Payment Does Not Imply Acceptance of Work The granting of any payment by City, or the receipt thereof by Contractor, shall in no way lessen the liability of Contractor to replace unsatisfactory work, equipment, or materials, although the unsatisfactory character of such work, equipment or materials may not have been apparent or detected at the time such payment was made. Materials, equipment, components, or workmanship that do not conform to the requirements of this Agreement may be rejected by City and in such case must be replaced by Contractor without delay.
Notification of Xxxxxx and Unauthorized Release (a) Vendor will promptly notify the District of any breach or unauthorized release of Protected Data it has received from the District in the most expedient way possible and without unreasonable delay, but no more than seven (7) calendar days after Vendor has discovered or been informed of the breach or unauthorized release.
(b) Vendor will provide such notification to the District by contacting Xxxxxx Xxx, Data Protection Officer, directly by email at xxxxxx.xxx@xxxxx.xxx or by calling 000-000-0000.
(c) Vendor will cooperate with the District and provide as much information as possible directly to Xxxxxx Xxx, Data Protection Officer or his/her designee about the incident, including but not limited to: a description of the incident, the date of the incident, the date Vendor discovered or was informed of the incident, a description of the types of Protected Data involved, an estimate of the number of records affected, the schools within the District affected, what the Vendor has done or plans to do to investigate the incident, stop the breach and mitigate any further unauthorized access or release of Protected Data, and contact information for Vendor representatives who can assist affected individuals that may have additional questions.
(d) Vendor acknowledges that upon initial notification from Vendor, the District, as the educational agency with which Vendor contracts, has an obligation under Section 2-d to in turn notify the Chief Privacy Officer in the New York State Education Department (“CPO”). Vendor agrees not to provide this notification to the CPO directly unless requested by the District or otherwise required by law. In the event the CPO contacts Vendor directly or requests more information from Vendor regarding the incident after having been initially informed of the incident by the District, Vendor will promptly inform Xxxxxx Xxx, Data Protection Officer or his/her designee.
Inspection; Acceptance The Contractor (immixTechnology, Inc.) can only, and shall only tender for acceptance those items that substantially conform to the software manufacturer’s (“Qualtrics”) published specifications. Therefore, items delivered shall be considered accepted upon delivery. The Government reserves the right to inspect or test any supplies or services that have been delivered. The Government may require repair or replacement of nonconforming supplies or re-performance of nonconforming services at no increase in contract price. If repair/replacement or re-performance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights-(1) Within the warranty period; and (2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.
Required Acceptance of Daily Load Deliveries and Notification If the State is harmed by purchaser’s refusal to accept up to 10 truck deliveries of any one sort per day, Purchaser will be in breach of contract and subject to damages as per the D-026.2 and D-027.2 clauses. A truck delivery is all the wood delivered including sorts on super trucks, mule trains and pups brought to the delivery point by a single truck. The Purchaser shall notify the Contract Administrator at least 48 hours in advance if:
1. Purchaser intends to limit the number of truck deliveries accepted on any day to less than that listed above, or
2. Purchaser intends to limit the number of truck deliveries accepted on any day to the number listed above.
Unauthorized Access Notification XXX shall notify Provider promptly of any known unauthorized access. XXX will assist Provider in any efforts by Provider to investigate and respond to any unauthorized access.
NON-ACCEPTANCE OF SETTLEMENT AGREEMENT If, for any reason whatsoever, this Settlement Agreement is not accepted by the Hearing Panel or an Order in the form attached as Schedule “A” is not made by the Hearing Panel, each of Staff and the Respondent will be entitled to any available proceedings, remedies and challenges, including proceeding to a disciplinary hearing pursuant to sections 20 and 24 of By- law No. 1, unaffected by this Settlement Agreement or the settlement negotiations.
PRODUCT ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor in the Authorized User Agreement, Authorized User(s) shall have sixty (60) days from the date of delivery to accept all Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Title or other property interest and risk of loss shall not pass from Contractor to the Authorized User until the Products have been accepted. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty
COMMENCEMENT OF WORK UNDER A SOW AGREEMENT Commencement of work as a result of the SOW-RFP process shall be initiated only upon issuance of a fully executed SOW Agreement and Purchase Order.
Acceptance of Order We may in our sole discretion accept an Order in whole or in part. An Order is accepted by us through our trading platform.
Delivery and Acceptance of the Manuscript The Author shall deliver the Contribution to the Editor (or, if requested by the Publisher, to the Publisher) on or before Delivery Date (the “Delivery Date”) electronically in the Publisher's standard requested format or in such other form as may be agreed in writing with the Publisher. The Author shall retain a duplicate copy of the Contribution. The Contribution shall be in a form acceptable to the Publisher (acting reasonably) and in line with the instructions contained in the Publisher’s guidelines as provided to the Author by the Publisher. The Author shall provide at the same time, or earlier if the Publisher reasonably requests, any editorial, publicity or other information (and in such form or format) reasonably required by the Publisher. The Publisher may exercise such additional quality control of the manuscript as it may decide at its sole discretion including through the use of plagiarism checking systems and/or peer review by internal or external reviewers of its choice. If the Publisher decides at its sole discretion that the final manuscript does not conform in quality, content, structure, level or form to the stated requirements of the Publisher, the Publisher shall be entitled to terminate this Agreement in accordance with the provisions of this Clause. The Author must inform the Publisher at the latest on the Delivery Date if the sequence of the naming of any co-authors entering into this Agreement shall be changed. If there are any changes in the authorship (e.g. a co-author joining or leaving), then the Publisher must be notified by the Author in writing immediately and the Parties will amend this Agreement accordingly. The Publisher shall have no obligation to consider publication under this Agreement in the absence of such agreed amendment. If the Author fails to deliver the Contribution in accordance with the provisions of this Clause above by the Delivery Date (or within any extension period given by the Publisher at its sole discretion) or if the Author (or any co-author) dies or becomes incapacitated or otherwise incapable of performing the Author’s obligations under this Agreement, the Publisher shall be entitled to either: (a) elect to continue to perform this Agreement in accordance with its terms and the Publisher may commission an appropriate and competent person (who, in the case of co-authors having entered into this Agreement, may be a co-author) to complete the Contribution; or (b) terminate this Agreement with immediate effect by written notice to the Author or the Author's successors, in which case all rights granted by the Author to the Publisher under this Agreement shall revert to the Author/Author's successors (subject to the provisions of the Clause "Termination"). The Author agrees, at the request of the Publisher, to execute all documents and do all things reasonably required by the Publisher in order to confer to the Publisher all rights intended to be granted under this Agreement. The Author warrants that the Contribution is original except for any excerpts from other works including pre-published illustrations, tables, animations, text quotations, photographs, diagrams, graphs or maps, and whether reproduced from print or electronic or other sources ("Third Party Material") and that any such Third Party Material is in the public domain (or otherwise unprotected by copyright/other rights) or has been included with written permission from or on behalf of the rights holder (and if requested in a form prescribed or approved by the Publisher) at the Author's expense unless otherwise agreed in writing, or is otherwise used in accordance with applicable law. On request from the Publisher, the Author shall in writing indicate the precise sources of these excerpts and their location in the manuscript. The Author shall also retain the written permissions and make them available to the Publisher on request.
