Common use of Extension of Time for Delay Clause in Contracts

Extension of Time for Delay. 3.14.1 If the work is delayed at any time by reason of a suspension ordered by the CITY or because of any other act of the CITY, or because of neglect by the CITY without contributory fault or neglect on the part of the CONTRACTOR, or if the work should be delayed at any time by reason of strikes, acts of God, the public enemy, acts of the CITY, fire, floods, epidemics, quarantine restrictions, freight embargoes, abnormal force, violence of the elements, or for any 3.14.2 The CONTRACTOR shall file a written request with the CITY for extension of time within ten (10) days following the beginning of such delay, and failure to do so shall constitute a waiver thereof, provided that in case of a continuing cause of delay, only one claim will be necessary. The CITY shall ascertain the facts and the extent of delay, and extend the time for performing the services for the period of the enforced delay when and if in the judgment of the CITY such delay is justified. The CITY’s determination shall be in writing and be final and conclusive upon the parties to this Agreement. 3.14.3 A request for an extension of time or the granting of an extension of time shall not constitute a basis for any claim against the CITY for additional compensation. The CONTRACTOR shall be deemed to have waived any claims for additional compensation and does hereby so waive any such claims unless he shall, at the time of filing a request for an extension of time, likewise file a claim for additional compensation on account of such delay.

Extension of Time for Delay. 3.14.1 3.13.1 If the work is delayed at any time by reason of a suspension ordered by the CITY or because of any other act of the CITY, or because of neglect by the CITY without contributory fault or neglect on the part of the CONTRACTORCONSULTANT, or if the work should be delayed at any time by reason of strikes, acts of God, the public enemy, acts of the CITY, fire, floods, epidemics, quarantine restrictions, freight embargoes, abnormal force, violence of the elements, or for anyany other unforeseen cause beyond the control and without the fault or negligence of the CONSULTANT, or for any other reason which in the opinion of the CONSULTANT is proper justification for such delay, then the 3.14.2 3.13.2 The CONTRACTOR CONSULTANT shall file a written request with the CITY for extension of time within ten (10) days following the beginning of such delay, and failure to do so shall constitute a waiver thereof, provided that in case of a continuing cause of delay, only one claim will be necessary. The CITY shall ascertain the facts and the extent of delay, and extend the time for performing the services for the period of the enforced delay when and if in the judgment of the CITY such delay is justified. The CITY’s determination shall be in writing and be final and conclusive upon the parties to this Agreement. 3.14.3 3.13.3 A request for an extension of time or the granting of an extension of time shall not constitute a basis for any claim against the CITY for additional compensation. The CONTRACTOR CONSULTANT shall be deemed to have waived any claims for additional compensation and does hereby so waive any such claims unless he shall, at the time of filing a request for an extension of time, likewise file a claim for additional compensation on account of such delay.

Extension of Time for Delay. 3.14.1 4.14.1 If the work is delayed at any time by reason of a suspension ordered by the CITY or because of any other act of the CITY, or because of neglect by the CITY without contributory fault or neglect on the part of the CONTRACTORCONSULTANT, or if the work should be delayed at any time by reason of strikes, acts of God, the public enemy, acts of the CITY, fire, floods, epidemics, quarantine restrictions, freight embargoes, abnormal force, violence of the elements, or for anyany other unforeseen cause beyond the control and without the fault or negligence of CONSULTANT, or for any other reason which in the opinion of CONSULTANT is proper justification for such delay, then CONSULTANT shall be entitled to an extension of time equivalent to the time actually lost by such delay. 3.14.2 The CONTRACTOR 4.14.2 CONSULTANT shall file a written request with the CITY for extension of time within ten (10) days following the beginning of such delay, and failure to do so shall constitute a waiver thereof, provided that in case of a continuing cause of delay, only one claim will be necessary. The CITY shall ascertain the facts and the extent of delay, and extend the time for performing the services for the period of the enforced delay when and if in the judgment of the CITY such delay is justified. The CITY’s determination shall be in writing and be final and conclusive upon the parties to this Agreement. 3.14.3 4.14.3 A request for an extension of time or the granting of an extension of time shall not constitute a basis for any claim against the CITY for additional compensation. The CONTRACTOR CONSULTANT shall be deemed to have waived any claims for additional compensation and does hereby so waive any such claims unless he shall, at the time of filing a request for an extension of time, likewise file a claim for additional compensation on account of such delay.

Extension of Time for Delay. 3.14.1 ‌ 4.14.1 If the work is delayed at any time by reason of a suspension ordered by the CITY or because of any other act of the CITY, or because of neglect by the CITY without contributory fault or neglect on the part of the CONTRACTORCONSULTANT, or if the work should be delayed at any time by reason of strikes, acts of God, the public enemy, acts of the CITY, fire, floods, epidemics, quarantine restrictions, freight embargoes, abnormal force, violence of the elements, or for anyany other unforeseen cause beyond the control and without the fault or negligence of CONSULTANT, or for any other reason which in the opinion of CONSULTANT is proper justification for such delay, then CONSULTANT shall be entitled to an extension of time equivalent to the time actually lost by such delay. 3.14.2 The CONTRACTOR 4.14.2 CONSULTANT shall file a written request with the CITY for extension of time within ten (10) days following the beginning of such delay, and failure to do so shall constitute a waiver thereof, provided that in case of a continuing cause of delay, only one claim will be necessary. The CITY shall ascertain the facts and the extent of delay, and extend the time for performing the services for the period of the enforced delay when and if in the judgment of the CITY such delay is justified. The CITY’s determination shall be in writing and be final and conclusive upon the parties to this Agreement. 3.14.3 4.14.3 A request for an extension of time or the granting of an extension of time shall not constitute a basis for any claim against the CITY for additional compensation. The CONTRACTOR CONSULTANT shall be deemed to have waived any claims for additional compensation and does hereby so waive any such claims unless he shall, at the time of filing a request for an extension of time, likewise file a claim for additional compensation on account of such delay.

Extension of Time for Delay. 3.14.1 If the work is delayed at any time by reason of a suspension ordered by the CITY or because of any other act of the CITY, or because of neglect by the CITY without contributory fault or neglect on the part of the INDEPENDENT CONTRACTOR, or if the work should be delayed at any time by reason of strikes, acts of God, the public enemy, acts of the CITY, fire, floods, epidemics, quarantine restrictions, freight embargoes, abnormal force, violence of the elements, or for anyany other unforeseen cause beyond the control and without the fault or negligence of the INDEPENDENT CONTRACTOR, or for any other reason which in the opinion of the INDEPENDENT CONTRACTOR is proper justification for such delay, then the INDEPENDENT CONTRACTOR shall be entitled to an extension of time equivalent to the time actually lost by such delay. 3.14.2 The INDEPENDENT CONTRACTOR shall file a written request with the CITY for extension of time within ten (10) days following the beginning of such delay, and failure to do so shall constitute a waiver thereof, provided that in case of a continuing cause of delay, only one claim will be necessary. The CITY shall ascertain the facts and the extent of delay, and extend the time for performing the services for the period of the enforced delay when and if in the judgment of the CITY such delay is justified. The CITY’s determination shall be in writing and be final and conclusive upon the parties to this Agreement. 3.14.3 A request for an extension of time or the granting of an extension of time shall not constitute a basis for any claim against the CITY for additional compensation. The INDEPENDENT CONTRACTOR shall be deemed to have waived any claims for additional compensation and does hereby so waive any such claims unless he shall, at the time of filing a request for an extension of time, likewise file a claim for additional compensation on account of such delay.