Extensions of Time 34.1 If at any time during performance of the Contract, the Supplier or its subcontractors should encounter conditions impeding timely delivery of the Goods or completion of Related Services pursuant to GCC Clause 13, the Supplier shall promptly notify the Procuring Entity in writing of the delay, its likely duration, and its cause. As soon as practicable after receipt of the Supplier's notice, the Procuring Entity shall evaluate the situation and may at its discretion extend the Supplier's time for performance, in which case the extension shall be ratified by the parties by amendment of the Contract.
Extensions and Renewals All extensions or renewals of leaves shall be applied for and granted in writing.
DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.
Modifications of Agreement This Agreement may be modified in writing only, signed by the parties in interest at the time of the modification.
PROVISIONS OF LAW β It is understood and agreed that this Memorandum of Understanding is subject to all current and future applicable Federal, State and County laws; Federal and State regulations; the Charter of the County of Los Angeles, and any lawful rules and regulations enacted by County's Civil Service Commission, Employee Relations Commission, or similar independent commissions of the County. If any part or provision of this Memorandum of Understanding is in conflict or inconsistent with such applicable laws, rules or regulations, or is otherwise held to be invalid or unenforceable by any tribunal of competent jurisdiction, such part or provision shall be suspended and superseded by such applicable law, regulations, or rules, and the remainder of this Memorandum of Understanding shall not be affected thereby.
CONCLUSIONS OF LAW 4 1. The conduct described in the Findings of Fact constitute grounds for disciplinary 5 action pursuant to A.R.S. §§ 32-3552(A)(1) and (3) and violate the provisions of A.R.S. Β§ 32- 6 3501(9)(i) which states, βAny conduct or practice which is contrary to recognized standards of 7 ethics of the respiratory therapy profession or any conduct or practice which does or might 8 constitute a danger to the health, welfare or safety of the patient or the public.β
Decisions of the Board The decision of the majority shall be the decision of the Board. Where there is no majority decision, the decision of the Chairperson shall be the decision of the Board. The decision of the Board of Arbitration shall be final and binding and enforceable on all parties, but in no event shall the Board of Arbitration have the power to change this Agreement or to alter, modify or amend any of its provisions. However, the Board shall have the power to dispose of any discharge or a discipline grievance by any arrangement which in its opinion it deems just and equitable.
Conditions of Approval Project Specific Conditions
Conditions of Agreement This is a tentative Agreement and shall be of no force and effect unless and until all of the following occur:
Obligations of City 8.1 City shall β
