Site Preparation Axon will provide a hardcopy or digital copy of current user documentation for the Axon Devices ("User Documentation"). User Documentation will include all required environmental specifications for the professional services and Axon Devices to operate per the Axon Device User Documentation. Before installation of Axon Devices (whether performed by Customer or Axon), Customer must prepare the location(s) where Axon Devices are to be installed ("Installation Site") per the environmental specifications in the Axon Device User Documentation. Following installation, Customer must maintain the Installation Site per the environmental specifications. If Axon modifies Axon Device User Documentation for any Axon Devices under this Agreement, Axon will provide the update to Customer when Axon generally releases it
Surface Preparation Clean the surface to be treated of all dust, dirt, clay, grass, sod and any other deleterious matter before application of the asphalt surface treatment.
DOCUMENT PREPARATION The Transfer/Deed shall, save for the Land Transfer Tax Affidavit, be prepared in registrable form at the expense of Seller, and any Charge/Mortgage to be given back by the Buyer to Seller at the expense of the Buyer. If requested by Buyer, Seller covenants that the Transfer/Deed to be delivered on completion shall contain the statements contemplated by Section 50(22) of the Planning Act, R.S.O.1990.
Proposal Preparation The contractor shall assume all costs associated with preparation of proposals for task order awards under the proposal process as an indirect charge (B&P costs). The Government will not reimburse awardees for proposals as a direct charge.
Joint Preparation The preparation of this Agreement has been a joint effort of the parties and the resulting documents shall not, solely as a matter of judicial construction, be construed more severely against one of the parties than the other.
Delayed Delivery (a) No adjustment shall be made and the CONTRACT PRICE shall remain unchanged for the first thirty (30) days of the delay in delivery of the VESSEL ending as of 12 o'clock midnight Korean Standard Time on the thirtieth (30th) day of delay beyond the DELIVERY DATE calculated as provided in Article VII.1. hereof.
(b) If delivery of the VESSEL is delayed more than thirty (30) days beyond the DELIVERY DATE then, in such event, beginning at midnight of the thirtieth (30th) day after such due date, the CONTRACT PRICE of the VESSEL shall be reduced by U.S. Dollars Twenty Three Thousand (US$ 23,000) for each full day of delay. However, unless the parties agree otherwise, the total amount of deduction from the CONTRACT PRICE shall not exceed the amount due to cover the delay of one hundred and eighty (180) days after thirty (30) days of the delay in delivery of the VESSEL at the rate of deduction as specified hereinabove.
(c) But, if the delay in delivery of the VESSEL continues for a period of more than two hundred and ten (210) days beyond the DELIVERY DATE then, in such event, and after such period has expired, the BUYER may, at its option, rescind or cancel this CONTRACT, by serving upon the BUILDER a notice of cancellation by email or facsimile to be confirmed by a registered letter via airmail directed to the BUILDER at the address given in this CONTRACT. Such cancellation shall be effective as of the date the notice thereof is received by the BUILDER. If the BUYER has not served the notice of cancellation after the aforementioned two hundred and ten (210) days delay in delivery, the BUILDER may demand the BUYER to make an election in accordance with Article VIII.3. hereof.
(d) For the purpose of this Article, the delivery of the VESSEL shall be deemed to be delayed when and if the VESSEL, after taking into full account extension of the DELIVERY DATE or permissible delays as specifically provided in Articles V, VI, VIII, XI or elsewhere in this CONTRACT, is delivered beyond the date upon which delivery would then be due under the terms of this CONTRACT.
Preparation Awarded vendor shall not begin a project for which TIPS Member has not prepared the site, unless awarded vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in a purchase order. Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre-installation requirements. Registered sex offender restrictions: For work to be performed at schools, awarded vendor agrees that no employee of a sub-contractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present. Awarded vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the purchase order at the TIPS Member’s discretion. Awarded vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety measures: Awarded vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Awarded vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage.
Negotiation In the event of a controversy, dispute or claim arising out of, in connection with, or in relation to the interpretation, performance, nonperformance, validity or breach of this Agreement or otherwise arising out of, or in any way related to this Agreement or the transactions contemplated hereby, including any claim based on contract, tort, statute or constitution (collectively, “Agreement Disputes”), the Party claiming such Agreement Dispute shall give written notice to the other Party setting forth the Agreement Dispute and a brief description thereof (a “Dispute Notice”) pursuant to the terms of the notice provisions of Section 7.1 hereof. Following delivery of a Dispute Notice, the general counsels of the relevant Parties and/or such other executive officer designated by the relevant Party shall negotiate for a reasonable period of time to settle such Agreement Dispute; provided that such reasonable period shall not, unless otherwise agreed by the Parties in writing, exceed forty-five (45) calendar days from the time of receipt by a Party of a Dispute Notice; provided further, that in the event of any arbitration in accordance with Section 6.3 hereof, the relevant Parties shall not assert the defenses of statute of limitations and laches arising during the period beginning after the date of receipt of the Dispute Notice, and any contractual time period or deadline under this Agreement to which such Agreement Dispute relates occurring after the Dispute Notice is received shall not be deemed to have passed until such Agreement Dispute has been resolved.
Costs of negotiation, preparation etc The Borrowers shall pay to the Agent on its demand the amount of all expenses incurred by the Agent or the Security Trustee in connection with the negotiation, preparation, execution or registration of any Finance Document or any related document or with any transaction contemplated by a Finance Document or a related document.
Loan Application Buyer agrees, within a reasonable time, to make a good faith loan application with a credible financial institution;
