Obligations of the Adviser (a) The Adviser shall provide (or cause the Fund’s Custodian (as defined in Section 5 hereof, the Fund’s accountant and the Fund’s distributor) to provide) timely information to the Sub-Adviser regarding such matters as the composition of the Sub-Advised Assets, cash requirements and cash available for investment in the Sub-Advised Assets, and all other information as may be reasonably necessary for the Sub-Adviser to perform its responsibilities hereunder. (b) The Adviser has furnished the Sub-Adviser with a copy of the prospectus and statement of additional information of the Fund and it agrees during the continuance of this Agreement to furnish the Sub-Adviser copies of any revisions or supplements thereto at, or, if practicable, before the time the revisions or supplements become effective. The Adviser agrees to furnish the Sub-Adviser with copies of any financial statements or reports made by the Fund to its shareholders, and any further materials or information that the Sub-Adviser may reasonably request to enable it to perform its functions under this Agreement.
Representations of the Adviser The Adviser represents, warrants and further covenants as follows:
FUNCTIONS OF MANAGEMENT 4.01 The Union agrees that the Employer has the exclusive right and power to manage its business to direct the working forces and to suspend, discharge or discipline employees for just and sufficient cause, to hire, promote, demote, transfer or lay-off employees, to establish and maintain reasonable rules and regulations covering the operation of the stores, provided however, that any exercise of these rights and powers in conflict with any of the provisions of this Agreement shall be subject to the provisions of the Grievance Procedure as set out herein. 4.02 It is agreed that the direction of the working force shall be at the discretion of the Employer within the terms of this Agreement.
CONDITIONS OF THE OBLIGATIONS OF THE COMPANY The obligations of the Company to sell and deliver the portion of the Shares required to be delivered as and when specified in this Agreement are subject to the conditions that at the Closing Date or the Option Closing Date, as the case may be, no stop order suspending the effectiveness of the Registration Statement shall have been issued and in effect or proceedings therefor initiated or threatened.
Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder. (ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works. (iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor: (a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre. (b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7 (c) all environmental clearances as required under Clause 4.3.8 (iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
REPRESENTATIONS OF THE ADVISOR (a) The Advisor shall use its best judgment and efforts in rendering the advice and services to the Fund as contemplated by this Agreement. (b) The Advisor shall maintain all licenses and registrations necessary to perform its duties hereunder in good order. (c) The Advisor shall conduct its operations at all times in conformance with the Advisers Act, the Investment Company Act, and any other applicable state and/or self-regulatory organization regulations. (d) The Advisor shall maintain errors and omissions insurance in an amount at least equal to that disclosed to the Board of Trustees in connection with their approval of this Agreement.
Obligations of the Academy Trust The Academy Trust must keep the Land clean and tidy and make good any damage or deterioration to the Land. The Academy Trust must not do anything to lessen the value or marketability of the Land without the Secretary of State’s consent.
Conditions of the Obligations of the Underwriter The obligations of the Underwriter hereunder shall be subject to the accuracy of the representations and warranties on the part of the Company set forth in Section 2 hereof, in each case as of the date hereof and as of each Closing Date as though then made, to the timely performance by each of the Company of its covenants and other obligations hereunder on and as of such dates, and to each of the following additional conditions:
Conditions of the Obligations of the Underwriters The obligations of the several Underwriters to purchase and pay for the Firm Securities on the First Closing Date and the Optional Securities to be purchased on each Optional Closing Date will be subject to the accuracy of the representations and warranties of the Company herein (as though made on such Closing Date), to the accuracy of the statements of Company officers made pursuant to the provisions hereof, to the performance by the Company of its obligations hereunder and to the following additional conditions precedent:
Instructions of the Company The Company shall have the right, by one or more instruments in writing executed and delivered to the Collateral Agent, the Custodial Agent or the Securities Intermediary, as the case may be, to direct the time, method and place of conducting any proceeding for the realization of any right or remedy available to the Collateral Agent, or of exercising any power conferred on the Collateral Agent, the Custodial Agent or the Securities Intermediary, as the case may be, or to direct the taking or refraining from taking of any action authorized by this Agreement; provided, however, that (i) such direction shall not conflict with the provisions of any law or of this Agreement and (ii) the Collateral Agent, the Custodial Agent and the Securities Intermediary shall be adequately indemnified as provided herein. Nothing in this Section 8.2 shall impair the right of the Collateral Agent in its discretion to take any action or omit to take any action which it deems proper and which is not inconsistent with such direction.