Termination Payment for Force Majeure Event 30.9.1 If Termination is on account of a Non-Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to 55% (fifty five per cent) of the Debt Due less Insurance Cover.
30.9.2 If Termination is on account of an Indirect Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to:
(a) 55% of the Debt Due less Insurance Cover; provided that if any insurance claims forming part of the Insurance Cover are not admitted and paid, then 80% (eighty per cent) of such unpaid claims shall be included in the computation of Debt Due;
(b) 60.5% (sixty point five per cent) of the Adjusted Equity; and
30.9.3 If Termination is on account of a Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount that would be payable under Clause 33.3.2 as if it were Authority’s Default.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Compensation for Breakage or Non-Commencement of Interest Periods Borrower shall compensate each Lender, as promptly as practicable after written request by such Lender (which request shall set forth the basis for requesting such amounts and shall be conclusive absent manifest error), for all reasonable losses, expenses and liabilities (including any interest paid or calculated to be due and payable by such Lender to lenders of funds borrowed by it to make or carry its Eurodollar Rate Loans and any loss, expense or liability sustained by such Lender in connection with the liquidation or deployment of such funds but excluding loss of anticipated profits) which such Lender may sustain: (i) if for any reason (other than a default by such Lender) a borrowing of any Eurodollar Rate Loan does not occur on a date specified therefor in a Funding Notice or a telephonic request for borrowing, or a conversion to or continuation of any Eurodollar Rate Loan does not occur on a date specified therefor in a Conversion/Continuation Notice or a telephonic request for conversion or continuation; (ii) if any prepayment or other principal payment of, or any conversion of, any of its Eurodollar Rate Loans occurs on a date prior to the last day of an Interest Period applicable to that Loan; or (iii) if any prepayment of any of its Eurodollar Rate Loans is not made on any date specified in a notice of prepayment given by Borrower.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Termination for Nonpayment In the event of the nonpayment of fees owed to DSI, DSI shall provide written notice of delinquency to all parties to this Agreement. Any party to this Agreement shall have the right to make the payment to DSI to cure the default. If the past due payment is not received in full by DSI within one month of the date of such notice, then DSI shall have the right to terminate this Agreement at any time thereafter by sending written notice of termination to all parties. DSI shall have no obligation to take any action under this Agreement so long as any payment due to DSI remains unpaid.
Termination Notice for Force Majeure Event If a Force Majeure Event subsists for a period of 180 (one hundred and eighty) days or more within a continuous period of 365 (three hundred and sixty five) days, either Party may in its discretion terminate this Agreement by issuing a Termination Notice to the other Party without being liable in any manner whatsoever, save as provided in this Article 34, and upon issue of such Termination Notice, this Agreement shall, notwithstanding anything to the contrary contained herein, stand terminated forthwith; provided that before issuing such Termination Notice, the Party intending to issue the Termination Notice shall inform the other Party of such intention and grant 15 (fifteen) days time to make a representation, and may after the expiry of such 15 (fifteen) days period, whether or not it is in receipt of such representation, in its sole discretion issue the Termination Notice.
Termination for Non-Payment We may terminate this Agreement with immediate effect by giving written notice to you if you fail to pay any amount due under this Agreement on the due date for payment and remain in default not less than thirty
Termination for Cause with Notice to Cure Requirement Contractor may terminate this contract for the Department’s failure to perform any of its duties under this contract after giving the Department written notice of the failure. The written notice must demand performance of the stated failure within a specified period of time of not less than 30 days. If the demanded performance is not completed within the specified period, the termination is effective at the end of the specified period.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Termination for Default The Commonwealth may terminate this Agreement by notice where it reasonably believes the Grantee:
(a) has breached this Agreement; or
(b) has provided false or misleading statements in their application for the Grant; or
(c) has become bankrupt or insolvent, entered into a scheme of arrangement with creditors, or come under any form of external administration.
