Failure to Satisfy Conditions If the Secured Party or its Custodian fails to satisfy any conditions for holding Posted Collateral, then upon a demand made by the Pledgor, the Secured Party will, not later than five Local Business Days after the demand, Transfer or cause its Custodian to Transfer all Posted Collateral held by it to a Custodian that satisfies those conditions or to the Secured Party if it satisfies those conditions.
Outage Restoration If an outage on the Attachment Facilities or System Upgrade Facilities or System Deliverability Upgrades of the Connecting Transmission Owner or Developer adversely affects the other Party’s operations or facilities, the Party that owns the facility that is out of service shall use Reasonable Efforts to promptly restore such facility(ies) to a normal operating condition consistent with the nature of the outage. The Party that owns the facility that is out of service shall provide the other Party and NYISO, to the extent such information is known, information on the nature of the Emergency State, an estimated time of restoration, and any corrective actions required. Initial verbal notice shall be followed up as soon as practicable with written notice explaining the nature of the outage.
Failure to Complete If Artist becomes ill, dies, or is otherwise unable or unwilling to complete the Project in accordance with the Agreement, any work already done on the Project will be the City’s property. The City will be entitled to withhold any sums not yet paid to Artist, and may use any such sums toward completion of the Project in any manner the City deems appropriate.
Failure to Fulfill Conditions In the event that either of the parties hereto determines that a condition to its respective obligations to consummate the transactions contemplated hereby cannot be fulfilled on or prior to the termination of this Agreement, it will promptly notify the other party.
Incident Notice and Remediation If Contractor becomes aware of any Incident, it shall notify the State immediately and cooperate with the State regarding recovery, remediation, and the necessity to involve law enforcement, as determined by the State. Unless Contractor can establish that none of Contractor or any of its agents, employees, assigns or Subcontractors are the cause or source of the Incident, Contractor shall be responsible for the cost of notifying each person who may have been impacted by the Incident. After an Incident, Contractor shall take steps to reduce the risk of incurring a similar type of Incident in the future as directed by the State, which may include, but is not limited to, developing and implementing a remediation plan that is approved by the State at no additional cost to the State.
SAFETY CONDITIONS 8.1 The District shall make every effort to provide a place of employment which is safe. A unit member shall not be required to perform duties under conditions which endanger his/her health or safety.
8.2 The District shall make a good faith effort to reduce or alleviate those conditions which cause stress. The reduction of threats or intimidation by students or other members of the public shall be a continuous effort of both the District and unit members working together.
8.3 Unit members who feel they are being required to work under unsafe or unsanitary conditions, or to perform tasks that endanger their health or safety, shall submit written recommendations for changes to the principal or site administrator. The principal or site administrator shall respond and take corrective action as needed.
8.4 The District shall ensure that each unit member has access to a lockable desk, cupboard or other lockable space.
8.5 Unit members other than the school nurse, shall not be required to provide specialized physical health care.
8.6 Unit members are authorized to administer discipline to students in accordance with the Education Code and the rules and regulations of the District. A written description of the rights and duties of unit members with respect to student discipline shall be provided to unit members at the beginning of each school year. In addition, said written descriptions shall be available at each school site. The District shall not take action against a unit member who uses reasonable and lawful force in the performance of his/her duties. Unit members shall report any physical assault against the unit member to the principal or site administrator, who shall report the incident to the appropriate law enforcement agency.
8.7 During conditions of excessive heat, the Superintendent or designee, whenever appropriate, will reduce the school day for students in schools with non-operable air conditioning, to the State required minimum day. Unit members may be directed to proceed to a district air conditioned location for the remainder of the service day. The Superintendent or designee shall have the discretion to reduce the school day to the State required minimum day whenever other weather conditions pose a danger to students and unit members. Unit members may be directed to proceed to another District location for the remainder of the service day.
8.8 For protection of unit members whose normal duties may require transportation of students in unit member's vehicles, the District shall provide secondary insurance against personal liability for damages for death, injury to a person, or damage or loss of property caused by the negligent act or omission of the unit member when acting within the scope of his/her employment. Additionally, the District will provide this same coverage to unit members who are required to travel from site-to- site or make home visitations in order to perform assigned duties. When a loss occurs, the unit member's primary insurance deductible will be reimbursed up to a maximum of $500.00. If administrator approval is unobtainable, the teacher's best judgment for the protection of student safety shall be included in the above.
8.9 Restrooms shall be available to unit members whenever they are required to render service.
8.10 Adequate lounge facilities shall be provided for unit members' use. Additionally, the District shall provide, when fiscally possible, at least one piece of furniture per site where a staff member may recline. The site safety committee shall determine the placement of these facilities and furniture.
8.11 Unit members shall have the right to refer to the office, a student who exhibits symptoms of illness which endanger the health of other students or the unit member. The student shall not return to the classroom until it is determined by the principal/site administrator that his/her health is not a clear and present danger to those with whom he/she shares space. The student shall be given a pass to return to class signed by the principal/site administrator confirming the decision.
8.12 The District shall reimburse or repair articles of clothing, glasses and hearing aids damaged while the unit member is acting in the proper discharge of disciplinary/ supervisorial duties. In addition, all other accessories damaged under the conditions listed above shall be reimbursed up to a maximum of $200.00.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Landlord’s Work Prior to the execution of the Lease, Landlord and Tenant have approved the detailed description of base, shell and core work for the Phase I Premises and Phase II Premises attached hereto as Exhibit B-1 (the “Base, Shell and Core Description”). Based upon and in conformity with the Base Shell and Core Description, Landlord shall cause its architect and engineers, at Landlord’s sole cost and expense, to prepare and deliver to Tenant, for Tenant’s approval, detailed specifications and engineered working drawings in CAD format, which shall include, without limitation, ADA path of travel, restroom locations and counts, exit lighting plans for the Phase I Work (the “Base Building Working Drawings”) by no later than June 1, 2019. Within seven (7) days after Tenant’s and Landlord’s receipt of the Base Building Working Drawings, Tenant and Landlord shall approve or disapprove the same, which approval shall not be unreasonably withheld; provided, however, that Tenant may only disapprove the Base Building Working Drawings to the extent such Base Building Working Drawings are inconsistent with the Base, Shell and Core Description and only if Tenant delivers notice thereof to Landlord within such seven (7) day period. If any specific changes proposed by Tenant to rectify any inconsistencies with the Base, Shell and Core Description are timely and properly proposed by Tenant, Landlord shall cause its architect and engineers to revise the Base Building Working Drawings to incorporate such revisions and submit the same for Tenant’s approval in accordance with the foregoing provisions, and the parties shall follow the foregoing procedures for approving the Base Building Working Drawings until the same are finally approved by Landlord and Tenant. Upon Landlord’s and Tenant’s approval of the Base Building Working Drawings, the same shall be referred to as the “Approved Working Drawings for Landlord’s Phase I Work”. Based upon and in conformity with the Base, Shell and Core Description, Landlord shall cause its architect and engineers, at Landlord’s sole cost and expense, to prepare and deliver to Tenant, for Tenant’s approval, detailed specifications and engineered working drawings in CAD format, which shall include, without limitation, ADA path of travel, restroom locations and counts, exit lighting plans for the Phase II Work (the “Phase II Base Building Working Drawings”) by no later than October 1, 2019. Within seven (7) days after Tenant’s and Landlord’s receipt of the Phase II Base Building Working Drawings, Tenant and Landlord shall approve or disapprove the same, which approval shall not be unreasonably withheld; provided, however, that Tenant may only disapprove the Phase II Base Building Working Drawings to the extent such Phase II Base Building Working Drawings are inconsistent with the Base, Shell and Core Description and only if Tenant delivers notice thereof to Landlord within such seven (7) day period. If any specific changes proposed by Tenant to rectify any inconsistencies with the Base, Shell and Core Description are timely and properly proposed by Tenant, Landlord shall cause its architect and engineers to revise the Phase II Base Building Working Drawings to incorporate such revisions and submit the same for Tenant’s approval in accordance with the foregoing provisions, and the parties shall follow the foregoing procedures for approving the Phase II Base Building Working Drawings until the same are finally approved by Landlord and Tenant. Upon Landlord’s and Tenant’s approval of the Phase II Base Building Working Drawings, the same shall be referred to as the “Approved Working Drawings for Landlord’s Phase II Work”. The improvements shown on the Approved Working Drawings for Landlord’s Phase I Work and the Approved Working Drawings for Landlord’s Phase II Work are hereby collectively referred to as “Landlord’s Work”. The Approved Working Drawings for Landlord’s Phase I Work and the Approved Working Drawings for Landlord’s Phase II Work are sometimes collectively referred to herein as the “Approved Working Drawings for Landlord’s Work”.
Tenant’s Compliance Tenant shall materially comply with all Applicable Laws and operational registrations and licenses, including without limitation, the Marijuana Code, and shall promptly comply with all governmental orders and directives for the correction, prevention, and abatement of any nuisances and any violation of Applicable Laws in, upon, or connected with the Premises, all at Tenant’s sole expense. Tenant warrants that all improvements or alterations of the Premises made by Tenant or Tenant’s employees, agents or contractors, either prior to Tenant’s occupancy of the Premises or during the Term, will comply with all Applicable Laws, including any and all on site security requirements set forth under Applicable Laws or as otherwise reasonably required by Landlord given the safety concerns associated with the Permitted Use hereunder. In the event that (i) Tenant’s specific use and occupancy of the Premises, or (ii) any alterations to the Premises performed by or on behalf of Tenant pursuant to this Lease, necessitates or triggers any modifications (including structural modifications) to the Premises or Buildings or alterations to the Buildings systems, the same shall be made by Landlord pursuant to a budget reasonably agreed upon by Landlord and Tenant and promptly reimbursed by Tenant within thirty (30) days after written demand by Landlord, including backup substantiating Tenant’s proportionate share of the expenses. In addition, Tenant warrants that its use of the Premises will be in material compliance with all Applicable Laws subject to the Legal Compliance Clarification.
Retainage for Unacceptable Corrective Action Plan or Plan Failure If the corrective action plan is unacceptable to the Department or Customer, or implementation of the plan fails to remedy the performance deficiencies, the Department or Customer will retain ten percent (10%) of the total invoice amount. The retainage will be withheld until the Contractor resolves the performance deficiencies. If the performance deficiencies are resolved, the Contractor may invoice the Department or Customer for the retained amount. If the Contractor fails to resolve the performance deficiencies, the retained amount will be forfeited to compensate the Department or Customer for the performance deficiencies.
