SUPPLIER’S WARRANTIES 16.1 The Supplier represents, warrants and undertakes to the Authority that:
16.1.1 the Supplier has the full right, power and authority to enter into and perform this Agreement and to grant all of the Authority Rights to the Authority and for the Authority to use and exploit the same as contemplated in this Agreement;
16.1.2 all information, representations, warranties and other matters of fact contained in the Supplier’s tender submission as part of the competitive tender process referred to in the recitals to this Agreement are true, complete and accurate in all respects and the Supplier agrees to be bound by the obligations and statements made in such tender submission as if the same were set out in this Agreement, save where there is any inconsistency between the terms of this Agreement and such tender submission the terms of this Agreement shall prevail;
16.1.3 save in respect of any Third Party Content, no Deliverable has and no Deliverable will have been broadcast, released or otherwise exploited in any Broadcast Media anywhere in the world prior to the relevant Delivery Date;
16.1.4 there is no contract or arrangement to which the Supplier is a party and the Supplier will not enter into any contract or arrangement and there is and will be no other encumbrance or restriction which could in any way interfere with or inhibit the full exercise or exploitation of any and all of the Authority Rights by the Authority;
16.1.5 the Supplier has paid and shall promptly pay all sums due to any person who is or may be entitled to any payment in respect of services or facilities rendered or goods supplied or rights granted in connection with the Deliverables or on the exercise by the Authority of any of the Authority Rights or in respect of any tax, duty, levy, national insurance or any similar payment in connection with the Deliverables required to be made by the Supplier;
16.1.6 the Supplier will have, by and as at the relevant Delivery Date, obtained all necessary consents, grants, clearances and rights (including any rights in musical compositions contained within the Deliverables (if any) which are controlled by the Performing Right Society or its affiliated bodies) to enable it to produce and deliver the Deliverables and to grant to and enable the Authority to exercise the Authority Rights free from any liens, claims and encumbrances;
16.1.7 to the extent any musical compositions are contained in the Deliverables:
16.1.7.1 all recording synchronisation and dubbing licences have been obtained and licence fees have been paid; and
16.1.7.2 the performing rights in such compositions shall throughout the Term be controlled (i) by the Performing Right Society or its affiliated bodies; or (ii) by the Supplier; or (iii) are in the public domain, in all cases to the extent required for the purposes of the Authority's full exercise of its rights as contemplated by this Agreement;
16.1.8 no claim or litigation is pending or threatened in respect of the Deliverables or any the Authority Rights;
16.1.9 the Deliverables will be produced in accordance with all Laws (including with respect to health and safety);
16.1.10 the Deliverables will be free from all Viruses;
16.1.11 the Deliverables will not contain anything which is in contravention of the Codes and Guidelines or any Laws or which is obscene, blasphemous, seditious, racially inflammatory, defamatory or which infringes the rights of any person, including rights of copyright or trade marks or service marks, privacy, publicity or confidentiality or any other civil or common law or statutory right whatsoever or breaches any contract or is in contempt of court;
16.1.12 the Supplier has not entered and will not enter into any co-production, co-financing, pre-sale or other arrangement or agreement which involves the surrender by the Supplier of any control of the Deliverables;
16.1.13 all information, records and data provided to the Authority and with respect to the Deliverables and the production process will be accurate in all respects, full and up to date;
16.1.14 the Supplier is not insolvent nor unable to pay its debts as they fall due and no steps have been taken with a view to the winding-up or administration of the Supplier or the making of any composition or arrangement with any creditors of the Supplier; and
16.1.15 the Supplier will not at any time do or say anything which is or may be considered by the Authority (acting reasonably) to be detrimental or prejudicial to or to affect adversely the name, image, reputation or business of the Authority or otherwise to bring the Authority or any member of the Authority Group into disrepute.
16.2 The Supplier's warranties shall be deemed repeated on each Delivery Date (or, if any Deliverables are delivered to the Authority after the scheduled Delivery Date and the Authority has not exercised any right under this Agreement to treat such delay as an Event of Default under clause 27.1, within ten Working Days of the date of actual delivery) and on every occasion when the Authority exercises its Authority Rights.
Manufacturer’s Warranties If a Lease Vehicle is covered by a Manufacturer’s warranty, the Lessee, during the Vehicle Term for such Lease Vehicle, shall have the right to make any claims under such warranty that the Lessor could make.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Manufacturer’s Warranty The Goods include the manufacturer’s standard limited parts warranty to replace defective parts covered under such warranty exclusive of labor. Labor is warranted by the Elevator Contractor for 90 days following installation. The manufacturer’s parts warranty may require that the Goods be maintained throughout the warranty period by an authorized manufacturer’s representative under a separate maintenance contract. Any warranty is conditioned on written notice to the Elevator Contractor within warranty period and contingent upon receipt of final payment to Elevator Contractor.
Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Quality Specifications SANMINA-SCI shall comply with the quality specifications set forth in its Quality Manual, incorporated by reference herein, a copy of which is available from SANMINA-SCI upon request.
Manufacturer Warranties Prior to the transfer to the Interconnected Transmission Owner of title to the Transmission Owner Interconnection Facilities built by the Interconnection Customer, the Interconnection Customer shall produce documentation satisfactory to the Interconnected Transmission Owner evidencing the transfer to the Interconnected Transmission Owner of all manufacturer warranties for equipment and/or materials purchased by the Interconnection Customer for use and/or installation as part of the Transmission Owner Interconnection Facilities built by the Interconnection Customer.
Supplier Warranties The warranties made by Supplier with respect to each Product are solely those that are contained in the product insert accompanying such Product. No other affirmation of fact or promise made by Distributor or its Suppliers, whether or not in this Agreement, by words or action shall constitute a warranty. The foregoing warranty does not extend to any Product that is modified or altered, or treated with abuse, negligence or other improper treatment. Standard Limited Warranty. Distributor shall pass on to Subdistributor so that it may pass on to the customers the Supplier’s standard limited warranty for Products, including limitations set for in subsection (b) Limitation of Liability and Warranty below. Except for the stated warranty set forth on, or included with, the Products as delivered to the Subdistributor and /or its customers, the warranty and remedy set forth in this 0 are exclusive and all other warranties, guarantees or representations, express or implied, by Distributor’s Suppliers with respect to the applicable Products, including, without limitation, warranties of merchantability and fitness for particular purpose, and any other obligation or liability of Distributor and its Suppliers to Subdistributor or to any third party with respect to the Products, are hereby excluded. This warranty is contingent upon proper use of a Product in the application for which such Product was intended and does not cover Products that were modified without Distributor or its Supplier’s prior written approval, that have expired or that were subjected to physical, chemical or electrical stress that the products were not originally designed for.
Quality- and Cost-Based Selection Except as ADB may otherwise agree, the Borrower shall apply quality- and cost-based selection for selecting and engaging consulting services.
