuse or Postponement
Postponement The Company shall be entitled once in any six-month period to postpone for a reasonable period of time (but not exceeding 90 days) (the “Postponement Period”) the filing of any registration statement required to be prepared and filed by it pursuant to this Section 2.1 if the Company determines, in its reasonable judgment, that such registration and offering would materially interfere with any material financing, corporate reorganization or other material transaction involving the Company or any subsidiary, or would require premature disclosure thereof, and promptly gives Mitsui written notice of such determination, containing a general statement of the reasons for such postponement and an approximation of the anticipated delay. If the Company shall so postpone the filing of a registration statement, (i) the Company shall use its reasonable best efforts to limit the delay to as short a period as is practicable and (ii) Mitsui shall have the right to withdraw the request for registration by giving written notice to the Company at any time and, in the event of such withdrawal, such request shall not be counted for purposes of the requests for registration to which Mitsui is entitled pursuant to this Section 2.1.
Vacation Postponement If a bargaining unit employee's vacation becomes due during a period when he/she is on leave due to illness or injury, he/she may request that his/her vacation date be changed, and the Board shall grant such request in accordance with vacation dates available at that time. The employee may elect to have his/her vacation rescheduled in accordance with the vacation schedule available at that time. If rescheduling is impossible, then the vacation may be accumulated or paid in cash.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
CONSEQUENCES OF EARLY TERMINATION OR OTHER BREACH BY APPLICANT A. In the event that the Applicant terminates this Agreement without the consent of the District, except as provided in Section 7.2 of this Agreement, the Applicant shall pay to the District liquidated damages for such failure within thirty (30) days after receipt of the notice of breach.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Vacating at End of Term; Renewal This Agreement does not automatically renew, and Owner is not obligated to renew it. Owner reserves the right to contract with others for the premises at any time, for occupancy commencing after the End Date. The parties mutually agree that Resident’s tenancy and right of occupancy will end automatically on the End Date and that this provision constitutes notice of termination on the End Date. Upon termination or expiration of this Agreement for any reason, Resident will immediately vacate and relinquish the bedroom space and entire apartment, and all of Owner’s fixtures, in a clean and sanitary condition, including removing all trash. Resident will pay all utility and service bills to the bedroom space and apartment (except those provided by Owner as specified above) and cancel all utility accounts in the name of Resident. Resident will return to Owner all keys issued to Resident by Owner. If all keys issued to Resident are not returned promptly to Owner, Resident will pay all costs associated with re-keying or reprogramming locks for the bedroom space and/or apartment, along with the cost of key replacement. If Resident fails to vacate the bedroom space and apartment by the end of the Term or upon earlier termination of the Agreement, Resident will pay an administrative fee in the amount of $300.00 plus agreed holdover charges equal to three (3) times the daily pro- rated housing charges during the Term (but not more than the amount provided by law), plus associated expenses, including attorneys’ fees as allowed by law. In no event after termination or expiration of this Agreement will it be deemed to be renewed or extended.
No Excuse Without Notice If Contractor accepts a proposed Change Order adding a Bulletin to this Contract that designates a Sole Source without invoking this Article and putting the Owner on notice, Contractor shall not be excused from its obligations with respect to the described Work by reason of the refusal of a designated Sole Source to provide warranties as required under this Contract.
Notice of In the event of a proposed lay-off at the Hospital of a permanent or long-term nature or the elimination of a position within the bargaining unit, the Hospital shall: provide the Union with no less than six months' written notice of the proposed layoff or elimination of position; and
