Contractor’s Obligations Pursuant to this contract, the Contractor agrees to provide the specific services detailed herein and shall be responsible for the following:
Authority’s Obligations Save as otherwise expressly provided, the obligations of the Authority under the Contract are obligations of the Authority in its capacity as a contracting counterparty and nothing in the Contract shall operate as an obligation upon, or in any other way xxxxxx or constrain the Authority in any other capacity, nor shall the exercise by the Authority of its duties and powers in any other capacity lead to any liability under the Contract (howsoever arising) on the part of the Authority to the Contractor.
Vendor’s Obligations Vendor shall incur no further obligations in connection with the terminated work and on the date set in the notice of termination Vendor will stop work to the extent specified. Vendor shall also terminate outstanding orders and subcontracts as they relate to the terminated work. Vendor shall settle the liabilities and claims arising out of the termination of subcontracts and orders connected with the terminated work. The MTC or designee may direct Vendor to assign Vendor’s right, title, and interest under terminated orders or subcontracts to the MTC. Vendor must still complete the work not terminated by the notice of termination and may incur obligations as are necessary to do so.
Guarantor’s Obligations Unconditional The covenants and agreements of the Guarantor set forth herein shall be primary obligations of the Guarantor, and such obligations shall be continuing, absolute and unconditional, shall not be subject to any counterclaim, setoff, deduction, diminution, abatement, recoupment, suspension, deferment, reduction or defense (other than full and strict compliance by the Guarantor with its obligations hereunder), whether based upon any claim that Lessee or the Guarantor or any other Person may have against Lessor or any other Person or otherwise, and shall remain in full force and effect without regard to, and shall not, to the fullest extent permitted by applicable laws, be released, discharged or in any way affected by, any circumstance or condition whatsoever (whether or not the Guarantor or Lessee shall have any knowledge or notice thereof) including, without limitation:
(a) any amendment, modification, addition, deletion, supplement or renewal to or other change in the Obligations, the Lease or any other Operative Document or any of the agreements referred to in any thereof, or any other instrument or agreement applicable to any Operative Document or any of the parties to such agreements, or to the Aircraft, or any assignment, mortgage or transfer thereof or of any interest therein, or any furnishing or acceptance of additional security for, guarantee of, or right of offset with respect to, any of the Obligations; or the failure or release of any security or the failure of Lessor to perfect or insure any interest in any collateral, including the Collateral;
(b) any failure, omission or delay on the part of Lessee or Lessor to conform or comply with any term of any instrument or agreement referred to in clause (a) above;
(c) any waiver, consent, extension, indulgence, compromise, release or other action or inaction under or in respect of any instrument, agreement, guarantee, right of offset or security referred to in clause (a) above or any obligation or liability of Lessee or Lessor, or any exercise or nonexercise by Lessor of any right, remedy, power or privilege under or in respect of any such instrument, agreement, guarantee, right of offset or security or any such obligation or liability;
(d) any bankruptcy, insolvency, reorganization, arrangement, readjustment, composition, liquidation or similar proceeding with respect to Lessee, Lessor or any other Person or any of their respective properties or creditors, or any action taken by any trustee, receiver, other Person or court in any such proceeding;
(e) any limitation on the liability or obligations of any Person under the Lease or any other Operative Document, the Obligations, any collateral security for the Obligations or any other guarantee of the Obligations or any reductions, limitation, impairment, discharge, termination, cancellation, frustration, irregularity, invalidity or unenforceability, in whole or in part, of any of the foregoing, the obligations under the Lease or any other agreement, instrument, guarantee or security referred to in clause (a) above or any term of any thereof;
(f) any defect in the title, compliance with specifications, condition, design, operation or fitness for use of or any damage to or loss or destruction of, or any interruption or cessation in the use of the Aircraft or any part thereof by Lessee or any other Person for any reason whatsoever (including, without limitation, any governmental prohibition or restriction, condemnation, requisition, seizure or any other act on the part of any governmental or military authority, or any act of God or of the public enemy) regardless of the duration thereof (even though such duration would otherwise constitute a frustration of a lease), whether or not resulting from accident and whether or not without fault on the part of Lessee or any other Person;
(g) any merger or liquidation of Lessee or any merger or consolidation of the Guarantor into or with any other corporation or partnership or any sale, lease or transfer of any of the assets of Lessee or the Guarantor to any other Person;
(h) any change in the ownership of the capital stock of Lessee; or
(i) any other occurrence or circumstance whatsoever, whether similar or dissimilar to the foregoing and any other circumstance that might otherwise constitute a legal or equitable defense or discharge of the liabilities of a guarantor or surety or that might otherwise limit recourse against the Guarantor. The obligations of the Guarantor, set forth herein constitute the full recourse obligations of the Guarantor enforceable against it to the full extent of all its assets and properties, notwithstanding any provision in the Lease or any other agreement limiting the liability of Lessor or any other Person. Nothing herein shall prohibit Lessor from exercising its rights against the Guarantor or any other Person simultaneously, jointly or severally. The Guarantor shall be bound by each and every ruling, order and judgment obtained by Lessor in respect of any of the obligations guaranteed hereunder whether or not the Guarantor is a party to the action or proceeding in which such ruling, order or judgment is issued or rendered.
CONTRACTOR’S OBLIGATION FOR RESELLER PARTICIPATION Contractor shall not, directly or indirectly, by agreement, communication or any other means, restrict any Reseller’s participation or ability to participate or compete in an Authorized User RFQ. Conditions of Reseller Participation Resellers must be approved in advance by OGS and posted to the State website before they may respond to an Authorized User’s RFQ. OGS also reserves the right to rescind any such participation at any time or request that Contractor name additional Resellers, in the best interests of Authorized Users, at the OGS’s sole discretion. Contractor shall have the right to qualify Resellers and their participation under this Contract provided that:
PLEDGORS’ OBLIGATIONS ABSOLUTE, ETC The obligations of each Pledgor under this Agreement shall be absolute and unconditional and shall remain in full force and effect without regard to, and shall not be released, suspended, discharged, terminated or otherwise affected by, any circumstance or occurrence whatsoever, including, without limitation: (i) any renewal, extension, amendment or modification of or addition or supplement to or deletion from any Secured Debt Agreement or any other instrument or agreement referred to therein, or any assignment or transfer of any thereof; (ii) any waiver, consent, extension, indulgence or other action or inaction under or in respect of any such agreement or instrument including, without limitation, this Agreement; (iii) any furnishing of any additional security to the Pledgee or its assignee or any acceptance thereof or any release of any security by the Pledgee or its assignee; (iv) any limitation on any party's liability or obligations under any such instrument or agreement or any invalidity or unenforceability, in whole or in part, of any such instrument or agreement or any term thereof; or (v) any bankruptcy, insolvency, reorganization, composition, adjustment, dissolution, liquidation or other like proceeding relating to any Pledgor or any Subsidiary of any Pledgor, or any action taken with respect to this Agreement by any trustee or receiver, or by any court, in any such proceeding, whether or not such Pledgor shall have notice or knowledge of any of the foregoing.
City’s Obligations A. Following the execution of this Agreement, the CITY shall begin efforts to implement the activities described in Article I of this Agreement. The failure by the CITY to develop and implement the activities described in Article I of this Agreement shall constitute a breach of this Agreement. The CITY understands and agrees that, in the event termination of this Agreement by CITY, or pursuant to Article V of this Agreement, the CITY shall reimburse the IDC the full amount of money paid by the IDC to the CITY.
B. In accordance with Chapter 2264 of the Texas Government Code, the CITY agrees not to knowingly employ an undocumented worker. During the term of this Agreement, the CITY shall notify the IDC of any complaint brought against CITY alleging that it has employed undocumented workers. If the CITY, or any branch, division or department of the CITY is convicted of a violation under 8 U.S.C. Section 1324a (f), the total amount of economic development grants it has received, together with interest at the rate of five percent (5%), shall be repaid by the CITY to the IDC not later than the one hundred twentieth (120th) day after the date the IDC becomes aware of and notifies the CITY of the violation. The CITY shall not be liable for a violation of Chapter 2264 by a subsidiary, affiliate, or franchisee, or by any person with whom the CITY contracts. The CITY shall reimburse the IDC the required amount within thirty (30) days of the termination of this Agreement. The CITY further certifies that CITY is following Texas Government Code Chapter 2252 (foreign terrorist organizations prohibited), Texas Government Code Chapter 2270 (boycott-Israel), and Texas Government Code Chapter 2274, (boycotts-energy company; discrimination – firearms entity or trade association).
C. The CITY shall keep and maintain complete and accurate records relating to its hiring and employment of persons, which is separate and identifiable from its other records, and shall make such records available for not less than three (3) years following termination of this Agreement. The IDC and its representatives shall be entitled to inspect said records during the term of this Agreement and for three (3) years thereafter, upon reasonable notice to the CITY. The CITY’s failure to comply with this provision will constitute a breach of the Agreement.
Conditions to Agent’s Obligations The obligations of the Agent hereunder with respect to a Placement will be subject to the continuing accuracy and completeness of the representations and warranties made by the Company herein, to the due performance by the Company of its obligations hereunder, to the completion by the Agent of a due diligence review satisfactory to it in its reasonable judgment, and to the continuing satisfaction (or waiver by the Agent in its sole discretion) of the following additional conditions:
Developer’s Obligations 7.1.1 In consideration of the Rights hereby granted, the Developer shall pay to the Authority an annual fee of Rs. /- (Rupees only) (“Fee”) commencing from the 1st (first) anniversary of Appointed Date. The Fee is exclusive of GST and all other applicable taxes and shall be payable by the Developer at actual over and above the Fee. The Fee is payable to the Authority on or before 30 (thirty) days prior to the start of every year in advance as set out in Schedule 1 throughout the Agreement Period. During the Agreement Period the Fee shall be increased by 5% (five percent) every year over the previous year’s Fee on compounded basis.
7.1.2 The Developer should pay the Fee to the Authority notwithstanding the fact that, the development of Project Facilities is not completed within the specified period or Developer does not start the commercial operation of the Project. In other words, the Developer shall not be entitled to seek any reduction of Fee, claim, damages, compensation or any other consideration from the Authority on account of any reason.
7.1.3 Any delay in payment of the Fee shall attract an interest for the delayed period at the rate of SBI PLR plus 5% per annum on the outstanding amount, which shall be due from the date of such payment till the amount is realized by the Authority. In addition to the foregoing, any delay in payment of Fee beyond a period of 60 (sixty) days from the due date of such payment will be construed to be Material Breach under this Agreement.
FURTHER CONDITIONS OF THE INVESTOR'S OBLIGATION TO PURCHASE The obligation of the Investor hereunder to purchase Shares is subject to the satisfaction, on or before each Closing Date, of each of the following conditions set forth below.
(A) The Company shall have executed the Equity Line Transaction Documents and delivered the same to the Investor.
(B) The Common Stock shall be authorized for quotation on the Principal Market and trading in the Common Stock shall not have been suspended by the Principal Market or the SEC, at any time beginning on the date hereof and through and including the respective Closing Date (excluding suspensions of not more than one (1) Trading Day resulting from business announcements by the Company, provided that such suspensions occur prior to the Company's delivery of the Put Notice related to such Closing).
(C) The representations and warranties of the Company shall be true and correct as of the date when made and as of the applicable Closing Date as though made at that time and the Company shall have performed, satisfied and complied with the covenants, agreements and conditions required by the Equity Line Transaction Documents to be performed, satisfied or complied with by the Company on or before such Closing Date. The Investor may request an update as of such Closing Date regarding the representation contained in Section 4(C) above.
(D) The Company shall have executed and delivered to the Investor the certificates representing, or have executed electronic book-entry transfer of, the Securities (in such denominations as the Investor shall request) being purchased by the Investor at such Closing.
(E) The Board of Directors of the Company shall have adopted resolutions consistent with Section 4(B)(II) above (the "Resolutions") and such Resolutions shall not have been amended or rescinded prior to such Closing Date.
