Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
MAINTENANCE OF THE SAID BUILDING / APARTMENT / PROJECT The Promoter shall be responsible to provide and maintain essential services in the Project till the taking over of the maintenance of the project by the association of the allottees. The cost of such maintenance has been included in the Total Price of the [Apartment/Plot]. [Insert any other clauses in relation to maintenance of project, infrastructure and equipment]
Completion of Concrete Pours and Emergency Work 24.14.1 Except as provided in this sub-clause an employee shall not work or be required to work in the rain.
BUILDER’S RISK FOR NEW CONSTRUCTION PROJECTS If the project is NEW CONSTRUCTION, then the following provisions apply:
Access to Property, Property’s Management, Property Lender, and Property Tenants Potential Investor agrees to not seek to gain access to any non-public areas of the Property or communicate with Property’s management employees, the holder of any financing encumbering the Property, the Property’s tenants, and the Owner’s partners in the ownership of the Property, without the prior consent of Owner or HFF, which consent may be withheld in the Owner’s sole discretion.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
BUILDER’S RISK FOR CONSTRUCTION RENOVATION PROJECTS If the project is CONSTRUCTION RENOVATION of an existing structure, and the State has already determined that Contractor will not be obligated to obtain and maintain Builder’s Risk insurance, then the following provisions apply:
Construction Development of the Project The Allottee has seen the proposed layout plan/demarcation-cum-zoning/sanctioned plans, / site plan / building plan, specifications, amenities and facilities, etc. depicted in the advertisement / brochure / agreement / website (as the case may be) regarding the Project where the Said Independent Floor for residential usage along with parking is located and has accepted the floor / site plan, Payment Plan and the specifications, amenities, facilities, etc. [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the bye-laws such as Haryana Building Code, 2017, FAR, density norms, provisions prescribed, approved plans, terms and condition of the license/ allotment as well as registration of RERA, etc. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the provisions and norms prescribed by the relevant State laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act and Rules made thereunder or as per approvals/instructions/ guidelines of the competent authorities, and any breach of this term by the Promoter shall constitute a material breach of the Agreement.
