Final claims for the term of July 1, 2013a final claim for each COUNTY fiscal year, July 1 through June 30, 2014, must be received covered under the term of this Agreement, as stated in Paragraph 1, by no later than August 30, 2014 at 5:00 p.m.
Final claims for the Sample Clauses
Related to Final claims for the
Claims for Additional Time 1 If the Contractor wishes to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Contractor’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary.
No Actions, Claims, Etc As of the date hereof, each of the Loan Parties hereby acknowledges and confirms that it has no knowledge of any actions, causes of action, claims, demands, damages and liabilities of whatever kind or nature, in law or in equity, against the Administrative Agent, the Lenders, or the Administrative Agent’s or the Lenders’ respective officers, employees, representatives, agents, counsel or directors arising from any action by such Persons, or failure of such Persons to act under the Credit Agreement on or prior to the date hereof.
CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.
Claims for Benefits All Claims for benefits will be deemed to have been filed on the date received by AvMed. If a Claim is a Pre-Service or Urgent Care Claim, a Health Professional with knowledge of the Member’s Condition will be permitted to act as the Member’s authorized representative, and will be notified of all approvals on the Member’s behalf.
CLAIMS FOR ADDITIONAL COST 12.3.1 If the Contractor wishes to make a claim for an increase in the Contract Sum, he shall give the Architect written notice thereof within twenty days after the occurrence of the event giving rise to such claim. This notice shall be given by the Contractor before proceeding to execute the Work, except in an emergency endangering life or property in which case the Contractor shall proceed in accordance with Paragraph 10.3 of these General Conditions. No such claim shall be valid unless so made. If the State and the Contractor cannot agree on the amount of the adjustment in the Contract Sum, it shall be determined by the Architect. Any change in the Contract Sum resulting from such claim shall be authorized by Change Order. 12.3.2 If the Contractor claims that additional cost is involved because of, but not limited to, (1) any order by the State to stop the Work pursuant to Paragraph 3.3 of these General Conditions where the Contractor was not at fault, or (2) failure of payment by the State pursuant to Paragraph 9.7(of these General Conditions), the Contractor shall make such claim as provided in Subparagraph 12.3.1 of this agreement. 12.3.3 The Architect will have authority to order minor changes in the Work not involving an adjustment in the Contract Sum or an extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes shall be effected by written order and shall be binding on the State and Contractor within 10 days unless the Contractor or the State objects to the change in writing.
Disputes and Claims Failure to file such a protest within the time specified shall constitute agreement on the part of the Contractor with the terms, conditions, amounts and adjustments or non- adjustment to the contract price and/or contract time set forth in the field order.
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
No Entitlement or Claims for Compensation By accepting this Agreement, you hereby acknowledge and agree as follows:
Disputes, Etc Prompt written notice of (i) any claims, legal or arbitration proceedings, proceedings before any Governmental Authority, or disputes, or to the knowledge of the Borrower threatened, or affecting the Borrower, or any of its Subsidiaries which, if adversely determined, could reasonably be expected to cause a Material Adverse Change, or any material labor controversy of which the Borrower or any of its Subsidiaries has knowledge resulting in or reasonably considered to be likely to result in a strike against the Borrower or any of its Subsidiaries and (ii) any claim, judgment, Lien or other encumbrance (other than a Permitted Lien) affecting any Property of the Borrower or any Subsidiary if the value of the claim, judgment, Lien, or other encumbrance affecting such Property shall exceed $1,000,000;
Contested Claims In the event that the Indemnifying Party disputes the Claimed Amount, as soon as practicable but in no event later than ten (10) days after the receipt of the notice referenced in Section 10.2(b)(ii) hereof, the Parties will begin the process to resolve the matter in accordance with the dispute resolution provisions of Section 1.4 hereof. Upon ultimate resolution thereof, the Parties will take such actions as are reasonably necessary to comply with such agreement or instructions.
