Suretyship Waivers Each Borrower hereby expressly waives (a) diligence, presentment, demand for payment, protest, benefit of any statute of limitations affecting such Borrower's liability under this Agreement or the Loan Documents; (b) discharge due to any disability of any Borrower; (c) any defenses of any Borrower to obligations under this Agreement or the Loan Documents not arising under the express terms of this Agreement or the Loan Documents or from a material breach thereof by Agent of the Lenders which under applicable law has the effect of discharging any Borrower from the obligations as to which this Agreement is sought to be enforced; (d) the benefit of any act or omission by Agent of the Lenders which directly or indirectly results in or aids the discharge of any Borrower from any of the Obligations by operation of law or otherwise; (e) except as expressly provided herein, all notices whatsoever, including, without limitation, notice of acceptance of the incurring of the Indebtedness; (f) any right it may have to require the Agent of the Lenders to disclose to it any information that the Agent or the Lenders may now or hereafter acquire concerning the financial condition or any circumstance that bears on the risk of nonpayment by any other Borrower, including, without limitation, the release of such other Borrower from the Indebtedness; and (g) any requirement that the Agent of the Lenders exhaust any right, power or remedy or proceed against any other Borrower or any other security for, or any guarantor of, or any other party liable for, any of the Indebtedness, or any portion thereof. Each Borrower specifically agrees that it shall not be necessary or required, and Borrowers shall not be entitled to require, that the Agent or the Lenders (i) file suit or proceed to assert or obtain a claim for personal judgment against any other Borrower for all or any part of the Indebtedness; (ii) make any effort at collection or enforcement of all or any part of the Obligations from any Borrower; (iii) foreclose against or seek to realize upon any security now or hereafter existing for all or any part of the Indebtedness; (iv) file suit or proceed to obtain or assert a claim for personal judgment against any Borrower or any guarantor or other party liable for all or any party of the Indebtedness; (v) exercise or assert any other right or remedy to which the Agent or any Lender is or may be entitled in connection with the Obligations or any security or guaranty relating thereto to assert; or (vi) file any claim against assets of one Borrower before or as a condition of enforcing the liability of any other Borrower under this Agreement or the Loan Documents. Without limiting the foregoing in any way, each Borrower hereby irrevocably waives and releases:
Guaranty Agreements Any Guaranty Agreement or any provision thereof shall for any reason cease to be in full force and effect or valid and binding on or enforceable against any Credit Party or a Credit Party shall so state in writing or bring an action to limit its obligations or liabilities thereunder; or any Credit Party shall fail to perform any of its obligations thereunder; or
Guaranty Agreement FOR VALUE RECEIVED, the receipt and sufficiency of which is hereby acknowledged, and in consideration of the agreement of Xxxxxxxx Development Company, LLC, (the "Developer") to permit deferral of the $246,884 due from Desloge Associates I, L.P. a Missouri limited partnership ("Debtor") to the Developer, the undersigned Guarantor(s), hereby unconditionally guaranty the full and prompt payment when due, whether by acceleration or otherwise of that certain Developer Fee from Debtor to the Developer, evidenced by the Development Services Agreement dated October 1, 1998 incorporated herein by this reference. The foregoing described debt is referred to hereinafter as the "Liabilities" or "Liability." The undersigned further agree to pay all expenses paid or incurred by the Developer in endeavoring to collect the Liabilities, or any part thereof, and in enforcing the Liabilities or this Guaranty Agreement (including reasonable attorneys' fees if collected or enforced by law or through an attorney-at-law). The undersigned hereby represent and warrant that the extension of credit or other financial accommodations by the Developer to Debtor will be to the interest and advantage of the undersigned, and acknowledge that this Guaranty Agreement is a substantial inducement to the Developer to extend credit to Debtor and that the Developer would not otherwise extend credit to Debtor. The Developer may, from time to time, without notice to or consent of the undersigned, (a) retain or obtain a security interest in any property to secure any of the Liabilities or any obligation hereunder, (b) retain or obtain the primary or secondary liability of any party or parties, in addition to the undersigned, with respect to any of the Liabilities, (c) extend or renew for any period (whether or not longer than the original period) or alter any of the Liabilities, (d) release or compromise any Liability of the undersigned hereunder or any Liability of any other party or parties primarily or secondarily liable on any of the Liabilities, (e) release, compromise or subordinate its title or security interest, or any part thereof, if any, in all or any property now or hereafter securing any of the Liabilities or any obligation hereunder, and permit any substitution or exchange for any such property, and (f) resort to the undersigned for payment of any of the Liabilities, whether or not the Developer shall have resorted to any property securing any of the Liabilities or any obligation hereunder or shall have preceded against any other party primarily or secondarily liable on any of the Liabilities. The undersigned hereby expressly waive: (a) notice of the existence or creation of all or any of the Liabilities, (b) notice of any amendment or modification of any of the instruments or documents evidencing or securing the Liabilities, (c) presentment, demand, notice of dishonor and protest, (d) all diligence in collection or protection of or realization upon the Liabilities or any thereof, any obligation hereunder, or any security for any of the foregoing, and (e) the right to require the Developer to proceed against Debtor on any of the Liabilities. In the event any payment of Debtor to the Developer is held to constitute a preference under the bankruptcy laws, or if for any other reason the Developer is required to refund such payment or pay the amount thereof to any other party, such payment by Debtor to the Developer shall not constitute a release of Guarantor from any Liability hereunder, but Guarantor agrees to pay such amount to the Developer upon demand and this Guaranty shall continue to be effective or shall be reinstated, as the case may be, to the extent of any such payment or payments. No delay or failure on the part of the Developer in the exercise of any right or remedy shall operate as a waiver thereof, and no single or partial exercise by the Developer of any right or remedy shall preclude other or future exercise thereof or the exercise of any other right or remedy. No action of the Developer permitted hereunder shall in any way impair or affect this Guaranty Agreement. For the purpose of this Guaranty Agreement, the Liabilities of Debtor to the Developer are guaranteed notwithstanding any right or power of Debtor or anyone else to assert any claim or defense as to the invalidity or unenforceability of any such obligation, and no such claim or defense shall impair or affect the obligations of the undersigned hereunder. Payment by the Guarantor under this Guaranty Agreement shall be recorded as a cost overrun and not repayable. It shall be a payment from the Guarantor to Debtor and, subsequently, as a payment of the Development Fee from Debtor to Developer. This Guaranty Agreement shall be binding upon the undersigned, and upon the legal representatives, heirs, successors and assigns of the undersigned. This Guaranty Agreement has been made and delivered in the state of Missouri and shall be construed and governed under Missouri law. Whenever possible, each provision of the Guaranty Agreement shall be interpreted in such manner as to be effective and valid under applicable law, but if any provision of this Guaranty Agreement shall be prohibited by or invalid under such law, such provision shall be ineffective to the extent of such prohibition of invalidity, without invalidating the remainder of such provision or the remaining provisions of this Guaranty Agreement. No person not a Party to this Agreement is an intended beneficiary of this Agreement, and no person not a Party to this Agreement shall have any right to enforce any term of this Agreement. Whenever the singular or plural number, masculine or feminine or neuter is used herein, it shall equally include the other where applicable. In the event this Guaranty Agreement is executed by more than one guarantor, this Guaranty Agreement and the obligations hereunder are the joint and several obligation of the undersigned. Guarantor consents to the jurisdiction of the courts in the State of Missouri and/or to the jurisdiction and venue of any United States District Court in the State of Missouri having jurisdiction over any action or judicial proceeding brought to enforce, construe or interpret this Guaranty. Guarantor agrees to stipulate in any such proceeding that this Guaranty is to be considered for all purposes to have been executed and delivered within the geographical boundaries of the State of Missouri, even if it was, in fact, executed and delivered elsewhere.
Guaranty Matters The Lenders irrevocably authorize the Administrative Agent, at its option and in its discretion, to release any Guarantor from its obligations under the Guaranty if such Person ceases to be a Subsidiary as a result of a transaction permitted hereunder. Upon request by the Administrative Agent at any time, the Required Lenders will confirm in writing the Administrative Agent’s authority to release any Guarantor from its obligations under the Guaranty pursuant to this Section 9.10.
Guaranty and Collateral Agreement A counterpart of the Guaranty and Collateral Agreement executed by each Loan Party, together with all instruments, transfer powers and other items required to be delivered in connection therewith.
Guaranty and Security Agreement The security interest granted pursuant to this [Copyright] [Patent] [Trademark] Security Agreement is granted in conjunction with the security interest granted to Agent pursuant to the Guaranty and Security Agreement and each Grantor hereby acknowledges and agrees that the rights and remedies of Agent with respect to the security interest in the [Copyright] [Patent] [Trademark] Collateral made and granted hereby are more fully set forth in the Guaranty and Security Agreement, the terms and provisions of which are incorporated by reference herein as if fully set forth herein.
Waiver of Suretyship Defenses Each Guarantor agrees that the Credit Parties may, at any time and from time to time, and without notice to the Guarantors, make any agreement with the Borrower or with any other person or entity liable on any of the Guaranteed Obligations, for the extension, renewal, payment, compromise, discharge, or release of the Guaranteed Obligations, or for any modification or amendment of the terms thereof or of any instrument or agreement evidencing the Guaranteed Obligations, all without in any way impairing, releasing, discharging, or otherwise affecting the obligations of any Guarantor under this Guaranty. Each Guarantor waives any defense arising by reason of any disability or other defense of the Borrower or any other guarantor, or the cessation from any cause whatsoever of the liability of the Borrower, or any claim that any Guarantor’s obligations exceed or are more burdensome than those of the Borrower and waives the benefit of any statute of limitations affecting the liability of any Guarantor hereunder. Each Guarantor waives any right to enforce any remedy which such Guarantor now has or may hereafter have against the Borrower and waives any benefit of and any right to participate in any security now or hereafter held by the Administrative Agent for the benefit of the Credit Parties. Further, each Guarantor consents to the taking of, or failure to take, any action which might in any manner or to any extent vary the risks of such Guarantor under this Guaranty or which, but for this provision, might operate as a discharge of such Guarantor.
Indemnity Agreements Simultaneously with any person becoming a Designated Director, the Company shall execute and deliver to each such Designated Director an Indemnity Agreement dated the date such Designated Director becomes a director of the Company.
Credit Agreement; Guarantee and Collateral Agreement The Administrative Agent shall have received (i) this Agreement, executed and delivered by the Administrative Agent, Holdings, the Borrower and each Person listed on Schedule 1.1A and (ii) the Guarantee and Collateral Agreement, executed and delivered by Holdings, the Borrower and each Subsidiary Guarantor.
Indemnity Agreement The Indemnity Agreement Regarding Hazardous Materials made by the Borrower and Guarantors, in favor of the Agent and the Lenders, as the same may be modified, amended or ratified, pursuant to which each of the Borrower and the Guarantors agrees to indemnify the Agent and the Lenders with respect to Hazardous Substances and Environmental Laws.
