Financing Costs or Allowance for Funds Used During Construction. Each Owner shall record its own financing costs, including allowance for funds used during construction.
Financing Costs or Allowance for Funds Used During Construction Sample Clauses
Related to Financing Costs or Allowance for Funds Used During Construction
Maintenance during Construction Period (i) During the Construction Period, the Contractor shall maintain, at its cost, the existing lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at no time materially inferior as compared to their condition on Appointed Date, and shall undertake the necessary repair and maintenance works for this purpose; provided that the Contractor may, at its cost, interrupt and divert the flow of traffic if such interruption and diversion is necessary for the efficient progress of Works and conforms to Good Industry Practice; provided further that such interruption and diversion shall be undertaken by the Contractor only with the prior written approval of the Authority’s Engineer which approval shall not be unreasonably withheld. For the avoidance of doubt, it is agreed that the Contractor shall at all times be responsible for ensuring safe operation of the Project Highway. It is further agreed that in the event the Project includes construction of a bypass or tunnel and realignment of the existing carriageway, the Contractor shall maintain the existing highway in such sections until the new Works are open to traffic.
Refinancing Preparation Advance; Capitalizing Front-end Fee and Interest (a) If the Loan Agreement provides for the repayment out of the proceeds of the Loan of an advance made by the Bank or the Association (“Preparation Advance”), the Bank shall, on behalf of such Loan Party, withdraw from the Loan Account on or after the Effective Date the amount required to repay the withdrawn and outstanding balance of the advance as at the date of such withdrawal from the Loan Account and to pay all accrued and unpaid charges, if any, on the advance as at such date. The Bank shall pay the amount so withdrawn to itself or the Association, as the case may be, and shall cancel the remaining unwithdrawn amount of the advance.”
Delays during construction Without prejudice to the provisions of Clause 10.3 (ii), in the event the Contractor does not achieve any of the Project Milestones or the Authority’s Engineer shall have reasonably determined that the rate of progress of Works is such that Completion of the Project Highway is not likely to be achieved by the end of the Scheduled Completion Date, it shall notify the same to the Contractor, and the Contractor shall, within 15 (fifteen) days of such notice, by a communication inform the Authority’s Engineer in reasonable detail about the steps it proposes to take to expedite progress and the period within which it shall achieve the Project Completion Date.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Unobligated and Unearned Funds and Allowable Costs In accordance with Section 215.971, Florida Statutes, the Grantee shall refund to the State of Florida any balance of unobligated funds which has been advanced or paid to the Grantee. In addition, funds paid in excess of the amount to which the recipient is entitled under the terms and conditions of the agreement must be refunded to the state agency. Further, the recipient may expend funds only for allowable costs resulting from obligations incurred during the specified agreement period. Expenditures of state financial assistance must be in compliance with the laws, rules, and regulations applicable to expenditures of State funds, including, but not limited to, the Reference Guide for State Expenditures.
C4 Contract Price During Extension of the Initial Contract Period C4.1 Subject to the Pricing Schedule and the provision in clause F6 (Variation), the Contract Price shall apply for the Initial Contract Period and following an extension pursuant to clause F8 (Extension of Initial Contract Period), to the date of expiry of the extended period, or such earlier date of termination or partial termination of the agreement in accordance with the Law or the provisions of the Contract. C5 Euro
Taxes and Fees Imposed on Purchasing Party But Collected And Remitted By Providing Party 11.3.1 Taxes and fees imposed on the purchasing Party shall be borne by the purchasing Party, even if the obligation to collect and/or remit such taxes or fees is placed on the providing Party.
Construction Phase Payments 10.3.1 Payments for Construction Phase Services shall be made as provided for in the UGSC and Owner’s Specifications. All payment requests shall be submitted through e- Builder® with a Schedule of Values and include all required attachments. Payment for approved Change Orders shall be made as part of Contractor’s Application for Payment. Failure to submit a Prime Contractor Progress Assessment Report form with each Application for Payment will cause rejection of the application by Owner and its return to Contractor.
Additional Fee on Late Payments For any payments thirty (30) calendar days or more overdue under this Agreement, Registry Operator shall pay an additional fee on late payments at the rate of 1.5% per month or, if less, the maximum rate permitted by applicable law.
Union Activity During Working Hours The Employer and the Union recognize that union representatives and stewards play an important role in effectuating the terms of this Agreement; however, both parties acknowledge that the duties undertaken as a union representative or xxxxxxx are in addition to the their job assignments. The Union shall notify the Department of Budget and Management in writing of the names of designated stewards and union representatives prior to them assuming any duties. Consistent with the operational needs of the Employer, the Employer shall grant time off with pay for designated stewards and union representatives, including reasonable travel time when necessary, to attend:
