Tenant Alterations Tenant will not make or allow to be made any alterations in or to the Premises without first obtaining the written consent of Landlord, which consent may be granted or withheld in Landlord’s sole discretion; provided, however that such Landlord consent shall not be required for changes that are not to the exterior, or are not to the structure, or are not to Buildings systems, or which are merely cosmetic in nature. All Tenant alterations will be accomplished in a good and workmanlike manner at Tenant’s sole expense, in conformity with all Applicable Laws by a licensed and bonded contractor approved in advance by Landlord, such approval of contractor not to be unreasonably withheld or delayed. All contractors performing alterations in the Premises shall carry workers’ compensation insurance, commercial general liability insurance, automobile insurance and excess liability insurance in amounts reasonably acceptable to Landlord and shall deliver a certificate of insurance evidencing such coverages to Landlord prior to commencing work in the Premises. Upon completion of any such work, Tenant shall provide Landlord with “as built” plans, copies of all construction contracts, and proof of payment for all labor and materials. All alterations or improvements, shall remain with the Premises upon Lease termination or expiration and will be surrendered to Landlord along with the Premises at such time and will be deemed owned by Landlord at all times from and after and upon completion thereof (but rights to the use of same and Tenant’s obligations to keep in good order, condition and repair and maintain same, as a part of the Premises, shall remain with Tenant pursuant to this Lease during the term of this Lease). Tenant will have no authority or power, express or implied, to create or cause any construction lien or mechanics’ or materialmen’s lien or claim of any kind against the Premises, the Property or any portion thereof. Landlord’s interest in the Premises is not and shall not be subject to any liens as a result of Tenant’s use or occupancy of the Premises including specifically, without limitation, for improvements made by Tenant, and all such liens are expressly prohibited. Tenant will promptly cause any such liens or claims to be released by payment, bonding or otherwise within thirty (30) days after request by Landlord, and will indemnify Landlord against losses arising out of any such claim including, without limitation, legal fees and court costs. Landlord has the right, but not the obligation, to discharge any such lien. Any amount paid by Landlord for such purpose and Landlord’s related reasonable attorneys’ fees shall be paid by Tenant to Landlord upon demand and shall accrue interest from the date paid by Landlord until Landlord is reimbursed therefor at the highest rate permitted by Law. NOTICE IS HEREBY GIVEN THAT LANDLORD WILL NOT BE LIABLE FOR ANY LABOR, SERVICES OR MATERIAL FURNISHED OR TO BE FURNISHED TO TENANT, OR TO ANYONE HOLDING THE PREMISES THROUGH OR UNDER TENANT, AND THAT NO MECHANICS’ OR OTHER LIENS FOR ANY SUCH LABOR, SERVICES OR MATERIALS WILL ATTACH TO OR AFFECT THE INTEREST OF LANDLORD IN THE PREMISES. TENANT WILL DISCLOSE THE FOREGOING PROVISIONS TO ANY CONTRACTOR ENGAGED BY TENANT PROVIDING LABOR, SERVICES OR MATERIAL TO THE PREMISES.
LEASE ALTERATIONS The Owner hereby gives power to the Agent to initiate, sign, renew, modify, or cancel rental agreements and leases for the Property, or any part thereof and collect and give receipts for rents, other fees, charges, and security deposits.
Alterations Tenant shall not make any alterations to the Premises, including any changes to the existing landscaping, without Landlord's prior written consent. Tenant may make non-structural alterations costing less than $50,000 per event without Landlord's consent. Regardless of whether Landlord's consent for alteration is required, Tenant must provide Landlord at least fifteen (15) business days prior to the commencement of any alteration with a complete description of each such alteration including any building permit drawing(s) and specifications. Landlord may post notices regarding non-responsibility in accordance with the laws of the state in which the Premises are located. All alterations made by Tenant, whether or not subject to the approval of Landlord, shall be performed by Tenant and its contractors in a first class workmanlike manner and permits and inspections shall be obtained from all required governmental entities. Any alterations made shall remain on and be surrendered with the Premises upon expiration or termination of this Lease, except that Landlord may, in connection with Tenant's request for Landlord's approval of any such alteration, elect to require Tenant to remove some or all of the alterations which Tenant may have made to the Premises ("REQUIRED REMOVABLES"). If Landlord so elects, Tenant shall at its own cost restore the Premises to the condition designated by Landlord in its election or pursuant to any prior approval, before the last day of the Term. Should Landlord consent in writing to Tenant's alteration of the Premises, Tenant shall contract with a contractor approved by Landlord for the construction of such alterations, shall secure all appropriate governmental approvals and permits, and shall complete such alterations with due diligence in compliance with plans and specifications approved by Landlord (if required). Tenant shall pay all costs for such construction and shall keep the Premises free and clear of all mechanics' liens which may result from construction by Tenant. Tenant's property shall include, without limitation, Tenant's furniture, furnishings, business machines and equipment, computer conduits, communications equipment and such other property as may be required in the conduct of Tenant's business. Tenant shall have the right, but not the obligation (except at the expiration or prior termination of the Term), to remove the same at any time, to finance the purchase thereof, to grant security interests therein and to otherwise encumber same.
Tenant’s Alterations (a) Except as hereafter provided, Tenant shall make no alterations, additions or improvements (“Tenant Alterations”) to the Leased Space without the consent of Landlord, which consent shall not be unreasonably withheld, delayed or conditioned. At the time of Landlord’s consent, Landlord shall designate whether Tenant shall be required to remove the proposed Tenant Alteration upon termination of this Lease, and the absence of such designation in Landlord’s written consent shall be deemed Landlord’s agreement that Tenant shall not be obligated to remove Tenant Alterations upon the termination of this Lease. Landlord also may impose such reasonable conditions as part of its consent as Landlord deems appropriate, taking into consideration the nature of the proposed Tenant Alteration, including, without limitation, requiring Tenant to furnish Landlord with security for the payment of all costs to be incurred in connection with such work, insurance, and copies of the plans, specifications and permits necessary for such work. Nothing herein, however, shall be construed to obligate Tenant to construct any Tenant Alteration for which Landlord has given its consent.
(b) Landlord’s consent shall not be required for Tenant Alterations which (i) do not adversely impact the structural integrity of the Building or the systems serving the Building or their operation, (ii) are not visible from the Building exterior and (iii) qualify under the following:
(A) The Tenant Alteration is to be made to portions of the Leased Premises other than the laboratory areas and the cost thereof is $10,000 or less with respect to any Tenant Alteration project (or $20,000 or less in the aggregate with respect to Tenant Alteration projects undertaken over any twelve (12) consecutive month period); or
(B) The Tenant Alteration is to be made to the laboratory areas of the Leased Premises and the cost thereof is $50,000 or less with respect to any Tenant Alteration project (or $100,000 or less in the aggregate with respect to Tenant Alteration projects undertaken over any twelve (12) consecutive month period). Tenant Alterations described in this subsection (b) for which Landlord’s consent is not required hereinafter are called “Permitted Tenant Alterations.” Notwithstanding the foregoing, painting or carpeting of the interior of the Leased Space and like cosmetic improvements shall not be deemed Tenant Alterations regardless of the cost thereof. Tenant shall not be obligated to remove Permitted Tenant Alterations upon the termination of this Lease unless an Event of Default has occurred which is then continuing and Landlord so requires such removal.
(c) All Tenant Alterations shall be done at Tenant’s expense by contractors approved by Landlord, which approval shall not be unreasonably withheld, delayed or conditioned and shall be deemed given unless Landlord notifies Tenant of its objections within ten (10) business days after delivery of Tenant’s request for approval. With respect to Tenant Alterations other than the Permitted Tenant Alterations, no work shall be performed until the plans therefore have been approved by Landlord, which approval shall not be unreasonably withheld, delayed or conditioned and shall be deemed approved unless Landlord notifies Tenant of objections to the proposed plans within ten (10) business days after delivery to Landlord of a complete set of the plans therefor. In connection with the review of plans submitted by Tenant, Landlord shall be reimbursed by Tenant for Landlord’s cost in reviewing such plans at the rate of $125.00 per hour; subject to reasonable increase to reflect the then current hourly charge imposed for such review by Landlord for its tenants in the Center generally, and prior to undertaking any such review, Landlord shall provide a statement of the maximum review hours to be dedicated to such review. With respect to Permitted Tenant Alterations, Tenant shall provide Landlord with a copy of Tenant’s application for a building permit therefor, if applicable (together with all attachments thereto), and no review fee shall be charged to Tenant by Landlord in connection therewith nor shall Landlord’s approval of such application be required. Tenant shall provide copies of as-built plans and specifications for all Tenant Alterations to Landlord within a reasonable time of completion of the Tenant Alteration. All Tenant Alterations shall be done in a first class, workmanlike manner and shall comply with all insurance requirements then made available to Tenant and all applicable laws, ordinances, rules and regulations of governmental authorities having jurisdiction thereover, and, where applicable, with all reasonable requirements of Landlord imposed as a condition of such consent.
(d) If, as a condition of Landlord’s consent, removal of a Tenant Alteration is required at termination of this Lease, Tenant shall promptly remove such Tenant Alterations and repair any damage occasioned by such removal. In default thereof, Landlord may effect said removal and repairs at Tenants expense. With respect to any Tenant Alterations which Tenant is not obligated to remove hereunder (including without limitation Permitted Tenant Alterations), such Tenant Alterations, if not removed by Tenant upon the termination of this Lease, shall be deemed abandoned by Tenant, and deemed a part of Landlord’s property, notwithstanding any provision of Section 16 to the contrary.
Landlord’s Consent to Alterations Tenant may not make any improvements, alterations, additions or changes to the Premises (collectively, the “Alterations”) without first procuring the prior written consent of Landlord to such Alterations, which consent shall be requested by Tenant not less than fifteen (15) days prior to the commencement thereof, and which consent shall not be unreasonably withheld, conditioned or delayed by Landlord; provided, however, Landlord may withhold its consent in its sole and absolute discretion with respect to any Alterations which may adversely affect the structural components of the Building or the Systems and Equipment in more than a de minimis manner (e.g., the mere tying into Systems shall not be subject to the sole discretion standard) or which can be seen from outside the Building. Tenant shall pay (i) for Alterations performed by Tenant, Landlord’s reasonable third-party costs incurred in connection with reviewing such Alterations, and (ii) for Alterations for which Tenant has engaged Landlord to supervise and Landlord’s contractors to perform, a supervision fee of two and one-half percent (2.5%) of the total cost of such Alteration (for the avoidance of doubt, the foregoing supervisory fee shall not be due or payable in connection with the Tenant Improvements and the Vivarium improvements and no supervisory fee shall be due or payable in connection with any capital improvements performed by Landlord). Notwithstanding the foregoing, no Landlord approval shall be required (provided advance notice shall be provided to Landlord) for (a) installation, removal or realignment of furniture systems not involving any modifications to the structure or connections (other than by ordinary plugs or jacks) to the Systems, (b) Alterations which could not reasonably be expected to affect the structural components of the Building or the Systems and Equipment and which cost less than $150,000 for any one (1) job and no more than $300,000 in the aggregate in any calendar year during the Lease Term (excluding any costs for painting, carpeting, and similar purely cosmetic work), (c) Alterations which do not require a building permit, and (d) merely cosmetic work (such as painting and carpeting). The construction of the initial improvements to the Premises shall be governed by the terms of the Tenant Work Letter and not the terms of this Article 8.
Landlord Improvements (a) On the Commencement Date, Landlord will deliver the Leased Premises to Tenant in a broom clean condition, and, along with the lighting, electrical (excluding the UPS system and the diesel generator), mechanical and plumbing fixtures, plumbing systems, dock doors and HVAC servicing the Leased Premises, hot water, doors and plate-glass, will be delivered to Tenant in good condition and repair, as defined in Section 5.05 above.
(b) After receipt of the Letter of Credit and any required building permit, Landlord will commence and diligently pursue to completion, the construction of the improvements to the Leased Premises (the “Landlord Improvements”), in accordance with plans and specifications as shown in Exhibit B, subject to approval by local regulatory authorities (the “Plans”), which Plans are made a part of this Lease by reference. Any changes or modifications to the Plans must be made and accepted by written change order or agreement signed by Landlord and Tenant and will constitute an amendment to this Lease. Any Landlord Improvements made by Landlord are the property of Landlord and must be surrendered to Landlord upon the termination of this Lease without credit to Tenant. Upon completion of any Landlord Improvements and issuance of a final certificate of occupancy (to be applied for by Landlord’s general contractor) and certification from Landlord’s general contractor certifying to Tenant that all Landlord Improvements have been completed in accordance with the Plans (the “General Contractor’s Certificate”), thereafter Landlord shall provide and Tenant shall acknowledge receipt and acceptance of “as-built plans” of all work done in accordance with this Section 6.01.
(c) Landlord shall furnish an allowance of up to $172,800.00 (One hundred seventy-two thousand, eight hundred dollars) (“Landlord Improvement Allowance”) to be credited against the cost of the construction of the Landlord Improvements. If the actual cost of construction of the Landlord Improvements is less than the Landlord Improvement Allowance (“Allowance Overage”), Tenant shall have no right or claim to such difference; provided however, that if there is an Allowance Overage, Landlord, upon submission of supporting documentation by Tenant, will reimburse Tenant for any third party costs of low voltage wiring and laboratory benches for the Leased Premises, but such reimbursement shall not exceed the lesser of the Allowance Overage or 69,120.00 (Sixty-nine thousand, one hundred twenty & xx/100 dollars). If the actual cost of construction of the Landlord Improvements exceeds the Landlord Improvement Allowance, Tenant shall pay such excess cost to Landlord within ten (10) business days after receipt of supporting documentation and the General Contractor’s Certificate,.
(d) Notwithstanding anything contained in Section 6.01 (c) above, within 30 days after the issuance of the General Contractor’s Certificate, Landlord will determine the sum of (i) the actual cost of the Landlord Improvements, plus (ii) if any, the actual costs submitted by Tenant towards the Contingent Allowance, and the product of the calculation shall be rounded to the next $1,000.00 (One Thousand Dollars). If the resultant amount is less than the Landlord Improvement Allowance, Landlord shall reduce the monthly Base Rent by $20.25 (“Base Rent Reduction Factor”) for each whole $1,000.00 (One Thousand Dollars) of such amount effective January 1, 2012. If it is determined that the monthly Base Rent is to be reduced and if Tenant has already paid Base Rent in a pre-reduction amount, Landlord shall give Tenant credit for any such excess payment, and reduction in monthly Base Rent shall be memorialized in an amendment to this Lease. In the event that the monthly Base Rent is reduced in accordance with this Section 6.01(d), there shall be no reduction in the Security Deposit Amount or in the requirements set forth for the Letter of Credit. The following example illustrates the intentions of the parties hereto as to computation of any reduction of the monthly Base Rent: Assumptions:
1. Actual cost of the Landlord Improvements: $100,000.00
2. Actual cost of qualifying costs for Contingent Allowance: $50,500.00 Total cost of Landlord Improvements and Contingent Allowance Costs: ($100,000.00 + $50,500.00) = $150,500.00 Determination of reduction in monthly Base Rent: Total Landlord Improvement Allowance $ 172,800.00 Less total cost of Landlord Improvements and contingent costs 150,500.00 $ 22300.00 Rounded to next $1,000.00 (One Thousand Dollars) $ 23,000.00 Divided by $1,000.00 (One Thousand Dollars) 1,000.00 Base Rent Reduction Factor 20.25 Reduction in monthly Base Rent $ 465.75
(e) In addition to the Landlord Improvements, Landlord, at Landlord’s sole cost and expense, shall have the following additional work performed on the Leased Premises prior to delivery of possession to Tenant, such work to be coordinated with the construction of the Landlord Improvements:
(i) Replace all stained, damaged or missing ceiling tiles,
(ii) Paint all walls in the Leased Premises, the color to be designated by Tenant,
(iii) Replace all vinyl floor tiles in the open laboratory area as shown in Exhibit C,
(iv) Shampoo all carpets in the office areas and hallways and
(v) Any existing water supply or drainage pipes in the open lab area that are not initially utilized by Tenant shall be capped and made reasonably flush with the floor, but such capping shall allow for those pipes to be tapped by Tenant for future use.
(vi) Re-caulk all perimeter flashing; install new pads under all gas line blocking; repair any loose or open curb or wall flashing; repack all pitch pans; repair any open joints on gravel guard; repair any loose scupper flashing; clean, prime and install EPDM peel and stick tape to all roof side tilt wall joints; clean all debris from around drains and entire roof; install Xxxxxx 97 asbestos free aluminum coating to entire roof surface
(vii) Repair any existing alligator or pothole areas.
Tenant Improvements Landlord shall cause the Core and Shell Contractor or another Contractor designated by Landlord and approved by Tenant, such consent not to be unreasonably withheld or delayed (“TI Contractor”, and together with Core and Shell Contractor, “Contractor”) to commence and thereafter diligently prosecute the construction of the tenant improvements in the Premises pursuant to the Work Letter (the “Tenant Improvements”); provided, however, that before performing the Tenant Improvements, Landlord shall prepare in good faith an estimated budget for the construction of the Tenant Improvements and deliver such budget to Tenant for Tenant’s written approval prior the start of construction (the “Budget”). Landlord and Tenant shall work together cooperatively and in good faith to achieve a mutually acceptable Budget. Landlord shall update the Budget for Tenant’s review and approval at reasonable intervals and shall notify Tenant in writing if the Budget is likely to be exceeded. If there is an indication that the Budget is likely to be exceeded, Landlord and Tenant shall work together cooperatively, if required by Tenant, to modify the scope of the Tenant Improvements to bring the same in line with a budget reasonably acceptable to Tenant. The Tenant Improvements shall be performed in a workmanlike manner and shall substantially conform with Applicable Laws and the Approved TI Plans (as defined in the Work Letter). Tenant shall pay all TI Costs, except that Landlord shall pay for TI Costs that do not exceed the TI Allowance. The “TI Allowance” shall mean (a) One Hundred Twenty Five Dollars ($125.00) per rentable square foot of the Premises (the “Initial TI Allowance”), together with (b) the Additional Allowance. The “TI Costs” shall mean all Tenant Core and Shell Costs (as defined in the Work Letter) and all costs and expenses of performing the TI Work, including without limitation the hard and soft costs of (i) construction, (ii) the Construction Management Fee (as such term is defined in the Work Letter) and any Project or construction management fees paid by Tenant to an unaffiliated third party (such fees not to exceed three percent (3%) of the TI Allowance), (iii) space planning, design, architect, engineering, data and phone cabling and other related services, (iv) costs and expenses for labor, material, equipment, data and phone cabling and fixtures (including, without limitation, any of the Attached Property (as defined in Section 18.5), (v) building permits and other taxes, fees, charges and levies by governmental and quasi-governmental agencies for permits or for inspections of the Tenant Improvements, and (vi) the Warm Shell Costs. In no event shall the TI Allowance be used for: (w) the purchase of any furniture, personal property or other non-building system equipment, (x) costs resulting from a Tenant Delay, (y) costs resulting from any default by Tenant of its obligations under this Lease, or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). In the event the estimated total TI Costs (as set forth in the Budget) exceed the TI Allowance, Tenant shall deposit with Landlord such overage (the “TI Allowance Excess”), within five (5) business days of receiving the Budget (the “TI Deposit”). In the event Landlord determines the estimate of the TI Costs set forth in the Budget underestimates the amount of TI Costs so that the TI Deposit will not be sufficient to cover the TI Allowance Excess, then Landlord shall communicate the same to Tenant and, if required by Tenant, the parties shall discuss revisions to the Budget and Tenant may make a TI Tenant Change Order Request to reduce TI Costs, and unless the TI Costs are reduced to be within the Budget and previously paid TI Deposit, Tenant shall promptly pay the additional amount to Landlord, and such additional amount shall be added to the TI Deposit. If the sum of the TI Allowance plus the TI Deposit is not sufficient to cover the TI Costs, Tenant shall reimburse Landlord the difference between (a) the TI Costs and (b) the sum of the TI Allowance and the TI Deposit. However, Landlord shall be solely responsible for any costs related to the Tenant Improvements to the extent the same result from Landlord’s gross negligence, intentional misconduct or breach of Lease. Landlord and Tenant shall work together cooperatively at no cost or risk to Landlord to maximize Tenant’s ability, to the extent reasonably possible, to obtain the benefit of any applicable research and development tax credits with respect to the Tenant Improvements.
No Alterations No alterations or additions may be made to the premises nor may any fixtures be installed or placards, decorations or other articles be attached in any way to any part of the premises without the prior written approval of the Village Hall Secretary. Any alteration, fixture or fitting or attachment so approved shall at the discretion of the Village Hall remain in the premises at the end of the hiring. It will become the property of the Village Hall unless removed by the Hirer who must make good to the satisfaction of the Village Hall any damage caused to the premises by such removal.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
MAINTENANCE, REPAIRS, OR ALTERATIONS The Tenant shall, at their own expense and at all times, maintain premises in a clean and sanitary manner, and shall surrender the same at termination hereof, in as good condition as received, normal wear and tear excepted. The Tenant may not make any alterations to the leased premises without the consent in writing of the Landlord. The Landlord shall be responsible for repairs to the interior and exterior of the building. If the Premises includes a washer, dryer, freezer, dehumidifier unit and/or air conditioning unit, the Landlord makes no warranty as to the repair or replacement of units if one or all shall fail to operate. The Landlord will place fresh batteries in all battery-operated smoke detectors when the Tenant moves into the premises. After the initial placement of the fresh batteries it is the responsibility of the Tenant to replace batteries when needed. A monthly "cursory" inspection may be required for all fire extinguishers to make sure they are fully charged.
