Trustee to Retain Possession of Certain Insurance Policies and Documents The Trustee (or the Custodian, as directed by the Trustee), shall retain possession and custody of the originals (to the extent available) of any Primary Mortgage Insurance Policies, or certificate of insurance if applicable, and any certificates of renewal as to the foregoing as may be issued from time to time as contemplated by this Agreement. Until all amounts distributable in respect of the Certificates have been distributed in full and the Master Servicer otherwise has fulfilled its obligations under this Agreement, the Trustee (or its Custodian, if any, as directed by the Trustee) shall also retain possession and custody of each Mortgage File in accordance with and subject to the terms and conditions of this Agreement. The Master Servicer shall promptly deliver or cause to be delivered to the Trustee (or the Custodian, as directed by the Trustee), upon the execution or receipt thereof the originals of any Primary Mortgage Insurance Policies, any certificates of renewal, and such other documents or instruments that constitute portions of the Mortgage File that come into the possession of the Master Servicer from time to time.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
LOCATION AND DESCRIPTION OF THE PROPERTY The subject property is a single-storey terraced house bearing the postal address of Xx. 00, Xxxxxx 00/XX0, Xxxxxx Xxxxx Xxxxxxx, 00000 Xxxxxxx Xxxxx, Xxxxxx. The subject property will be sold on an “as is where is basis” and subject to a reserve price of RM310,000.00 (RINGGIT MALAYSIA THREE HUNDRED TEN THOUSAND ONLY) and subject to the Conditions of Sale and by way of an Assignment from the above Assignee/Bank subject to the consent being obtained by the Purchaser from the Developer and other relevant authorities if any, including all terms, conditions, stipulations and covenants which were and may be imposed by the Developer and the relevant authorities. Any arrears of quit rent, assessments and service or maintenance charges which may be lawfully due to any relevant authority or the Developer up to the date of auction sale of the property shall be paid out of the purchase money upon receipt of full purchase price. All other fees, costs and charges relating to the transfer and assignment of the property shall be borne by the successful Purchaser. Online bidders are further subject to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx. All intending bidders are required to deposit 10% of the fixed reserve price for the said property by Bank Draft or Cashier’s Order in favour of UOBM for KRISHNAMAL A/P MURLIGIAH & XXXXXXXXXXX A/L XXXXXXX or remit the same through online banking transfer, one (1) working day before auction date. The balance of the purchase money shall be paid by the Purchaser within one hundred and twenty (120) days from the date of auction sale to UNITED OVERSEAS BANK (MALAYSIA) BHD via Real Time Electronics Transfer of Funds and Securities (XXXXXX). For online bidders please refer to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx on the manner of payment of the deposit. FOR FURTHER PARTICULARS, please contact M/S HOE & MOIRA, of Xxxxx 000X (Xxxxx), 0xx Xxxxx, Xxxxx Xxxxxx Xxxxxx, Xxxxxxxxxx Xxxx, 00000 Xxxxxx, Xxxxxxxx. (Ref:H&M/MT/Z4P/CB23/16) Tel.: 00-000 0000, Fax: 00-000 0000) the Assignee herein or the undermentioned Auctioneer. Suite C-20-3A, Level 20, Block C, Megan Avenue II, / XXXXX XXXXX BIN XXXXXX 00, Xxxxx Xxx Xxxx Xxxx, 50450 Kuala Lumpur (Licensed Auctioneers) Tel No.: 00-0000 0000 Fax No.: 00-0000 0000 Our Ref: LIAN/UOB1035HM Website: xxx.xxxxxxxxxxxxxxxx.xxx E-mail: xxxx@xxxxxxxxxxxxxxxx.xxx [berkuatkuasa dari 1.11.2022, perniagaan perbankan pengguna (consumer banking business) CITIBANK BERHAD (No. Syarikat: 199401011410 (297089-M) telah dipindahmilik kepada xxx diletakhakkan kepada UOB di bawah Perintah Letakhak bertarikh 12.10.2022 melalui Mahkamah Tinggi Kuala Lumpur Saman Pemula No. WA-24NCC-903-09/2022] Dalam menjalankan xxx xxx kuasa xxxx telah diberikan kepada Pihak Pemegang Serahhak/Bank dibawah Perjanjian Kemudahan, Penyerahanhak xxx Surat Kuasa Wakil kesemuanya Bertarikh 09hb Julai, 2001 diantara Pihak Penyerahhak, Pihak Pelanggan xxx Pihak Pemegang Serahhak/Bank yang diperbuat dalam perkara diatas, adalah dengan ini diisytiharkan bahawa Pihak Pemegang Serahhak/Bank tersebut dengan bantuan Pelelong yang tersebut dibawah.
Skidding and Yarding Methods of skid- ding or yarding specified for particular areas, if any, are indicated on Sale Area Map. Outside Clearcutting Units and construction clearings, insofar as ground conditions permit, products shall not be skidded against reserve trees or groups of reproduction and tractors shall be equipped with a winch to facilitate skidding. B6.421 Rigging. Insofar as practicable, needed rigging shall be slung on stumps or trees desig- nated for cutting.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Certification Regarding Prohibition of Certain Terrorist Organizations (Tex Gov. Code 2270) Certification Regarding Prohibition of Boycotting Israel (Tex. Gov. Code 2271) 5 Certification Regarding Prohibition of Contracts with Certain Foreign-Owned Companies (Tex. Gov. 5 Code 2274) 5 Certification Regarding Prohibition of Discrimination Against Firearm and Ammunition Industries (Tex.
Restrictions on chartering, appointment of managers etc The Borrower shall procure that no Owner shall: (a) let the Ship owned by it on demise charter for any period; (b) other than the relevant Initial Charterparty or Future Charterparty, enter into any time or consecutive voyage charter in respect of the Ship owned by it for a term which exceeds, or which by virtue of any optional extensions may exceed, 11 months; (c) change the terms on which the Ship owned by it is employed or the identity of the person by whom that Ship is employed; (d) enter into any charter in relation to the Ship owned by it under which more than 2 months’ hire (or the equivalent) is payable in advance; (e) charter the Ship owned by it otherwise than on bona fide arm’s length terms at the time when the Ship is fixed; (f) appoint a manager of the Ship owned by it other than an Approved Manager or agree to any alteration to the terms of an Approved Manager’s appointment; (g) de-activate or lay up the Ship owned by it; or (h) put the Ship owned by it into the possession of any person for the purpose of work being done upon her in an amount exceeding or likely to exceed $250,000 (or the equivalent in any other currency) unless that person has first given to the Security Trustee and in terms satisfactory to it a written undertaking not to exercise any lien on the Ship or her Earnings for the cost of such work or otherwise.
Term of Agreement; Resignation and Removal of the Administrator (a) This Agreement shall continue in force until the dissolution of the Issuing Entity, upon which event this Agreement shall automatically terminate. (b) Subject to Section 8(e), the Administrator may resign its duties hereunder by providing the Issuing Entity, the Trustee, the Indenture Trustee and the Servicer with at least 60 days’ prior written notice. (c) Subject to Section 8(e), the Issuing Entity may remove the Administrator without cause by providing the Administrator, the Trustee, the Indenture Trustee and the Servicer with at least 60 days’ prior written notice. (d) Subject to Section 8(e), at the sole option of the Issuing Entity, the Administrator may be removed immediately upon written notice of termination from the Issuing Entity to the Administrator, the Trustee, the Indenture Trustee and the Servicer if any of the following events shall occur: (i) the Administrator shall default in the performance of any of its duties under this Agreement and, after notice of such default, shall not cure such default within ten days (or, if such default cannot be cured in such time, shall not give within ten days such assurance of cure as shall be reasonably satisfactory to the Issuing Entity); (ii) a court having jurisdiction in the premises shall enter a decree or order for relief, and such decree or order shall not have been vacated within 60 days, in respect of the Administrator in any involuntary case under any applicable bankruptcy, insolvency or other similar law now or hereafter in effect or appoint a receiver, liquidator, assignee, custodian, trustee, sequestrator or similar official for the Administrator or any substantial part of its property or order the winding-up or liquidation of its affairs; or (iii) the Administrator shall commence a voluntary case under any applicable bankruptcy, insolvency or other similar law now or hereafter in effect, shall consent to the entry of an order for relief in an involuntary case under any such law, or shall consent to the appointment of a receiver, liquidator, assignee, trustee, custodian, sequestrator or similar official for the Administrator or any substantial part of its property, shall consent to the taking of possession by any such official of any substantial part of its property, shall make any general assignment for the benefit of creditors or shall fail generally to pay its debts as they become due. The Administrator agrees that if any of the events specified in clauses (ii) or (iii) of this subsection shall occur, it shall give written notice thereof to the Issuing Entity, the Servicer, the Trustee and the Indenture Trustee within seven days after the happening of such event. (e) Upon the Administrator’s receipt of notice of termination, pursuant to Sections 8(c) or (d), or the Administrator’s resignation in accordance with this Agreement, the predecessor Administrator shall continue to perform its functions as Administrator under this Agreement, in the case of termination, only until the date specified in such termination notice or, if no such date is specified in a notice of termination, until receipt of such notice and, in the case of resignation, until the later of: (x) the date 45 days from the delivery to the Issuing Entity, the Trustee, the Indenture Trustee and the Servicer of written notice of such resignation (or written confirmation of such notice) in accordance with this Agreement and (y) the date upon which the predecessor Administrator shall become unable to act as Administrator, as specified in the notice of resignation and accompanying Opinion of Counsel. In the event of the Administrator’s termination hereunder, the Issuing Entity shall appoint a successor Administrator acceptable to the Indenture Trustee, and the successor Administrator shall accept its appointment by a written assumption in form acceptable to the Indenture Trustee. In the event that a successor Administrator has not been appointed at the time when the predecessor Administrator has ceased to act as Administrator in accordance with this Section, and if the predecessor Administrator is currently serving as the Servicer under the Transaction Documents, the Indenture Trustee without further action shall automatically be appointed the successor Administrator and the Indenture Trustee shall be entitled to the compensation specified in Section 3. Notwithstanding the above, the Indenture Trustee shall, if it shall be unable so to act, appoint or petition a court of competent jurisdiction to appoint any established institution having a net worth of not less than $50,000,000 and whose regular business shall include the performance of functions similar to those of the Administrator, as the successor to the Administrator under this Agreement. (f) Upon appointment, the successor Administrator (including the Indenture Trustee acting as successor Administrator) shall be the successor in all respects to the predecessor Administrator and shall be subject to all the responsibilities, duties and liabilities arising thereafter relating thereto placed on the predecessor Administrator and shall be entitled to the compensation specified in Section 3 and all the rights granted to the predecessor Administrator by the terms and provisions of this Agreement. (g) Except when and if the Indenture Trustee is appointed successor Administrator, the Administrator may not resign unless it is prohibited from serving as such by law as evidenced by an Opinion of Counsel to such effect delivered to the Indenture Trustee. No resignation or removal of the Administrator pursuant to this Section shall be effective until: (i) a successor Administrator shall have been appointed by the Issuing Entity and (ii) such successor Administrator shall have agreed in writing to be bound by the terms of this Agreement in the same manner as the Administrator is bound hereunder. (h) The appointment of any successor Administrator shall be effective only after satisfaction of the Rating Agency Condition with respect to the proposed appointment.
Liability for Failure to Stop Payment of Preauthorized Transfers If you order us to stop payment of a preauthorized transfer three (3) business days or more before the transfer is scheduled and we do not do so, we will be liable for your losses or damages.
Cancellation and Destruction of Surrendered Receipts; Maintenance of Records All Receipts surrendered to the Depositary shall be cancelled by the Depositary. The Depositary is authorized to destroy Receipts so cancelled in accordance with its customary practices. Cancelled Receipts shall not be entitled to any benefits under this Deposit Agreement or be valid or obligatory for any purpose.
