Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Reporting Requirements of the Commission and Indemnification Notwithstanding any other provision of this Agreement, the Servicer acknowledges and agrees that the purpose of Sections 4.02(c) and (d), 5.02, 5.03, 5.04, 6.01(j), 6.03 and 7.04 of this Agreement is to facilitate compliance by the Trustee, the Securities Administrator, the Master Servicer and the Depositor with the provisions of Regulation AB. Therefore, the Servicer agrees that (a) the obligations of the Servicer hereunder shall be interpreted in such a manner as to accomplish that purpose, (b) such obligations may change over time due to interpretive advice or guidance of the Commission, convention or consensus among active participants in the asset-backed securities markets, advice of counsel, or otherwise in respect of the requirements of Regulation AB, (c) the Servicer shall agree to enter into such amendments to this Agreement as may be necessary, in the judgment of the Depositor, the Master Servicer and their respective counsel, to comply with such interpretive advice or guidance, convention, consensus, advice of counsel, or otherwise, (d) the Servicer shall otherwise comply with requests made by the Trustee, the Securities Administrator, the Master Servicer or the Depositor for delivery of additional or different information as such parties may determine in good faith is necessary to comply with the provisions of Regulation AB and (e) the Servicer shall (i) agree to such modifications and enter into such amendments to this Agreement as may be necessary, in the judgment of the Depositor, the Master Servicer and their respective counsel, to comply with any such clarification, interpretive guidance, convention or consensus and (ii) promptly upon request provide to the Depositor for inclusion in any periodic report required to be filed under the Exchange Act, such items of information regarding this Agreement and matters related to the Servicer, (collectively, the “Servicer Information”), provided that such information shall be required to be provided by the Servicer only to the extent that such shall be determined by the Depositor in its sole discretion and its counsel to be necessary or advisable to comply with any Commission and industry guidance and convention. For purposes of clarification, any modifications or amendments of the obligations of the Servicer under this agreement made pursuant to this Section 6.05 shall be made in writing and upon mutual agreement with the Servicer (provided that such agreement will not unreasonably withheld) and in accordance with Section 9.12 of this Agreement. The Servicer hereby agrees to indemnify and hold harmless the Depositor, the Master Servicer, their respective officers and directors and each person, if any, who controls the Depositor or Master Servicer within the meaning of Section 15 of the Securities Act of 1933, as amended (the “Act”), or Section 20 of the Exchange Act, from and against any and all losses, claims, expenses, damages or liabilities to which the Depositor, the Master Servicer, their respective officers or directors and any such controlling person may become subject under the Act or otherwise, as and when such losses, claims, expenses, damages or liabilities are incurred, insofar as such losses, claims, expenses, damages or liabilities (or actions in respect thereof) arise out of or are based upon any untrue statement or alleged untrue statement of any material fact contained in the Servicer Information or arise out of, or are based upon, the omission or alleged omission to state therein any material fact required to be stated therein or necessary to make the statements therein, in light of the circumstances under which they were made, not misleading, and will reimburse the Depositor, the Master Servicer, their respective officers and directors and any such controlling person for any legal or other expenses reasonably incurred by it or any of them in connection with investigating or defending any such loss, claim, expense, damage, liability or action, as and when incurred; provided, however, that the Servicer shall be liable only insofar as such untrue statement or alleged untrue statement or omission or alleged omission relates solely to the information in the Servicer Information furnished to the Depositor or Master Servicer by or on behalf of the Servicer specifically in connection with this Agreement.
INSURANCE and INDEMNIFICATION REQUIREMENTS See Exhibit C, attached hereto, for insurance requirements for this Agreement. The COUNTY’S insurance requirements are a material provision to this Agreement.
WAIVER OF LIABILITY, ASSUMPTION OF RISK, AND INDEMNITY AGREEMENT I, , IN CONSIDERATION of being permitted to participate in any way in the Rocky Mountain Cycling Club 600km brevet calendared for June 4, 2021 (“Activity”), I hereby acknowledge, agree, attest and represent the following:
Specific Limitations on Indemnification Notwithstanding anything in this Agreement to the contrary, the Corporation shall not be obligated under this Agreement to make any payment to Indemnitee with respect to any Proceeding:
(a) To the extent that payment is actually made to Indemnitee under any insurance policy, or is made to Indemnitee by the Corporation or an affiliate otherwise than pursuant to this Agreement. Notwithstanding the availability of such insurance, Indemnitee also may claim indemnification from the Corporation pursuant to this Agreement by assigning to the Corporation any claims under such insurance to the extent Indemnitee is paid by the Corporation;
(b) Provided there has been no Change in Control, for Liabilities in connection with Proceedings settled without the Corporation’s consent, which consent, however, shall not be unreasonably withheld;
(c) For an accounting of profits made from the purchase or sale by Indemnitee of securities of the Corporation within the meaning of section 16(b) of the Securities Exchange Act of 1934, as amended (the “Exchange Act”), or similar provisions of any state statutory or common law;
(d) To the extent it would be otherwise prohibited by law, if so established by a judgment or other final adjudication adverse to Indemnitee; or
(e) In connection with a Proceeding commenced by Indemnitee (other than a Proceeding commenced by Indemnitee to enforce Indemnitee’s rights under this Agreement) unless the commencement of such Proceeding was authorized by the Board of Directors.
Certain Limits on Indemnification Notwithstanding any other provision of this Agreement (other than Section 6), Indemnitee shall not be entitled to:
(a) indemnification hereunder if the Proceeding was one by or in the right of the Company and Indemnitee is adjudged, in a final adjudication of the Proceeding not subject to further appeal, to be liable to the Company;
(b) indemnification hereunder if Indemnitee is adjudged, in a final adjudication of the Proceeding not subject to further appeal, to be liable on the basis that personal benefit was improperly received in any Proceeding charging improper personal benefit to Indemnitee, whether or not involving action in the Indemnitee’s Corporate Status; or
(c) indemnification or advance of Expenses hereunder if the Proceeding was brought by Indemnitee, unless: (i) the Proceeding was brought to enforce indemnification under this Agreement, and then only to the extent in accordance with and as authorized by Section 12 of this Agreement, or (ii) the Company’s charter or Bylaws, a resolution of the stockholders entitled to vote generally in the election of directors or of the Board of Directors or an agreement approved by the Board of Directors to which the Company is a party expressly provide otherwise.
CERTIFICATION PROHIBITING DISCRIMINATION AGAINST FIREARM AND AMMUNITION INDUSTRIES (Texas law as of September 1, 2021) By submitting a proposal to this Solicitation, you certify that you agree, when it is applicable, to the following required by Texas law as of September 1, 2021: If (a) company is not a sole proprietorship; (b) company has at least ten (10) full-time employees; (c) this contract has a value of at least $100,000 that is paid wholly or partly from public funds; (d) the contract is not excepted under Tex. Gov’t Code § 2274.003 of SB 19 (87th leg.); and (e) governmental entity has determined that company is not a sole-source provider or governmental entity has not received any bids from a company that is able to provide this written verification, the following certification shall apply; otherwise, this certification is not required. Pursuant to Tex. Gov’t Code Ch. 2274 of SB 19 (87th session), the company hereby certifies and verifies that the company, or association, corporation, partnership, joint venture, limited partnership, limited liability partnership, or limited liability company, including a wholly owned subsidiary, majority-owned subsidiary parent company, or affiliate of these entities or associations, that exists to make a profit, does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association and will not discriminate during the term of this contract against a firearm entity or firearm trade association. For purposes of this contract, “discriminate against a firearm entity or firearm trade association” shall mean, with respect to the entity or association, to: “
(1) refuse to engage in the trade of any goods or services with the entity or association based solely on its status as a firearm entity or firearm trade association; (2) refrain from continuing an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association; or (3) terminate an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association. See Tex. Gov’t Code § 2274.001(3) of SB 19. “Discrimination against a firearm entity or firearm trade association” does not include: “
(1) the established policies of a merchant, retail seller, or platform that restrict or prohibit the listing or selling of ammunition, firearms, or firearm accessories; and (2) a company’s refusal to engage in the trade of any goods or services, decision to refrain from continuing an existing business relationship, or decision to terminate an existing business relationship to comply with federal, state, or local law, policy, or regulations or a directive by a regulatory agency, or for any traditional business reason that is specific to the customer or potential customer and not based solely on an entity’s or association’s status as a firearm entity or firearm trade association.” See Tex. Gov’t Code § 2274.001(3) of SB 19.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Guaranty; Limitation of Liability (a) Each Guarantor jointly and severally, hereby absolutely, unconditionally and irrevocably guarantees the punctual payment when due, whether at scheduled maturity or on any date of a required prepayment or by acceleration, demand or otherwise, of all Secured Obligations of each other Loan Party now or hereafter existing (including, without limitation, any extensions, modifications, substitutions, amendments or renewals of any or all of the Secured Obligations) whether direct or indirect, absolute or contingent, and whether for principal, reimbursement obligations, interest (including Post Petition Interest), premiums, fees, indemnities, contract causes of action, costs, expenses or otherwise (all of the foregoing being hereafter collectively referred to as the “Guaranteed Obligations”), and agrees to pay any and all expenses (including, without limitation, fees and expenses of counsel) incurred by the Administrative Agent or any other Secured Party in enforcing any rights under this Guaranty or any other Loan Document or any Secured Hedge Agreement or Secured Cash Management Agreement. Without limiting the generality of the foregoing, each Guarantor’s liability shall extend to all amounts that constitute part of the Guaranteed Obligations and would be owed by any other Loan Party to any Secured Party under or in respect of the Loan Documents, the Secured Cash Management Agreements or the Secured Hedge Agreements but for the fact that they are unenforceable or not allowable due to the existence of a bankruptcy, reorganization or similar proceeding involving such other Loan Party.
(b) Each Guarantor, and by its acceptance of this Guaranty, the Administrative Agent and each other Secured Party, hereby confirms that it is the intention of all such Persons that this Guaranty and the Obligations of each Guarantor hereunder not constitute a fraudulent transfer or conveyance for purposes of any Debtor Relief Law, the Uniform Fraudulent Conveyance Act, the Uniform Fraudulent Transfer Act or any similar foreign, federal or state law to the extent applicable to this Guaranty and the Obligations of each Guarantor hereunder. To effectuate the foregoing intention, the Administrative Agent, the other Secured Parties and the Guarantors hereby irrevocably agree that the Obligations of each Guarantor under this Guaranty at any time shall be limited to the maximum amount as will result in the Obligations of such Guarantor under this Guaranty not constituting a fraudulent transfer or conveyance (after taking into account the provisions of Section 8.01(c)).
(c) Each Guarantor hereby unconditionally and irrevocably agrees that in the event any payment shall be required to be made to any Secured Party under this Guaranty or any other guaranty, such Guarantor will contribute, to the maximum extent permitted by law, such amounts to each other Guarantor and each other guarantor so as to maximize the aggregate amount paid to the Secured Parties under or in respect of the Loan Documents. This Guaranty constitutes a guaranty of payment and performance when due and not merely a guaranty of collection, and each Guarantor specifically agrees that it shall not be necessary or required that any Secured Party exercise any right, assert any claim or demand or enforce any remedy whatsoever against any Loan Party or any other Person before or as a condition to the obligations of such Guarantor hereunder.
Survival of Agreements, Representations and Indemnities The respective indemnities of the Company, the Bank and the Agent and the representations and warranties and other statements of the Company, the Bank and the Agent set forth in or made pursuant to this Agreement shall remain in full force and effect, regardless of any termination or cancellation of this Agreement or any investigation made by or on behalf of the Agent, the Company, the Bank or any controlling person referred to in Section 8 hereof, and shall survive the issuance of the Shares, and any successor or assign of the Agent, the Company, the Bank, and any such controlling person shall be entitled to the benefit of the respective agreements, indemnities, warranties and representations.
