Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Multi-year Planning Targets Schedule A may reflect an allocation for the first Funding Year of this Agreement as well as planning targets for up to two additional years, consistent with the term of this Agreement. In such an event, the HSP acknowledges that if it is provided with planning targets, these targets: a. are targets only, b. are provided solely for the purposes of planning, c. are subject to confirmation, and d. may be changed at the discretion of the Funder in consultation with the HSP. The HSP will proactively manage the risks associated with multi-year planning and the potential changes to the planning targets; and the Funder agrees that it will communicate any changes to the planning targets as soon as reasonably possible.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
CONTRACTS WITH ELIGIBLE FOREIGN CUSTODIANS The Foreign Custody Manager shall determine that the contract governing the foreign custody arrangements with each Eligible Foreign Custodian selected by the Foreign Custody Manager will satisfy the requirements of Rule 17f-5(c)(2).
Conflicts with RS Means Unit Price Book If the terms of the solicitation referenced RS Means Unit Price Book occur, the RS Means Book shall control if it determines the legality of the solicitation award as it relates to the requisite Means Unit Price Book.
Know-How Necessary for the Business The Intellectual Property Rights are all those necessary for the operation of the Company’s businesses as it is currently conducted or as represented, in writing, to the Purchasers to be conducted. The Company is the owner of all right, title, and interest in and to each of the Intellectual Property Rights, free and clear of all liens, security interests, charges, encumbrances, equities, and other adverse claims, and has the right to use all of the Intellectual Property Rights. To the Company’s knowledge, no employee of the Company has entered into any contract that restricts or limits in any way the scope or type of work in which the employee may be engaged or requires the employee to transfer, assign, or disclose information concerning his work to anyone other than of the Company.
AGREEMENTS WITH EMPLOYEES AND SUBCONTRACTORS Grantee shall have written, binding agreements with its employees and subcontractors that include provisions sufficient to give effect to and enable Grantee’s compliance with Grantee’s obligations under this Article VI.
Agreements with Employees and Subcontractors Grantee shall have written, binding agreements with its employees and subcontractors that include provisions sufficient to give effect to and enable Grantee’s compliance with Grantee’s obligations under this Article VI, Intellectual Property.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Venue Limitation for TIPS Sales Vendor agrees that if any "Venue" provision is included in any TIPS Sale Agreement/contract between Vendor and a TIPS Member, that clause must provide that the "Venue" for any litigation or alternative dispute resolution shall be in the state and county where the TIPS Member operates unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing a “Venue” clause that conflicts with these terms is rendered void and unenforceable.
