Transfer of the Property Any sale, lease, conveyance, assignment, pledge, encumbrance, or transfer of all or any part of the Property or any interest therein, voluntarily or involuntarily, whether by operation of law or otherwise, except: (i) sales or transfers of items of the Accessories which have become obsolete or worn beyond practical use and which have been replaced by adequate substitutes, owned by Mortgagor, having a value equal to or greater than the replaced items when new; and (ii) the grant, in the ordinary course of business, of a leasehold interest in a part of the Improvements to a tenant for occupancy, not containing a right or option to purchase and not in contravention of any provision of this Mortgage or of any other Loan Document. Mortgagee may, in its sole discretion, waive a default under this paragraph, but it shall have no obligation to do so, and any waiver may be conditioned upon such one or more of the following (if any) which Mortgagee may require: the grantee’s integrity, reputation, character, creditworthiness and management ability being satisfactory to Mortgagee in its sole judgment and grantee executing, prior to such sale or transfer, a written assumption agreement containing such terms as Mortgagee may require, a principal paydown on the Note, an increase in the rate of interest payable under the Note, a transfer fee, a modification of the term of the Note, and any other modification of the Loan Documents which Mortgagee may require. NOTICE - THE DEBT SECURED HEREBY IS SUBJECT TO CALL IN FULL IN THE EVENT OF SALE OR CONVEYANCE OF THE PROPERTY CONVEYED.
Condition of the Property THE LESSEE ACKNOWLEDGES AND AGREES THAT IT IS LEASING THE PROPERTY "AS IS" WITHOUT REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) BY THE LESSOR AND SUBJECT TO (A) THE EXISTING STATE OF TITLE, (B) THE RIGHTS OF ANY PARTIES IN POSSESSION THEREOF, (C) ANY STATE OF FACTS WHICH AN ACCURATE SURVEY OR PHYSICAL INSPECTION MIGHT SHOW, AND (D) VIOLATIONS OF REQUIREMENTS OF LAW WHICH MAY EXIST ON THE DATE HEREOF OR ON THE ACQUISITION DATE. THE LESSOR HAS NOT MADE AND SHALL NOT BE DEEMED TO HAVE MADE ANY REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) AND SHALL NOT BE DEEMED TO HAVE ANY LIABILITY WHATSOEVER AS TO THE TITLE (OTHER THAN FOR LESSOR LIENS), VALUE, HABITABILITY, USE, CONDITION, DESIGN, OPERATION, OR FITNESS FOR USE OF THE PROPERTY (OR ANY PART THEREOF), OR ANY OTHER REPRESENTATION, WARRANTY OR COVENANT WHATSOEVER, EXPRESS OR IMPLIED, WITH RESPECT TO THE PROPERTY (OR ANY PART THEREOF) AND THE LESSOR SHALL NOT BE LIABLE FOR ANY LATENT, HIDDEN, OR PATENT DEFECT THEREIN (OTHER THAN FOR LESSOR LIENS) OR THE FAILURE OF THE PROPERTY, OR ANY PART THEREOF, TO COMPLY WITH ANY REQUIREMENT OF LAW.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Condition of the Business (a) Notwithstanding anything contained in this Agreement to the contrary, Purchaser acknowledges and agrees that Seller is not making any representations or warranties whatsoever, express or implied, beyond those expressly given by Seller in Article V hereof (as modified by the Seller Schedules as supplemented or amended), and Purchaser acknowledges and agrees that, except for the representations and warranties contained therein, the Purchased Assets and the Business are being transferred on a “where is” and, as to condition, “as is” basis. Any claims Purchaser may have for breach of representation or warranty shall be based solely on the representations and warranties of Seller set forth in Article V hereof (as modified by the Seller Schedules as supplemented or amended). Purchaser further represents that neither Seller nor any of its Affiliates nor any other Person has made any representation or warranty, express or implied, regarding Seller, the Purchased Assets, the Business or the transactions contemplated by this Agreement or as to the accuracy or completeness of any information not expressly set forth in this Agreement and neither Purchaser nor any of its Affiliates has relied on any such express or implied representation or warranty. Purchaser further agrees that none of Seller, any of its Affiliates or any other Person will have or be subject to any liability to Purchaser or any other Person resulting from the distribution to Purchaser or its representatives or Purchaser’s use of, any such information, including any confidential memoranda distributed on behalf of Seller relating to the Business or other publications or data room information provided to Purchaser or its representatives, or any other document or information in any form provided to Purchaser or its representatives in connection with the sale of the Business and the transactions contemplated hereby. Purchaser acknowledges that it has conducted to its satisfaction, its own independent investigation of the Business and, in making the determination to proceed with the transactions contemplated by this Agreement, Purchaser has relied on the results of its own independent investigation.
Sale and Purchase of the Assets 1.1 Acquired Assets Subject to the terms and conditions of this Agreement, Seller agrees to sell, convey and deliver to Xxxxx and Xxxxx agrees to purchase and acquire from Seller the assets set forth below (the “Assets”) owned by Seller as of 7:00 a.m., Central Daylight Time, on the Closing Date set forth below: (a) All of Seller’s right, title and interest in all oil and gas leases, including but not limited to those described in Exhibit A-1 attached hereto (the “Leases”), covering the land and depths described in Exhibit A-1 (the “Land”), together with all the property and rights incident thereto, including without limitation Seller’s rights in, to and under all operating agreements, pooling, communitization and unitization agreements, farmout agreements, joint venture agreements, product purchase and sale contracts, transportation, processing, treatment or gathering agreements, leases, permits, rights-of-way, surface interests easements, licenses, options, declarations, orders, contracts, and instruments in any way relating to Seller’s interest in and in the vicinity of the Leases and Land; (b) All of Seller’s right, title and interest in and to the xxxxx situated on the Leases and Land or otherwise pooled, communitized or unitized therewith, including without limitation the xxxxx described in Exhibit A-1 attached hereto (all such xxxxx, the “Xxxxx”); (c) All of Seller’s overriding royalty interests, net profits interests, operating interests, reversionary interests and other interests or benefits or credits owned by Seller in and to the Land, the Leases or attributable to production therefrom; (d) All of the oil and gas and associated hydrocarbons (“Oil and Gas”) in and under or otherwise attributable to the Leases, Land or produced from the Xxxxx (subject to Buyer’s obligation to pay for marketable Oil and Gas in storage on the Leases as of the Closing Date as provided in Section 2.1); (e) All of Seller’s interests in and to all of the assets described in Exhibit A-2 (collectively, the “Equipment”), including, without limitation, producing and non-producing xxxxx, injection xxxxx, disposal xxxxx, well equipment, casing, tubing, tanks, generators, boilers, buildings, pumps, motors, machinery, pipelines, gathering systems, power lines, telephone and telegraph lines, field processing plants, field offices and other furnishings related thereto, equipment leases, trailers, inventory in storage, storage yards, and all other improvements or appurtenances thereunto belonging; and (f) All of the files, records, and data of Seller relating to the items described in subsections (A), (B), (C), (D), and (E) above (the “Records”), including, without limitation, lease records, well records, and division order records; well files; title records (including title opinions and title curative documents); contracts and contract files; correspondence; computer software and data files; geological, geophysical and seismic records, interpretations, data, maps and information; production records, electric logs, core data, pressure data, decline curves and graphical production curves; reserve reports; and accounting records, but excluding files and information relating to internal or external valuations of the Assets and privileged information.
Purchase and Sale of the Assets Except for the Excluded Assets set forth in Section 2.2 below, at and as of the Effective Time, the Sellers shall Transfer to the Purchaser, and the Purchaser shall purchase and accept from the Sellers, free and clear of all Liens to the maximum extent provided in the Sale Approval Order, all of the Sellers’ right, title and interest in and to the following assets (the “Transferred Assets”): (a) the Accounts Receivable, a recent summary schedule of which is attached hereto as Schedule 2.1(a) (it being understood that such schedule does not reflect Accounts Receivable as of the Closing Date that will be included in the Transferred Assets); (b) the Equipment and Other Personalty whether located at the Transferred Facilities of the Sellers or elsewhere; (c) the Intellectual Property primarily used in the Business, including, without limitation, the patented or registered Intellectual Property set forth on Schedule 2.1(c) and pending patent applications or other applications for the registration of Intellectual Property; (d) all Inventory, a recent summary schedule of which is attached hereto as Schedule 2.1(d) (it being understood that such schedule does not reflect Inventory as of the Closing Date that will be included in the Transferred Assets); (e) all rights of the Sellers under Assigned Contracts; (f) originals or copies of all books, financial and other records and information which has been reduced to written, recorded or encoded form, in each case to the extent related to the Business (collectively, the “Books and Records”); (g) licenses and permits primarily used in the operation of the Business, to the extent transferable; (h) subject to the Purchaser’s right to reject any lease of Real Property in accordance with the terms of this Agreement, owned and leased Real Property primarily used in the operation of the Business, each parcel of which is set forth on Schedule 2.1(h); (i) any warranties of third parties on any Transferred Assets; (j) all prepaid expenses, security deposits and other credits owed to the Sellers from third parties, to the extent primarily related to the Transferred Assets; (k) all rights and incidents under policies, contracts or arrangements related to insurance of any Seller to the extent related to Assumed Liabilities or Transferred Assets and to the extent transferable (it being understood that (i) such policies will be cancelled at Closing and the Sellers will be entitled to any refunds upon such cancellation and (ii) the Sellers’ directors and officers insurance policies will constitute Excluded Assets in all respects); (l) all rights and claims of the Sellers of every kind and description under all non-disclosure, confidentiality, non-competition, non-solicitation, assignment of invention and other agreements of a comparable nature with (i) all present and former employees of the Sellers other than Eligible Employees who are hired by the Purchaser to the extent such agreements relate to the Transferred Assets and (ii) all Eligible Employees who are hired by the Purchaser whether or not such agreements relate to the Transferred Assets; and (m) all other assets primarily related to the Business, other than any Excluded Assets.
POSSESSION OF THE APARTMENT PLOT 8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions. 8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex. 8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.
CHARACTERISTICS OF THE ACADEMY The characteristics of the Academy set down in Section 1(6) of the Academies Act 2010, are that:
Operation of the Property Between June 1, 1998 and the Closing Date, Seller shall (a) lease, operate, manage and enter into contracts with respect to the Property, in the same manner done by Seller prior to the date hereof (provided, however, that without the prior consent of Purchaser, which as to (i) and (ii) shall not be unreasonably delayed, conditioned or withheld, (i) Seller shall not enter into any Service Contract that cannot be terminated with thirty (30) days notice or materially modify any existing Service Contracts to be assumed by Purchaser at Closing, and (ii) after June 1, 1998, Seller shall not materially modify or terminate any existing Tenant Lease or grant any material consents under any existing Tenant Lease (except as otherwise required pursuant to the terms and conditions of such Tenant Lease), or enter into any new Tenant Lease, and (iii) Seller shall not apply any then unapplied Deposits (as reflected on the Rent Roll delivered by Seller to Purchaser pursuant to Schedule 5.3(vii) hereof) under Tenant Leases); and (b) advise Purchaser of the commencement of any litigation, condemnation or other judicial or administrative proceedings affecting the Property of which Seller has current actual knowledge. Notwithstanding anything to the contrary set forth in this Contract, Purchaser acknowledges that after June 1, 1998 and prior to Closing, Seller will enter into contracts for the completion of Tenant improvements under Tenant Leases entered into after June 1, 1998 pursuant to the terms of Section 12.1 hereof (collectively, the "Tenant Finish Contracts"). Purchaser and Seller agree that at Closing, Purchaser shall assume the obligations of Seller under all such Tenant Finish Contracts including, without limitation, the obligations to pay any costs and expenses charged with respect to construction of improvements in the space subject to such Tenant Leases. At Closing, Purchaser shall execute and deliver to the Seller an Assignment, Assumption and Indemnity Agreement in the form attached hereto as Exhibit H and made a part hereof for all purposes.
RISK OF THE PROPERTY As from the time of the sale, the Property shall be at the sole risk of the Purchaser as regards to loss or damage of whatsoever nature or howsoever occurring including by fire or other accidents, state of cultivation, non-occupation or otherwise.