Faultless Final Acceptance Report faultless report signed by the Parties, stating the delivery of faultless brand-new laboratory equipment which is the Subject of the Agreement along with its technical documentation;
Faultless Final Acceptance Report Sample Clauses
Related to Faultless Final Acceptance Report
Final Acceptance When the Project/Service or any portion thereof, as designated by the COUNTY, is ready for its intended use, the COUNTY and any other invited parties shall make an inspection of the Project/Service, to verify its completeness and develop a punch list of items needing completion or correction before final payment will be made. CONTRACTOR shall have ten (10) calendar days to correct all deficiencies. An eighty-dollar ($80.00) re-inspection fee shall be applied for the third inspection and any required re-inspection thereafter. The COUNTY shall have the right to exclude CONTRACTOR from those portions of the work designated as complete after the inspection; provided, however, that CONTRACTOR will have reasonable access for the time allotted by the COUNTY to complete or correct items on the punch list. When the work provided for under this Agreement has been completely performed by CONTRACTOR, and the final inspection has been made by the COUNTY, a final invoice will be prepared by the CONTRACTOR. The amount of this invoice, less any sums that may have been deducted or retained under the provisions of this Agreement, will be paid to CONTRACTOR in accordance with this Agreement, and after CONTRACTOR has agreed in writing to accept the balance due, as determined by the COUNTY, as full settlement of the account under the contract and of all claims in connection therewith. Occupancy by the COUNTY alone does not constitute final acceptance.
Inspection and Final Acceptance District may, at its discretion, inspect and accept or reject any of Consultant’s work under this Agreement, either during performance or when within sixty (60) days after submitted to District. If District does not reject work by a timely written explanation, Consultant’s work shall be deemed to have been accepted. District’s acceptance shall be conclusive as to such work except with respect to latent defects, fraud and such gross mistakes as amount to fraud. Acceptance of any of Consultant’s work by District shall not constitute a waiver of any of the provisions of this Agreement including, but not limited to indemnification and insurance provisions.
361 Acceptance of Specified Roads Specified Road work may be accepted subject to completion of clearing work that does not affect the road structure when completion is delayed for reasons beyond control of Purchaser, such as adverse weather. Specified Road work may be accepted subject to completion of planting and seeding for soil stabilization when completion is delayed for reasons beyond control of Purchaser, such as seasonal limitations. Purchaser shall complete planting or seeding on such road during the next suitable planting season. Specified Road work may be conditionally accepted prior to the application of dust palliatives when application is not necessary to prevent dusting of the road surface due to climatic conditions. Purchaser shall apply dust palliative on such roads prior to use during periods when dusting may occur. Prior to request for final inspection, Specified Road work, roadways, borrow pits, and quarries, occupied and no longer needed by Purchaser in connection with Purchaser’s Operations, shall be cleared of all rubbish, excess materials, and temporary structures.
Additional Acceptable Uses of Student Data Contractor is prohibited from using Student Data for any secondary use not described in this agreement except:
ADDITIONAL SPECIAL CONTRACT CONDITIONS A. Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:
Requesting Price Increase/Required Documentation Contractor must submit a written notification at least thirty (30) calendar days prior to the requested effective date of the change, setting the amount of the increase, along with an itemized list of any increased prices, showing the Contractor’s current price, revised price, the actual dollar difference and the percentage of the price increase by line item. Price change requests must include H-GAC Forms D Offered Item Pricing and E Options Pricing, or the documentation used to submit pricing in the original Response and be supported with substantive documentation (e.g. manufacturer's price increase notices, copies of invoices from suppliers, etc.) clearly showing that Contractor's actual costs have increased per the applicable line item bid. The Producer Price Index (PPI) may be used as partial justification, subject to approval by H-GAC, but no price increase based solely on an increase in the PPI will be allowed. This documentation should be submitted in Excel format to facilitate analysis and updating of the website. The letter and documentation must be sent to the Bids and Specifications manager, Xxxxxxx Xxxxxx, at Xxxxxxx.Xxxxxx@x-xxx.xxx Review/Approval of Requests If H-GAC approves the price increase, Contractor will be notified in writing; no price increase will be effective until Contractor receives this notice. If H-GAC does not approve Contractor’s price increase, Contractor may terminate its performance upon sixty (60) days advance written notice to H-GAC, however Contractor must fulfill any outstanding Purchase Orders. Termination of performance is Contractor’s only remedy if H-GAC does not approve the price increase. H-GAC reserves the right to accept or reject any price change request.
Equipment Specifications All equipment must meet the contract specifications and all federal and State safety codes and regulations in effect at the date of manufacture. All equipment must be Original Equipment Manufacturer (OEM) equipment unless otherwise stated in the contract. Items Offered as New. All products, materials, supplies, replacement parts, and equipment offered and furnished must be new, of current manufacturer production, and must have been formally announced by the manufacturer as being commercially available, unless otherwise stated in this Contract.
How Do I Get More Information? For more information, including the full Notice, Claim Forms and Settlement Agreement go to xxx.xxxxxxxxxxxxxxxxxxxx.xxx, contact the settlement administrator at 0-000-000-0000, or call Class Counsel at 1-866-354-3015. Exhibit E UNITED STATES DISTRICT COURT FOR THE SOUTHERN DISTRICT OF FLORIDA Xxxxx v. AvMed, Inc., Case No. 10-cv-24513 If You Paid for or Received Insurance from AvMed, Inc. at Any Time Through December of 2009, You May Be Part of a Class Action Settlement. IMPORTANT: PLEASE READ THIS NOTICE CAREFULLY. THIS NOTICE RELATES TO THE PENDENCY OF A CLASS ACTION LAWSUIT AND, IF YOU ARE A MEMBER OF THE SETTLEMENT CLASSES, CONTAINS IMPORTANT INFORMATION ABOUT YOUR RIGHTS TO MAKE A CLAIM UNDER THE SETTLEMENT OR TO OBJECT TO THE SETTLEMENT (A federal court authorized this notice. It is not a solicitation from a lawyer.) Your legal rights are affected whether or not you act. Please read this notice carefully. YOUR LEGAL RIGHTS AND OPTIONS IN THIS SETTLEMENT SUBMIT A CLAIM FORM This is the only way to receive a payment. EXCLUDE YOURSELF You will receive no benefits, but you will retain any rights you currently have to xxx the Defendant about the claims in this case. OBJECT Write to the Court explaining why you don’t like the Settlement. GO TO THE HEARING Ask to speak in Court about your opinion of the Settlement. DO NOTHING You won’t get a share of the Settlement benefits and will give up your rights to xxx the Defendant about the claims in this case. These rights and options – and the deadlines to exercise them – are explained in this Notice. QUESTIONS? CALL 0-000-000-0000 TOLL FREE, OR VISIT XXX.XXXXXXXXXXXXXXXXXXXX.XXX PARA UNA NOTIFICACIÓN EN ESPAÑOL, LLAMAR O VISITAR NUESTRO WEBSITE BASIC INFORMATION
Technical Specification As enumerated in Special Conditions of Contract/Scope of Work/attached Drawing/ Details/Schedule of Rates.
Initial Forecasts/Trunking Requirements Because Verizon’s trunking requirements will, at least during an initial period, be dependent on the Customer segments and service segments within Customer segments to whom CSTC decides to market its services, Verizon will be largely dependent on CSTC to provide accurate trunk forecasts for both inbound (from Verizon) and outbound (to Verizon) traffic. Verizon will, as an initial matter, provide the same number of trunks to terminate Reciprocal Compensation Traffic to CSTC as CSTC provides to terminate Reciprocal Compensation Traffic to Verizon. At Verizon’s discretion, when CSTC expressly identifies particular situations that are expected to produce traffic that is substantially skewed in either the inbound or outbound direction, Verizon will provide the number of trunks CSTC suggests; provided, however, that in all cases Verizon’s provision of the forecasted number of trunks to CSTC is conditioned on the following: that such forecast is based on reasonable engineering criteria, there are no capacity constraints, and CSTC’s previous forecasts have proven to be reliable and accurate.
