Execution of an Interconnection Agreement. Designated Entity has executed an Interconnection Agreement with the Transmission Owner(s) to whose facilities the Project will interconnect, or such agreement has been filed unexecuted with the Commission.
Execution of an Interconnection Agreement Sample Clauses
Related to Execution of an Interconnection Agreement
Interconnection Agreement On or before December 31, 2015, Wholesale Market Participant must enter into an Interconnection Agreement with the Transmission Owner in order to effectuate the WMPA. Wholesale Market Participant shall demonstrate the occurrence of each of the foregoing milestones to Transmission Provider’s reasonable satisfaction. Transmission Provider may reasonably extend any such milestone dates, in the event of delays that Wholesale Market Participant (i) did not cause and (ii) could not have remedied through the exercise of due diligence. If (i) the Wholesale Market Participant suspends work pursuant to a suspension provision contained in an interconnection and/or construction agreement with the Transmission Owner or (ii) the Transmission Owner extends the date by which Wholesale Market Participant must enter into an interconnection agreement relative to this WMPA, and (iii) the Wholesale Market Participant has not made a wholesale sale under this WMPA, the Wholesale Market Participant may suspend this WMPA by notifying the Transmission Provider and the Transmission Owner in writing that it wishes to suspend this WMPA, with the condition that, notwithstanding such suspension, the Transmission System shall be left in a safe and reliable condition in accordance with Good Utility Practice and Transmission Provider’s safety and reliability criteria. Wholesale Market Participant’s notice of suspension shall include an estimated duration of the suspension period and other information related to the suspension. Pursuant to this section 3.1, Wholesale Market Participant may request one or more suspensions of work under this WMPA for a cumulative period of up to a maximum of three years. If, however, the suspension will result in a Material Modification as defined in Part I, Section 1.18A.02 of the Tariff, then such suspension period shall be no greater than one (1) year. If the Wholesale Market Participant suspends this WMPA pursuant to this Section 3.1 and has not provided written notice that it will exit such suspension on or before the expiration of the suspension period described herein, this WMPA shall be deemed terminated as of the end of such suspension period. The suspension time shall begin on the date the suspension is requested or on the date of the Wholesale Market Participant’s written notice of suspension to Transmission Provider, if no effective date was specified. All milestone dates stated in this Section 3.1 shall be deemed to be extended coextensively with any suspension period permitted pursuant to this provision.
EXECUTION OF SETTLEMENT AGREEMENT 36. This Settlement Agreement may be signed in one or more counterparts which together shall constitute a binding agreement.
Interconnection Customer’s Interconnection Facilities Construction The Interconnection Customer’s Interconnection Facilities shall be designed and constructed in accordance with Good Utility Practice. Within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Participating TO and Interconnection Customer agree on another mutually acceptable deadline, the Interconnection Customer shall deliver to the Participating TO and CAISO “as-built” drawings, information and documents for the Interconnection Customer’s Interconnection Facilities and the Electric Generating Unit(s), such as: a one-line diagram, a site plan showing the Large Generating Facility and the Interconnection Customer’s Interconnection Facilities, plan and elevation drawings showing the layout of the Interconnection Customer’s Interconnection Facilities, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Interconnection Customer's step-up transformers, the facilities connecting the Large Generating Facility to the step-up transformers and the Interconnection Customer’s Interconnection Facilities, and the impedances (determined by factory tests) for the associated step-up transformers and the Electric Generating Units. The Interconnection Customer shall provide the Participating TO and the CAISO specifications for the excitation system, automatic voltage regulator, Large Generating Facility control and protection settings, transformer tap settings, and communications, if applicable. Any deviations from the relay settings, machine specifications, and other specifications originally submitted by the Interconnection Customer shall be assessed by the Participating TO and the CAISO pursuant to the appropriate provisions of this LGIA and the LGIP.
EXECUTION OF CONTRACT 20.1 Depending on the type of service provided, one of the following methods will be employed. The method applicable to this contract will be checked below:
Data Processing Agreement The Data Processing Agreement, including the Approved Data Transfer Mechanisms (as defined in the Data Processing Agreement) that apply to your use of the Services and transfer of Personal Data, is incorporated into this Agreement by this reference. Each party will comply with the terms of the Data Processing Agreement and will train its employees on DP Law.
Development Agreement As soon as reasonably practicable following the ISO’s selection of a transmission Generator Deactivation Solution, the ISO shall tender to the Developer that proposed the selected transmission Generator Deactivation Solution a draft Development Agreement, with draft appendices completed by the ISO to the extent practicable, for review and completion by the Developer. The draft Development Agreement shall be in the form of the ISO’s Commission-approved Development Agreement for its reliability planning process, which is in Appendix C in Section 31.7 of Attachment Y of the ISO OATT, as amended by the ISO to reflect the Generator Deactivation Process. The ISO and the Developer shall finalize the Development Agreement and appendices as soon as reasonably practicable after the ISO’s tendering of the draft Development Agreement. For purposes of finalizing the Development Agreement, the ISO and Developer shall develop the description and dates for the milestones necessary to develop and construct the selected project by the required in-service date identified in the Generator Deactivation Assessment, including the milestones for obtaining all necessary authorizations. Any milestone that requires action by a Connecting Transmission Owner or Affected System Operator identified pursuant to Attachment P of the ISO OATT to complete must be included as an Advisory Milestone, as that term is defined in the Development Agreement. If the ISO or the Developer determines that negotiations are at an impasse, the ISO may file the Development Agreement in unexecuted form with the Commission on its own, or following the Developer’s request in writing that the agreement be filed unexecuted. If the Development Agreement is executed by both parties, the ISO shall file the agreement with the Commission for its acceptance within ten (10) Business Days after the execution of the Development Agreement by both parties. If the Developer requests that the Development Agreement be filed unexecuted, the ISO shall file the agreement at the Commission within ten (10) Business Days of receipt of the request from the Developer. The ISO will draft, to the extent practicable, the portions of the Development Agreement and appendices that are in dispute and will provide an explanation to the Commission of any matters as to which the parties disagree. The Developer will provide in a separate filing any comments that it has on the unexecuted agreement, including any alternative positions it may have with respect to the disputed provisions. Upon the ISO’s and the Developer’s execution of the Development Agreement or the ISO’s filing of an unexecuted Development Agreement with the Commission, the ISO and the Developer shall perform their respective obligations in accordance with the terms of the Development Agreement that are not in dispute, subject to modification by the Commission. The Connecting Transmission Owner(s) and Affected System Operator(s) that are identified in Attachment P of the ISO OATT in connection with the selected transmission Generator Deactivation Solution shall act in good faith in timely performing their obligations that are required for the Developer to satisfy its obligations under the Development Agreement.
Execution of Agreement The HSP represents and warrants that:
Service Agreement Refers to the Contract, Purchase Order or Terms of Service or Terms of Use. Student Data: Student Data includes any data, whether gathered by Provider or provided by LEA or its users, students, or students’ parents/guardians, that is descriptive of the student including, but not limited to, information in the student’s educational record or email, first and last name, birthdate, home or other physical address, telephone number, email address, or other information allowing physical or online contact, discipline records, videos, test results, special education data, juvenile dependency records, grades, evaluations, criminal records, medical records, health records, social security numbers, biometric information, disabilities, socioeconomic information, individual purchasing behavior or preferences, food purchases, political affiliations, religious information, text messages, documents, student identifiers, search activity, photos, voice recordings, geolocation information, parents’ names, or any other information or identification number that would provide information about a specific student. Student Data includes Meta Data. Student Data further includes “Personally Identifiable Information (PII),” as defined in 34 C.F.R. § 99.3 and as defined under any applicable state law. Student Data shall constitute Education Records for the purposes of this DPA, and for the purposes of federal, state, and local laws and regulations. Student Data as specified in Exhibit “B” is confirmed to be collected or processed by the Provider pursuant to the Services. Student Data shall not constitute that information that has been anonymized or De-Identified, or anonymous usage data regarding a student’s use of Provider’s services.
Cooperation Agreement Pursuant to a cooperation agreement dated on or around the date of this announcement between Britvic and Bidco (the "Cooperation Agreement"), among other things: (i) Britvic and Bidco have agreed to certain undertakings to co-operate and provide each other with information, assistance and access in a timely manner in relation to the filings, notifications or submissions as are necessary for the purposes of satisfying the regulatory conditions; (ii) Bidco has agreed to provide Britvic with certain information for the purposes of the Scheme Document and to otherwise assist with the preparation of the Scheme Document; (iii) Bidco and Britvic have agreed to certain provisions providing Bidco with the ability to effect the Acquisition by way of a takeover offer rather than the Scheme (and Xxxxx and Britvic have agreed to certain customary provisions if Bidco elects to implement the Acquisition by means of a takeover offer); and (iv) Britvic and Bidco have agreed certain arrangements in respect of Britvic's employees and the Britvic Share Plans, as well as directors' and officers' insurance. Pursuant to the Cooperation Agreement, Bidco shall use, and shall procure that each member of the Carlsberg Group shall use, all reasonable endeavours to achieve and otherwise satisfy the regulatory conditions as promptly as reasonably practicable (and, in any event, in sufficient time so as to enable the Effective Date to occur prior to the Long Stop Date) provided that all reasonable endeavours shall require Bidco to take, or agree to take all actions necessary to satisfy the regulatory conditions set out in paragraphs 3.1 and 3.2 of Part A of Appendix 1 to this announcement (including accepting any relevant remedies), in each case except to the extent that such actions would, individually or in the aggregate, be of material significance to Bidco in the context of the Acquisition (as such material significance standard is or would fall to be determined by the Panel under the Takeover Code), in which case Bidco shall not be required to take, or agree to take, such actions. The Cooperation Agreement shall be terminated with immediate effect (amongst others): (a) if Xxxxx and Britvic so agree in writing at any time prior to the Effective Date; (b) upon service of written notice by Xxxxx to Britvic, if the Britvic Directors change their recommendation in certain circumstances; (c) upon service of written notice by either Bidco to Britvic or Britvic to Bidco, if: (i) the Scheme is not approved by the requisite majority of Britvic Shareholders at the Court Meeting or the Resolutions are not passed by the requisite majority of Britvic Shareholders at the General Meeting; (ii) the Court Meeting and/or the General Meeting are not held on or before the 22nd day after the expected date of the Court Meeting and/or General Meeting; (iii) the Court makes a final determination not to sanction the Scheme; (iv) prior to the Long Stop Date, any Condition has been invoked by Bidco (where the invocation of the relevant Condition has been specifically permitted by the Panel); (v) prior to the Long Stop Date, a "competing proposal" (as defined therein) is recommended in whole or in part by the Britvic Board or completes, becomes effective or is declared or becomes unconditional; or (vi) if the Acquisition lapses, terminates or is withdrawn on or prior to the Long Stop Date other than: (A) as a result of Bidco's right to switch to a takeover offer; or (B) it is otherwise to be followed within six business days by a firm offer announcement made by Bidco (or a person acting in concert with Bidco) to implement the Acquisition by a different offer or scheme on substantially the same or improved terms and which is (or is intended to be) recommended by the Britvic Directors.
