Indemnification and Defense 16.1 To the fullest extent permitted by California law, Developer shall indemnify, keep and hold harmless the District, the Architect(s) and Construction Manager(s), their respective consultants, separate contractors, board members, officers, representatives, agents, and employees, in both individual and official capacities (“Indemnitees”), against all suits, claims, injury, damages, losses, and expenses (“Claims”), including but not limited to attorney’s fees and costs, caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Contract by Developer or its Subcontractors, vendors and/or suppliers. However, Developer’s indemnification and hold harmless obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent the Claim(s) is/are caused wholly by the active negligence or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. This indemnification and hold harmless obligation of Developer shall not be construed to negate, abridge, or otherwise reduce any right or obligation of indemnity that would otherwise exist or arise as to any Indemnitee or other person described herein. This indemnification and hold harmless obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any law and/or provision of the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developers obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR.
Defense and Indemnification a. The Contractor hereby agrees to defend, indemnify, reimburse and hold harmless the City, its appointed and elected officials, agents and employees for, from and against all liabilities, claims, judgments, suits or demands for damages to persons or property arising out of, resulting from, or relating to the work performed under this Agreement (“Claims”), unless such Claims have been specifically determined by the trier of fact to be the sole negligence or willful misconduct of the City. This indemnity shall be interpreted in the broadest possible manner to indemnify the City for any acts or omissions of the Contractor or its subcontractors either passive or active, irrespective of fault, including the City’s concurrent negligence whether active or passive, except for the sole negligence or willful misconduct of the City.
Indemnification and General Liability Section 10.4 Required Post-Expiration Coverage.
Exculpation and Indemnification (a) No Protected Person shall be liable to the Company or any Manager or any other Member for any action taken or omitted to be taken by it or by other Person with respect to the Company, including any negligent act or failure to act, except in the case of a liability resulting from such Protected Person’s own actual fraud, gross negligence, willful misconduct, bad faith, breach of fiduciary duty, reckless disregard of duty or any intentional and material breach of this Agreement or conduct that is subject of a criminal proceeding (where such Protected Person has reasonable cause to believe that such conduct was unlawful). With the prior consent of the Board, any Protected Person may consult with legal counsel and accountants with respect to Company affairs (including interpretations of this Agreement) and shall be fully protected and justified in any action or inaction which is taken or omitted in good faith, in reliance upon and in accordance with the opinion or advice of such counsel or accountants. In determining whether a Protected Person acted with the requisite degree of care, such Protected Person shall be entitled to rely on written or oral reports, opinions, certificates and other statements of the directors, officers, employees, consultants, attorneys, accountants and professional advisors of the Company selected with reasonable care; provided that no such Protected Person may rely upon such statements if it believed that such statements were materially false.
INDEMNIFICATION AND RECOVERY H-GAC’s liability under this Agreement, whether for breach of contract, warranty, negligence, strict liability, in tort or otherwise, is limited to its order processing charge. In no event will H-GAC be liable for any loss of use, loss of time, inconvenience, commercial loss, lost profits or savings or other incidental, special or consequential damages to the full extent such use may be disclaimed by law. Contractor agrees, to the extent permitted by law, to defend and hold harmless H-GAC, its board members, officers, agents, officials, employees and indemnities from any and all claims, costs, expenses (including reasonable attorney fees), actions, causes of action, judgements, and liens arising as a result of Contractor’s negligent act or omission under this Agreement. Contractor shall notifiy H-GAC of the threat of lawsuit or of any actual suit filed against Contractor relating to this Agreement.
Indemnification and Limitation of Liability (a) To the fullest extent that limitations on the liability of Trustees and officers are permitted by the DSTA, the officers and Trustees shall not be responsible or liable in any event for any act or omission of: any agent or employee of the Trust; any Investment Adviser or Principal Underwriter of the Trust; or with respect to each Trustee and officer, the act or omission of any other Trustee or officer, respectively. The Trust, out of the Trust Property, shall indemnify and hold harmless each and every officer and Trustee from and against any and all claims and demands whatsoever arising out of or related to such officer’s or Trustee’s performance of his or her duties as an officer or Trustee of the Trust. This limitation on liability applies to events occurring at the time a Person serves as a Trustee or officer of the Trust whether or not such Person is a Trustee or officer at the time of any proceeding in which liability is asserted. Nothing herein contained shall indemnify, hold harmless or protect any officer or Trustee from or against any liability to the Trust or any Shareholder to which such Person would otherwise be subject by reason of willful misfeasance, bad faith, gross negligence or reckless disregard of the duties involved in the conduct of such Person’s office.
Indemnification and Liability A. Neither the Contractor, OSC, nor the State shall be liable for any delay or failure in performance beyond its control resulting from acts of war, hostility or sabotage; act of God; electrical, internet or telecommunications outage that is not caused by the obligated party; or government restrictions, or other force majeure. The parties shall use reasonable efforts to eliminate or minimize the effect of such force majeure events upon performance of their respective duties under this Agreement. If such event continues for more than 90 days, either party may terminate all or any agreed upon portion of the Agreement immediately upon written notice. This section does not excuse either party’s obligation to take reasonable steps to follow its normal disaster recovery procedures, or OSC’s obligation to pay for Services provided by the Contractor which have been approved by OSC.
Limitations on Indemnification No payments pursuant to this Agreement shall be made by the Company:
Indemnification of City The Permittee shall indemnify, defend, save and hold harmless the City and its officers and employees, from and against all suits or claims that may be based upon any damage or injury or death, to any person or property that may occur, or that may be alleged to have occurred, in the course of the use of the Premises by the Permittee, and also whether such claims be made by an owner, officer, principal, employee, or a contractor or its employees, of the Permittee, or by any third party, also including Event and Festival licensees and vendors, their owners, principals, employees, and their contractors and contractor’s employees, and by members of the public, and whether or not it shall be claimed that the damage or injury or death was caused through the negligent act or omission in whole or in part of the City and/or its officers and/or employees. The Permittee shall indemnify, defend, save and hold harmless the City and its officers and employees, from and against all suits or claims that may be based upon any liability of the City, including such that may arise under U.S. Copyright Laws, to all music licensing agencies (including but not limited to SESAC, BMI and ASCAP) and any other third parties resulting from or accruing from Permittee’s unlicensed authorization, sponsoring or presenting recorded or live music on City property or in City buildings or facilities. The Permittee shall, at the Permittee’s own expense, pay all charges of attorneys, and all costs and other expenses arising therefrom or incurred in connection therewith, and if any judgment shall be rendered against the City and/or its officers and/or its employees in any such action, or actions, the Permittee, at the Permittee’s own expense, shall satisfy and discharge the same. The preceding shall not apply to require indemnification by Permittee for any liability, claims, suits, etc., arising from action by officers of the Bethlehem Police Department.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree (Yes) Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes Does Vendor agree? Yes, Vendor agrees (Yes) No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees (Yes)
