Release of Performance Security (i) The Authority shall return the Performance Security to the Contractor within 60 (sixty) days of the expiry of the Maintenance Period or the Defects Liability Period, whichever is later, under this Agreement. Notwithstanding the aforesaid, the Parties agree that the Authority shall not be obliged to release the Performance Security until all Defects identified during the Defects Liability Period have been rectified.
(ii) The Authority shall return the Additional Performance Security to the Contractor within 28 (twenty eight) days from the date of issue of Completion Certificate under Article 12 of this Agreement.
(iii) The Authority shall be liable to pay interest @ 9% (nine per cent) per annum for any delay in the return of Performance Security and Additional Performance Security, if any, beyond the period prescribed above for the period of delay.
Appropriation of Performance Security (i) Upon occurrence of a Contractor’s Default, the Authority shall, without prejudice to its other rights and remedies hereunder or in law, be entitled to encash and appropriate the relevant amounts from the Performance Security as Damages for such Contractor’s Default.
(ii) Upon such encashment and appropriation from the Performance Security, the Contractor shall, within 30 (thirty) days thereof, replenish, in case of partial appropriation, to its original level the Performance Security, and in case of appropriation of the entire Performance Security provide a fresh Performance Security, as the case may be, and the Contractor shall, within the time so granted, replenish or furnish fresh Performance Security as aforesaid failing which the Authority shall be entitled to terminate the Agreement in accordance with Article 23. Upon replenishment or furnishing of a fresh Performance Security, as the case may be, as aforesaid, the Contractor shall be entitled to an additional Cure Period of 30 (thirty) days for remedying the Contractor’s Default, and in the event of the Contractor not curing its default within such Cure Period, the Authority shall be entitled to encash and appropriate such Performance Security as Damages, and to terminate this Agreement in accordance with Article 23.
Time of Performance Time for performance of the Scope of Services under this Agreement shall begin with receipt of the Notice to Proceed and end no later than December 31, 2026. Consultant shall complete the tasks described in the Scope of Services, within this time or within such additional time as may be extended by the County.
Suspension of Performance or Disbursement Into Court If, at any time, (i) there shall exist any dispute between Broker, Issuer, NCPS, any Subscriber or any other person with respect to the holding or disposition of all or any portion of the Escrow Funds or any other obligations of NCPS hereunder, or (ii) if at any time NCPS is unable to determine, to NCPS’s reasonable satisfaction, the proper disposition of all or any portion of the Escrow Funds or NCPS’s proper actions with respect to its obligations hereunder, or (iii) if Broker and Issuer have not within 30 days of the furnishing by NCPS of a notice of resignation pursuant to Section 7 hereof appointed a successor NCPS to act hereunder, then NCPS may, in its reasonable discretion, take either or both of the following actions:
a. suspend the performance of any of its obligations (including without limitation any disbursement obligations) under this Escrow Agreement until such dispute or uncertainty shall be resolved to the sole satisfaction of NCPS or until a successor NCPS shall have been appointed (as the case may be).
b. petition (by means of an interpleader action or any other appropriate method) any court of competent jurisdiction in any venue convenient to NCPS, for instructions with respect to such dispute or uncertainty, and to the extent required or permitted by law, pay into such court all funds held by it in the Escrow Funds for holding and disposition in accordance with the instructions of such court. NCPS shall have no liability to Broker, Issuer, any Subscriber or any other person with respect to any such suspension of performance or disbursement into court, specifically including any liability or claimed liability that may arise, or be alleged to have arisen, out of or as a result of any delay in the disbursement of the Escrow Funds or any delay in or with respect to any other action required or requested of NCPS.
Suspension of Performance Disbursement Into Court If at any time, there shall exist any dispute between the Company and the Investor(s) with respect to holding or disposition of any portion of the Escrow Funds or any other obligations of Escrow Agent hereunder, or if at any time Escrow Agent is unable to determine, to Escrow Agent's sole satisfaction, the proper disposition of any portion of the Escrow Funds or Escrow Agent's proper actions with respect to its obligations hereunder, or if the parties have not within thirty (30) days of the furnishing by Escrow Agent of a notice of resignation pursuant to Section 9 hereof, appointed a successor Escrow Agent to act hereunder, then Escrow Agent may, in its sole discretion, take either or both of the following actions:
a. suspend the performance of any of its obligations (including without limitation any disbursement obligations) under this Escrow Agreement until such dispute or uncertainty shall be resolved to the sole satisfaction of Escrow Agent or until a successor Escrow Agent shall be appointed (as the case may be); provided however, Escrow Agent shall continue to invest the Escrow Funds in accordance with Section 8 hereof; and/or
b. petition (by means of an interpleader action or any other appropriate method) any court of competent jurisdiction in any venue convenient to Escrow Agent, for instructions with respect to such dispute or uncertainty, and to the extent required by law, pay into such court, for holding and disposition in accordance with the instructions of such court, all funds held by it in the Escrow Funds, after deduction and payment to Escrow Agent of all fees and expenses (including court costs and attorneys' fees) payable to, incurred by, or expected to be incurred by Escrow Agent in connection with performance of its duties and the exercise of its rights hereunder.
c. Escrow Agent shall have no liability to the Company, the Investor(s), or any person with respect to any such suspension of performance or disbursement into court, specifically including any liability or claimed liability that may arise, or be alleged to have arisen, out of or as a result of any delay in the disbursement of funds held in the Escrow Funds or any delay in with respect to any other action required or requested of Escrow Agent.
Monitoring of Performance Vendor shall continuously monitor and record its performance to ensure that all of Vendor's responsibilities and obligations hereunder are being met and fulfilled. Citizens may conduct programmatic and other administrative contract monitoring during the term of this Agreement. The purpose of this monitoring is to ensure that all of Vendor's responsibilities and obligations are being met and fulfilled. Such monitoring may include on-site visits, report reviews, invoice reviews, compliance reviews, and a review of any other areas reasonably necessary. Vendor acknowledges and agrees that Citizens may also monitor and record Vendor Staff communications to the extent they occur within or are connected to any Citizens’ resource, such as electronic or telecommunications systems.
Schedule of Performance Consultant shall commence the services pursuant to this Agreement upon receipt of a written notice to proceed and shall perform all services within the time period(s) established in the “Schedule of Performance” attached hereto as Exhibit “D” and incorporated herein by this reference. When requested by the Consultant, extensions to the time period(s) specified in the Schedule of Performance may be approved in writing by the Contract Officer but not exceeding one hundred eighty (180) days cumulatively.
Suspension of Performance Notwithstanding any other provision hereof, if an Event of Default or a Potential Event of Default has occurred and is continuing, the Non-Defaulting Party, upon written notice to the Defaulting Party, has the right (i) to suspend performance under any or all Transactions and (ii) to the extent an Event of Default has occurred and is continuing, to exercise any remedy available at law or in equity, except as limited be Section 5.7.
Excuse of Performance Seller shall not be liable for delays in performance or for non-performance due to failure or interruption of computer or telecommunication systems, acts of God, war, riot, fire, terrorism, labor trouble, unavailability of materials or components, explosion, accident, compliance with governmental requests, laws, regulations, orders or actions, or other unforeseen circumstances or causes beyond Seller's reasonable control. In the event of such delay, the time for performance or delivery shall be extended by a period of time reasonably necessary to overcome the effect of the delay.
Guaranty of Performance Each Guarantor also guarantees the full, prompt and unconditional performance of all obligations and agreements of every kind owed or hereafter to be owed by the Companies and the Guarantors to Purchasers and Agent under the Purchase Agreement, the Notes, and the other Transaction Documents. Every provision for the benefit of Purchasers and Agent contained in this Guaranty shall apply to the guaranty of performance given in this paragraph.
