Final Claim Procedures Sample Clauses

Final Claim Procedures. The Recipient shall submit, within forty-five (45) days after the Project Completion Date, the final claim along with: (a) an itemized statement certified by the Recipient’s chief financial officer, or such other person considered satisfactory to the Minister, attesting to the total Eligible Supported Costs for the Project incurred and paid; (b) a statement of the total government funding (federal, provincial and municipal funding as well as tax credits) received or requested to cover the Eligible Supported Costs of the Project; and (c) a final progress report on the Project, as more fully described in Subsection 1.3 of Schedule 4 - Reporting Requirements.
Sample 1Sample 2Sample 3See All (12)
AutoNDA by SimpleDocs
Final Claim Procedures. (a) The Recipient shall submit a final claim pertaining to the final reimbursement of any Eligible and Supported Costs, previously claimed or not, signed by a director or officer of the Recipient and accompanied by the following, in addition to the requirements set out in Subsection 6.2, in a form satisfactory to the Minister in scope and detail: (i) a final statement of total Project costs; (ii) a statement of the total government assistance (federal, provincial and municipal assistance) received or requested towards the Eligible Costs of the Project; (iii) a final report on the Project, as more fully described in Section 3 of Annex 3 – Reporting Requirements; and (iv) a final certificate executed by a director or officer of the Recipient substantially in the form prescribed by the Minister. (b) The Recipient shall submit the final claim for reimbursement of Eligible and Supported Costs incurred to the satisfaction of the Minister no later than three (3) months after the Completion Date or the date the Project is completed to the satisfaction of the Minister, whichever is earlier. The Minister shall have no obligation to pay any claims submitted after this date.
Sample 1Sample 2Sample 3See All (8)
Final Claim Procedures. (a) The Recipient shall submit a final claim pertaining to the final reimbursement of any Eligible and Supported Costs previously claimed or not, signed by a director or officer of the Recipient and accompanied by the following, in addition to the requirements set out in Subsection 6.2, in a form satisfactory to the Minister in scope and detail: (i) a final itemized statement of all Eligible Costs incurred and paid by the Recipient; (ii) a final statement of total Project Costs; (iii) a statement of the total government assistance (federal, provincial and municipal assistance) received or requested towards the Eligible Costs of the Project; (iv) a final report on the Project, as more fully described in Subsection 7.2; BlueWater Biochemicals Inc. #509040 (v) a final certificate executed by a director or officer of the Recipient substantially in the form attached hereto as Annex 6 – Forms of Final Report and Final Certificate; and (vi) a certificate by a director or officer of the Recipient confirming that it is the final claim for payment and as such, it includes all final Eligible and Supported Costs submitted for payment. (b) The Recipient shall submit the final claim for reimbursement of Eligible and Supported Costs to the satisfaction of the Minister no later than three (3) months after the Completion Date or the date the Project is completed to the satisfaction of the Minister, whichever is earlier. The Minister shall have no obligation to pay any claims submitted after this date.
Sample 1Sample 2Sample 3
Final Claim Procedures. (a) The Recipient shall submit a final claim pertaining to the final reimbursement of any Eligible and Supported Costs previously claimed or not, signed by a director or officer of the Recipient and accompanied by the following, in addition to the requirements set out in Subsection 6.2, in a form satisfactory to the Minister in scope and detail: (i) a final statement of total Project costs; (ii) a statement of the total government assistance (federal, provincial and municipal assistance) received or requested towards the Eligible Costs of the Project; (iii) a final report on the Project, as more fully described in Section 2 of Annex 3 – Reporting Requirements; and (iv) a final certificate executed by a director or officer of the Recipient substantially in the form prescribed by the Minister; (b) The Recipient shall submit the final claim for reimbursement of Eligible and Supported Costs to the satisfaction of the Minister no later than three (3) months after the Completion Date or the date the Project is completed to the satisfaction of the Minister, whichever is earlier. The Minister shall have no obligation to pay any claims submitted after this date. 6.6. Payment Procedures. Recipient Name: Algoma Steel Inc. (a) The Minister shall review and approve the documentation submitted by the Recipient following the receipt of the Recipient’s claim and in the event of any deficiency in the documentation, it will notify the Recipient and the Recipient shall immediately take action to address and rectify the deficiency. (b) Subject to the maximum Contribution amounts set forth in Subsection 4.1 and all other conditions contained in this Agreement, the Minister shall pay to the Recipient the Eligible and Supported Costs set forth in the Recipient’s claim, in accordance with the Minister’s customary practices. (c) The Minister may request at any time that the Recipient provides satisfactory evidence to demonstrate that all Eligible and Supported Costs claimed have been paid. (d) The Minister may require, at his expense, any claim submitted for payment of the Contribution be certified by the Recipient’s external auditor or by an auditor approved by the Minister.
Sample 1
Final Claim Procedures. Ultimate Recipient shall submit, within thirty (30) days after the Completion Date, the final claim along with: (a) an itemized statement certified, if requested by Lead Recipients, by Ultimate Recipient’s chief financial officer or such other person considered satisfactory to Lead Recipients, attesting to the total Funds received and total Eligible Supported Costs incurred and paid by Ultimate Recipient under this Agreement; (b) a statement of the total government funding as specified in Subsection 2.7 of this Agreement received or requested to cover the Eligible Supported Costs of Ultimate Recipient; and (c) a final Progress Report, as specified in Schedule D (Reporting Requirements).
Sample 1
Final Claim Procedures. (a) The Recipient shall submit a final claim pertaining to the final reimbursement of any Eligible Costs previously claimed or not, signed by a director or officer of the Recipient and accompanied by the following, in addition to the requirements set out in Subsection 6.2, in a form satisfactory to the Minister in scope and detail: (i) a confirmation that it is the final claim for payment and as such, it includes all final Eligible Costs submitted for payment; (ii) a Final Review Form on the Project; (iii) a Final Report of total Project Costs; and (iv) a Statement of Total Government Assistance (federal, provincial and Local Government assistance) received or requested towards the Eligible Costs of the Project substantially in the form of Annex 8 – Statement of Total Government Assistance. (b) The Recipient shall submit the final claim for reimbursement of Eligible Costs to the satisfaction of the Minister the earlier of: (i) the date which falls no later than three (3) months after Project is Substantially Completed; and (ii) the Final Report Date. The Minister shall have no obligation to pay any claims submitted after this date.
Sample 1
Final Claim Procedures. D-Wave Systems Inc. shall submit, within forty-five (45) days after the Project Completion Date, the final claim along with: (a) an itemized statement certified by D-Wave Systems Inc.’s chief financial officer, or such other person considered satisfactory to the Minister, attesting to the total Eligible Supported Costs for the Project incurred and paid; (b) a statement of the total government funding (federal, provincial and municipal funding as well as tax credits) received or requested to cover the Eligible Supported Costs of the Project; and (c) a final progress report on the Project, as more fully described in Subsection 1.3 of Schedule 4—Reporting Requirements.
Sample 1
AutoNDA by SimpleDocs

Related to Final Claim Procedures

  • Claim Procedures Claim forms or claim information as to the subject policy can be obtained by contacting Benmark, Inc. (800-544-6079). When the Named Fiduciary has a claim which may be covered under the provisions described in the insurance policy, they should contact the office named above, and they will either complete a claim form and forward it to an authorized representative of the Insurer or advise the named Fiduciary what further requirements are necessary. The Insurer will evaluate and make a decision as to payment. If the claim is payable, a benefit check will be issued in accordance with the terms of this Agreement. In the event that a claim is not eligible under the policy, the Insurer will notify the Named Fiduciary of the denial pursuant to the requirements under the terms of the policy. If the Named Fiduciary is dissatisfied with the denial of the claim and wishes to contest such claim denial, they should contact the office named above and they will assist in making an inquiry to the Insurer. All objections to the Insurer's actions should be in writing and submitted to the office named above for transmittal to the Insurer.

  • Direct Claim Procedures In the event an Indemnified Party has a claim for indemnity under Section 7.02 against the Indemnifying Party that does not involve a Third Party Claim, the Indemnified Party agrees to give notice in writing of such claim to the Indemnifying Party. Such notice shall set forth in reasonable detail such claim and the basis for indemnification (taking into account the information then available to the Indemnified Party). The failure to so notify the Indemnifying Party shall not relieve the Indemnifying Party of its obligations hereunder, except to the extent such failure shall have actually materially and adversely prejudiced the Indemnifying Party. If the Indemnifying Party does not notify the Indemnified Party within thirty (30) days following the receipt of a notice with respect to any such claim that the Indemnifying Party disputes its indemnity obligation to the Indemnified Party for any Losses with respect to such claim, such Losses shall be conclusively deemed a liability of the Indemnifying Party and the Indemnifying Party shall promptly pay to the Indemnified Party any and all Losses arising out of such claim. If the Indemnifying Party has timely disputed its indemnity obligation for any Losses with respect to such claim, the parties shall proceed in good faith to negotiate a resolution of such dispute and, if not resolved through such negotiations, such dispute shall be resolved by arbitration determined pursuant to Section 9.06.

  • Third Party Claim Procedures In the case of any claim asserted by a third party (a “Third Party Claim”) against a party entitled to indemnification under this Agreement (an “Indemnified Party”), notice shall be given by the Indemnified Party to the party required to provide indemnification (the “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of such Third Party Claim, and the Indemnified Party shall permit the Indemnifying Party (at the expense of such Indemnifying Party and so long as the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party for Losses related to such Third Party Claim) to assume the defense of such Third Party Claim, provided that (a) counsel for the Indemnifying Party who shall conduct the defense of such Third Party Claim shall be reasonably satisfactory to the Indemnified Party, and the Indemnified Party may participate in such defense at such Indemnified Party’s expense, and (b) the failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligation under this Agreement except to the extent that such failure results in a lack of actual notice to the Indemnifying Party and such Indemnifying Party is materially prejudiced as a result of such failure to be given notice. If the Indemnifying Party does not promptly assume the defense of such Third Party Claim following notice thereof, the Indemnified Party shall be entitled to assume and control such defense and to settle or agree to pay in full such Third Party Claim without the consent of the Indemnifying Party without prejudice to the ability of the Indemnified Party to enforce its claim for indemnification against the Indemnifying Party hereunder. Except with the prior written consent of the Indemnified Party, no Indemnifying Party, in the defense of any such Third Party Claim, shall consent to entry of any judgment or enter into any settlement that provides for injunctive or other nonmonetary relief affecting the Indemnified Party or that does not include as an unconditional term thereof the giving by each claimant or plaintiff to such Indemnified Party of an irrevocable release from all liability and wrongdoing with respect to such Third Party Claim. Seller and Buyers shall cooperate in the defense of any Third Party Claim subject to this Article IX and the records of each shall be reasonably available to the other with respect to such defense.

  • Dispute Procedures Contact Think with any questions concerning this Agreement or the Services by calling 0- 000-000-0000 (toll-free), Monday - Friday 8AM – 8PM ET (note these hours may change); by sending a letter to Think, P. O. Box 1288, Greens Farms, Connecticut 06838; or by sending an email to: xxxx@xxxxxxxxxxx.xxx. Think will refer all complaints and inquiries to a representative who will attempt to reach a mutually satisfactory resolution. If your complaint or inquiry is not resolved after you have called Think and/or the EDC, or for general information, you may contact the DPU for assistance toll-free at (000) 000-0000, or at XXXXxxxxxxx.Xxxxxxxxxx@xxxx.xxx, or by sending a letter to the DPU at: 0 Xxxxx Xxxxxxx, 0xx Xxxxx Xxxxxx, XX 00000. You have a right to make a formal or informal complaint to the DPU or any regulatory body with authority to review your complaint. In addition, mediation is available for disputes greater than $100. Nothing in the Arbitration, Waiver of Jury Trial, and Class Action Waiver Section below is intended to bar your right to make a complaint or request mediation. ARBITRATION. Think’s Arbitration and Class Action Wavier Policy Addendum, which is available and provided to you during the enrollment process is incorporated herein and made a part hereof, contains additional details and a complete description of the terms and conditions of the Arbitration and Class Action Waiver Policy, including your ability to opt out. Warranties. THINK MAKES NO EXPRESS REPRESENTATION OR WARRANTIES WITH REGARD TO THE PROVISION OF ELECTRIC SERVICE AND DISCLAIMS ANY AND ALL WARRANTIES, EXPRESSED OR IMPLIED, OR ARISING OUT OF ANY COURSE OF DEALING OR USAGE OF TRADE EXCEPT WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE. Limitation of Liability. You will be deemed to be in exclusive control (and responsible for any damages or injury caused thereby) of the electric power after receipt at the delivery point(s). TO THE FULLEST EXTENT PERMITTED BY LAW, THINK WILL NOT BE LIABLE FOR CONSEQUENTIAL, INCIDENTAL, SPECIAL, PUNITIVE, EXEMPLARY, OR INDIRECT DAMAGES (INCLUDING LOST PROFITS OR OTHER BUSINESS INTERRUPTION DAMAGES), WHETHER BY STATUTE, IN CONTRACT OR TORT, EVEN IF THE RESULT OF NEGLIGENCE (WHETHER SOLE, JOINT, CONCURRENT, ACTIVE, OR PASSIVE). ALL OTHER LIABILITY WILL BE LIMITED TO DIRECT ACTUAL DAMAGES ONLY, AND SUCH DIRECT ACTUAL DAMAGES WILL BE THE SOLE AND EXCLUSIVE REMEDY. YOU HEREBY WAIVE ALL OTHER REMEDIES AT LAW OR IN EQUITY. THERE ARE NO THIRD-PARTY BENEFICIARIES TO THIS AGREEMENT. To the extent any damages required to be paid hereunder are liquidated, the Parties acknowledge that the damages are not intended and shall not be construed as a penalty, such damages are difficult or impossible to determine, that otherwise obtaining an adequate remedy is inconvenient or impossible, and that the liquidated damages constitute a reasonable approximation of the harm or loss.

  • Claim Procedure Any Person entitled to indemnification hereunder shall (i) give prompt written notice to the indemnifying party of any claim with respect to which it seeks indemnification (provided that the failure to give prompt notice shall impair any Person’s right to indemnification hereunder only to the extent such failure has prejudiced the indemnifying party) and (ii) unless in such indemnified party’s reasonable judgment a conflict of interest between such indemnified and indemnifying parties may exist with respect to such claim, permit such indemnifying party to assume the defense of such claim with counsel reasonably satisfactory to the indemnified party. If such defense is assumed, the indemnifying party shall not be subject to any liability for any settlement made by the indemnified party without its consent (but such consent shall not be unreasonably withheld, conditioned or delayed). An indemnifying party who is not entitled to, or elects not to, assume the defense of a claim shall not be obligated to pay the fees and expenses of more than one counsel for all parties indemnified by such indemnifying party with respect to such claim, unless in the reasonable judgment of any indemnified party a conflict of interest may exist between such indemnified party and any other of such indemnified parties with respect to such claim. In such instance, the conflicted indemnified parties shall have a right to retain one separate counsel, chosen by the Holders representing a majority of the Registrable Securities included in the registration if such Holders are indemnified parties, at the expense of the indemnifying party.

  • Claims Procedures Each Party entitled to be indemnified by the other Party (an “Indemnified Party”) pursuant to Section 8.1 or 8.2 hereof shall give notice to the other Party (an “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of any threatened or asserted claim as to which indemnity may be sought, and shall permit the Indemnifying Party to assume the defense of any such claim or any litigation resulting therefrom; provided: (a) That counsel for the Indemnifying Party, who shall conduct the defense of such claim or any litigation resulting therefrom, shall be approved by the Indemnified Party (whose approval shall not unreasonably be withheld) and the Indemnified Party may participate in such defense at such party’s expense (unless (i) the employment of counsel by such Indemnified Party has been authorized by the Indemnifying Party; or (ii) the Indemnified Party shall have reasonably concluded that there may be a conflict of interest between the Indemnifying Party and the Indemnified Party in the defense of such action, in each of which cases the Indemnifying Party shall pay the reasonable fees and expenses of one law firm serving as counsel for the Indemnified Party, which law firm shall be subject to approval, not to be unreasonably withheld, by the Indemnifying Party); and (b) The failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its obligations under this Agreement to the extent that the failure to give notice did not result in harm to the Indemnifying Party. (c) No Indemnifying Party, in the defense of any such claim or litigation, shall, except with the approval of each Indemnified Party which approval shall not be unreasonably withheld, consent to entry of any judgment or enter into any settlement which (i) would result in injunctive or other relief being imposed against the Indemnified Party; or (ii) does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect to such claim or litigation. (d) Each Indemnified Party shall furnish such information regarding itself or the claim in question as an Indemnifying Party may reasonably request in writing and shall be reasonably required in connection with the defense of such claim and litigation resulting therefrom.

  • Indemnification Procedures If any third-­‐party claim is commenced that is indemnified under Section 7.1 above, ICANN shall provide notice thereof to Registry Operator as promptly as practicable. Registry Operator shall be entitled, if it so elects, in a notice promptly delivered to ICANN, to immediately take control of the defense and investigation of such claim and to employ and engage attorneys reasonably acceptable to ICANN to handle and defend the same, at Registry Operator’s sole cost and expense, provided that in all events ICANN will be entitled to control at its sole cost and expense the litigation of issues concerning the validity or interpretation of ICANN’s policies, Bylaws or conduct. ICANN shall cooperate, at Registry Operator’s cost and expense, in all reasonable respects with Registry Operator and its attorneys in the investigation, trial, and defense of such claim and any appeal arising therefrom, and may, at its own cost and expense, participate, through its attorneys or otherwise, in such investigation, trial and defense of such claim and any appeal arising therefrom. No settlement of a claim that involves a remedy affecting ICANN other than the payment of money in an amount that is fully indemnified by Registry Operator will be entered into without the consent of ICANN. If Registry Operator does not assume full control over the defense of a claim subject to such defense in accordance with this Section 7.2, ICANN will have the right to defend the claim in such manner as it may deem appropriate, at the cost and expense of Registry Operator and Registry Operator shall cooperate in such defense. [Note: This Section 7.2 is inapplicable to intergovernmental organizations or governmental entities.]

  • Indemnity Procedures Promptly after receipt by an Indemnified Party of any claim or notice of the commencement of any action or administrative or legal proceeding or investigation as to which the indemnity provided for in Article 18.1 may apply, the Indemnified Party shall notify the Indemnifying Party of such fact. Any failure of or delay in such notification shall not affect a Party’s indemnification obligation unless such failure or delay is materially prejudicial to the Indemnifying Party. Except as stated below, the Indemnifying Party shall have the right to assume the defense thereof with counsel designated by such Indemnifying Party and reasonably satisfactory to the Indemnified Party. If the defendants in any such action include one or more Indemnified Parties and the Indemnifying Party and if the Indemnified Party reasonably concludes that there may be legal defenses available to it and/or other Indemnified Parties which are different from or additional to those available to the Indemnifying Party, the Indemnified Party shall have the right to select separate counsel to assert such legal defenses and to otherwise participate in the defense of such action on its own behalf. In such instances, the Indemnifying Party shall only be required to pay the fees and expenses of one additional attorney to represent an Indemnified Party or Indemnified Parties having such differing or additional legal defenses. The Indemnified Party shall be entitled, at its expense, to participate in any such action, suit or proceeding, the defense of which has been assumed by the Indemnifying Party. Notwithstanding the foregoing, the Indemnifying Party (i) shall not be entitled to assume and control the defense of any such action, suit or proceedings if and to the extent that, in the opinion of the Indemnified Party and its counsel, such action, suit or proceeding involves the potential imposition of criminal liability on the Indemnified Party, or there exists a conflict or adversity of interest between the Indemnified Party and the Indemnifying Party, in such event the Indemnifying Party shall pay the reasonable expenses of the Indemnified Party, and (ii) shall not settle or consent to the entry of any judgment in any action, suit or proceeding without the consent of the Indemnified Party, which shall not be unreasonably withheld, conditioned or delayed.

  • Dispute Settlement Procedures Principles a) This procedure is designed to promote the resolution of issues that arise at the lowest possible level and to provide a step-by-step process which will be accessed if the parties are genuinely unable to resolve the issue. b) At each step in the procedure, reasonable time is to be allowed for the parties to resolve the matter. The parties agree not to proceed to each next step in the procedure until the previous step has been completed. Following these procedures will ensure the dispute is resolved in the most efficient manner. c) In the event of a dispute in relation to a matter arising under this agreement, in the first instance the parties will attempt to resolve the matter at the workplace by discussions between the employee or employees concerned and the relevant supervisor and, if such discussions do not resolve the dispute, by discussions between the employee or employees concerned and more senior levels of management as appropriate. If the matter is not resolved at this level, the grievance shall be referred to the designated management representative. d) Should the matter remain unresolved at this level, the Employee, at his/her discretion, may nominate a representative to meet with the Supervisor, the designated manager,and the Consultative Committee to resolve the issue. e) A party to the dispute may appoint another person, organisation or association to accompany or represent them in relation to the dispute. f) If a dispute in relation to a matter arising under the agreement is unable to be resolved at the workplace, and all agreed steps for resolving it have been taken, the dispute may be referred to the Australian Industrial Relations Commission (the Commission) for resolution by mediation and/or conciliation. Any solution proposed by the Commission or another third party must be consistent with the Construction Code and Guidelines and relevant legislation. g) It is a term of this agreement that while the dispute resolution procedure is being conducted work shall continue normally. The circumstances that applied prior to the dispute arising shall apply until final resolution of the matter. h) Any dispute referred to the Commission under this clause should be dealt with by a member agreed by the parties at the time or, in default of agreement, a member nominated by either the head of the relevant panel or the President. i) This dispute resolution procedure does not apply to Occupational Health and Safety matters. It is expected that the Occupational Health and Safety Representatives will follow appropriate procedures in the resolution of any Health and Safety matters.

  • Review Procedures a. In consultation with the Illinois SHPO, NRCS shall identify those undertakings with little to no potential to affect historic properties and list those undertakings in Appendix A. Upon the determination by the CRS that a proposed undertaking is included in Appendix A, the NRCS is not required to consult further with the SHPO for that undertaking. A list of undertakings with the potential to affect historic properties comprises Appendix B. b. The lists of undertakings provided in Appendices A and B may be modified through consultation and written agreement between the NRCS State Conservationist and the SHPO without requiring an amendment to this Illinois Prototype Agreement. The NRCS State Office will maintain the master list and will provide an updated list to all consulting parties with an explanation of the rationale for classifying the practices accordingly. c. Undertakings identified in Appendix B shall require further review as outlined in Stipulation V. a. The NRCS shall consult with the SHPO to define the undertaking’s APE, identify and evaluate historic properties that may be affected by the undertaking, assess potential effects, and identify strategies for resolving adverse effects prior to implementing the undertaking. 1) NRCS may provide its proposed APE, identification of historic properties and/or scope of identification efforts, and assessment of effects in a single transmittal to the SHPO, provided this documentation meets the substantive standards in 36 CFR Part 800.4-5 and 800.11. 2) The NRCS shall attempt to avoid adverse effects to historic properties whenever possible; where historic properties are located in the APE, NRCS shall describe how it proposes to modify, buffer, or move the undertaking to avoid adverse effects to historic properties. 3) Where the NRCS proposes a finding of "no historic properties affected" or "no adverse effect" to historic properties, the SHPO shall have 30 calendar days from receipt of this documented description and information to review it and provide comments. The NRCS shall take into account all timely comments. i. If the SHPO, or another consulting party, disagrees with NRCS' findings and/or determination, it shall notify the NRCS within the thirty (30) calendar daytime period. The NRCS shall consult with the SHPO or other consulting party to attempt to resolve the disagreement. If the disagreement cannot be resolved through this consultation, NRCS shall follow the dispute resolution process in Stipulation VIII below. ii. If the SHPO does not respond to the NRCS within the thirty (30) calendar day period and/or the NRCS receives no objections from other consulting parties, or if the SHPO concurs with the NRCS' determination and proposed actions to avoid adverse effects, the NRCS shall document the concurrence/lack of response within the review time noted above and may move forward with the undertaking. 4) Where a proposed undertaking may adversely affect historic properties, NRCS shall describe proposed measures to minimize or mitigate the adverse effects, and follow the process in 36 CFR Part 800.6, including consultation with other consulting patties and notification to the ACHP, to develop a Memorandum of Agreement to resolve the adverse effects. Should the proposed undertaking have the potential to adversely affect a known NHL, the NRCS shall, to the maximum extent possible, undertake such planning and actions that may be necessary to minimize harm to the NHL in accordance with 54 U.S.C. § 306107 of the NHPA and 36 CFR Part 800.6 and 800.10, including consultation with the ACHP and respective National Park Service, Regional National Historic Landmark Program Coordinator, to develop a Memorandum of Agreement. d. NRCS will conduct archaeological surveys and will submit reports and other documentation to SHPO for review and comment. When no archaeological sites have been located by the archaeological survey, NRCS may proceed with the proposed undertaking. Reports for negative surveys must be submitted to SHPO on a quarterly basis. All positive and negative reports submitted to SHPO will be sent digitally for submission to the Inventory of Illinois Archaeological Sites (IAS) data file maintained by staff at the Illinois State Museum (ISM) housed under the Illinois Department of Natural Resources (IDNR). The NRCS further agrees that access to specific site location data will be restricted to the CRS, the NRCS field personnel installing conservation practices adjacent to the cultural resource, and the landowner. Specific site location information for individual projects will be maintained in a secure cultural resources file kept in the field offices and will not be available to the public. e. Curation: NRCS personnel will not collect artifactual material during routine field inspections. However, if a professional survey, evaluation testing, or mitigation is required, NRCS shall ensure that all materials and records resulting from cultural resources surveys or data recovery activities on federal or state property are curated by the Illinois State Museum. The NRCS shall ensure that all records resulting from cultural resource surveys or data recovery activities on private property are curated by the Illinois State Museum or an equivalent curation facility in accordance with 36 CFR Part 79. Subject to the landowner's permission, all objects resulting from cultural resources surveys or data recovery activities are maintained by the Illinois State Museum or equivalent research institution until their analysis is complete and they are returned to their owner(s). Although landowners will be encouraged to donate artifactual material, it is understood that objects collected on private land remain the property of the landowner(s) unless the landowner(s) donates the material to the Illinois State Museum or equivalent research institution. This excludes burial goods, as stipulated by XXXXXX.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!