Intellectual Property Infringement Indemnification 1.1 We will defend you against any third party claim(s) that the Tyler Software or Documentation infringes that third party’s patent, copyright, or trademark, or misappropriates its trade secrets, and will pay the amount of any resulting adverse final judgment (or settlement to which we consent). You must notify us promptly in writing of the claim and give us sole control over its defense or settlement. You agree to provide us with reasonable assistance, cooperation, and information in defending the claim at our expense.
1.2 Our obligations under this Section G(1) will not apply to the extent the claim or adverse final judgment is based on your use of the Tyler Software in contradiction of this Agreement, including with non-licensed third parties, or your willful infringement.
1.3 If we receive information concerning an infringement or misappropriation claim related to the Tyler Software, we may, at our expense and without obligation to do so, either: (a) procure for you the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent, in which case you will stop running the allegedly infringing Tyler Software immediately. Alternatively, we may decide to litigate the claim to judgment, in which case you may continue to use the Tyler Software consistent with the terms of this Agreement.
1.4 If an infringement or misappropriation claim is fully litigated and your use of the Tyler Software is enjoined by a court of competent jurisdiction, in addition to paying any adverse final judgment (or settlement to which we consent), we will, at our option, either: (a) procure the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent. This section provides your exclusive remedy for third party copyright, patent, or trademark infringement and trade secret misappropriation claims.
Third Party Infringement Claims In the event any claim or action for infringement of any patent, trademark, or other intellectual property right shall be made or brought by a third party against Seller, Purchaser or any of their respective Affiliates because of, or in anticipation of, the manufacture and supply of Product by Seller to Purchaser hereunder, or the marketing, sale or distribution of such Product to Purchaser Customers in the Territory by Purchaser hereunder (a “Third Party Infringement Claim”), the party first receiving such notice of the Third Party Infringement Claim shall promptly notify the other party. With respect to the Third Party Infringement Claim, Seller and Purchaser each hereby agrees that all Damages arising from or related to the Third Party Infringement Claim (including any legal fees and associated costs incurred in defending the Third Party Infringement Claim and any fees, royalties or other amounts paid in settlement or upon judgment) shall be shared as follows:
(a) Except as provided in clause (b) below, Seller shall be 100% responsible for all Damages arising from any Third Party Infringement Claim, including any fees, royalties or other amounts agreed to be paid in settlement or upon judgment of the Lawsuit or otherwise; and
(b) Purchaser shall be 100% responsible for all Damages arising from any Third Party Infringement Claim with respect to the use of Purchaser Trademarks. Each party agrees to indemnify the other party to ensure that Damages arising from any Third Party Infringement Claim are allocated in accordance with clauses (a) and (b) above. Unless otherwise agreed to by the parties, Seller shall control the defense any Third Party Infringement Claim described in clause (a) above and Purchaser shall control the defense of any Third Party Infringement Claim described in clause (b) above. The party controlling the defense of any Third Party Infringement Claim shall have the sole right to defend or settle any such Third Party Infringement Claim; provided, however, that such settlement does not impose any obligation or burden on the other party without the prior written consent of the other party (which consent shall not be unreasonably withheld). The party controlling the defense of any Third Party Infringement Claim shall keep the other party, at its request, materially informed of the status and progress of the defense of the Third Party Infringement Claim. No Third Party Infringement Claim shall be settled by the party who is not controlling the defense of such Third Party Infringement Claim without the prior written consent of the party controlling such defense. The non-controlling party, its employees, agents and Affiliates shall reasonably cooperate with the party (and its legal representatives) controlling the defense of any Third Party Infringement Claim in the investigation and defense of such Third Party Infringement Claim. Notwithstanding the above, and by way of clarification, neither party shall be obligated to indemnify the other party hereunder for modification or misuse of the Product by the other party or by wholesalers or the customers of either party. The provisions of this Section 17.4 shall be notwithstanding any conflicting provisions set forth in this Agreement, including Sections 17.1, 17.2 and 17.3.
Infringement Indemnification If notified promptly in writing of any judicial action brought against City based on an allegation that City’s use of the Licensed Software infringes a patent, copyright, or any right of a third party or constitutes misuse or misappropriation of a trade secret or any other right in intellectual property (Infringement), Contractor will hold City harmless and defend such action at its own expense. Contractor will pay the costs and damages awarded in any such action or the cost of settling such action, provided that Contractor shall have sole control of the defense of any such action and all negotiations or its settlement or compromise. If notified promptly in writing of any informal claim (other than a judicial action) brought against City based on an allegation that City’s use of the Licensed Software constitutes Infringement, Contractor will pay the costs associated with resolving such claim and will pay the settlement amount (if any), provided that Contractor shall have sole control of the resolution of any such claim and all negotiations for its settlement. In the event a final injunction is obtained against City’s use of the Licensed Software by reason of Infringement, or in Contractor’s opinion City’s use of the Licensed Software is likely to become the subject of Infringement, Contractor may at its option and expense: (a) procure for City the right to continue to use the Licensed Software as contemplated hereunder, (b) replace the Licensed Software with a non-infringing, functionally equivalent substitute Licensed Software, or (c) suitably modify the Licensed Software to make its use hereunder non-infringing while retaining functional equivalency to the unmodified version of the Licensed Software. If none of these options is reasonably available to Contractor, then the Agreement may be terminated at the option of either Party hereto and Contractor shall refund to City all amounts paid under this Agreement for the license of such infringing Licensed Software. Any unauthorized modification or attempted modification of the Licensed Software by City or any failure by City to implement any improvements or updates to the Licensed Software, as supplied by Contractor, shall void this indemnity unless City has obtained prior written authorization from Contractor permitting such modification, attempted modification or failure to implement. Contractor shall have no liability for any claim of Infringement based on City’s use or combination of the Licensed Software with products or data of the type for which the Licensed Software was neither designed nor intended to be used.
Indemnification; Third Party Claims The Master Servicer agrees to indemnify the Depositor, the Sponsor and the Trustee, and their respective officers, directors, agents and affiliates, and hold each of them harmless against any and all claims, losses, penalties, fines, forfeitures, reasonable legal fees and related costs, judgments, and any other costs, liability, fees and expenses that the Depositor, the Sponsor or the Trustee may sustain as a result of (a) any material breach by the Master Servicer of any if its obligations hereunder, including particularly its obligations to provide any reports under Section 9.25(a), Section 9.25(b), Section 9.26 or any information, data or materials required to be included in any Exchange Act report, (b) any material misstatement or omission in any information, data or materials provided by the Master Servicer, or (c) the negligence, bad faith or willful misconduct of the Master Servicer in connection with its performance hereunder, provided, however, that in no event shall the Master Servicer be liable for any special, consequential, indirect or punitive damages pursuant to this Section 9.31, even if advised of the possibility of such damages. The Depositor, the Sponsor and the Trustee shall immediately notify the Master Servicer if a claim is made by a third party with respect to this Agreement or the Mortgage Loans entitling the Depositor, the Sponsor or the Trustee to indemnification hereunder, whereupon the Master Servicer shall assume the defense of any such claim and pay all expenses in connection therewith, including counsel fees, and promptly pay, discharge and satisfy any judgment or decree which may be entered against it or them in respect of such claim. Notwithstanding anything to the contrary contained herein, the Master Servicer shall not settle any claim involving any of the other parties hereto without such party’s prior written consent unless such settlement involves a complete and absolute release of such party from any and all liability in connection with such claim. This indemnification shall survive the termination of this Agreement or the termination of the Master Servicer as a party to this Agreement.
Indemnification Claims An Indemnified Party shall give written notification to the Indemnifying Party of the commencement of any Third Party Action. Such notification shall be given within 20 days after receipt by the Indemnified Party of notice of such Third Party Action, and shall describe in reasonable detail (to the extent known by the Indemnified Party) the facts constituting the basis for such Third Party Action and the amount of the claimed damages; provided, however, that no delay or failure on the part of the Indemnified Party in so notifying the Indemnifying Party shall relieve the Indemnifying Party of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Party may, upon written notice thereof to the Indemnified Party, assume control of the defense of such Third Party Action with counsel reasonably satisfactory to the Indemnified Party; provided that the Indemnifying Party may not assume control of the defense of Third Party Action involving criminal liability or in which equitable relief is sought against the Indemnified Party. If the Indemnifying Party does not, or is not permitted under the terms hereof to, so assume control of the defense of a Third Party Action, the Indemnified Party shall control such defense. The Non-controlling Party may participate in such defense at its own expense. The Controlling Party shall keep the Non-controlling Party advised of the status of such Third Party Action and the defense thereof and shall consider in good faith recommendations made by the Non-controlling Party with respect thereto. The Non-controlling Party shall promptly furnish the Controlling Party with such information as it may have or receive with respect to such Third Party Action (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party in the defense of such Third Party Action. The fees and expenses of counsel to the Indemnified Party with respect to a Third Party Action shall be considered Damages for purposes of this Agreement if (x) the Indemnified Party controls the defense of such Third Party Action pursuant to the terms of this Section 5.3 or (y) the Indemnifying Party assumes control of such defense and the Indemnified Party reasonably concludes that the Indemnifying Party and the Indemnified Party have conflicting interests with respect to such Third Party Action. The Indemnifying Party shall not agree to any settlement of, or the entry of any judgment arising from, any Third Party Action without the prior written consent of the Indemnified Party, which shall not be unreasonably withheld, conditioned or delayed. The Indemnified Party shall not agree to any settlement of, or the entry of any judgment arising from, any such Third Party Action without the prior written consent of the Indemnifying Party, which shall not be unreasonably withheld, conditioned or delayed.
PATENT INDEMNIFICATION The Contractor agrees to assume the defense of and shall indemnify and save harmless the Owner and all persons acting for or on behalf of it from all suits and claims against them, or any of them, arising from or occasioned by the use of any material, Equipment or apparatus, or any part thereof which infringes or is alleged to infringe on any patent rights. In case such material, equipment or apparatus, or any part thereof, in any such suit is held to constitute infringement, the Contractor, within a reasonable time, shall at its own expense, and as the Owner may elect, replace such material, Equipment or apparatus with non-infringing material, Equipment or apparatus, or remove the material, equipment, or apparatus and refund the sums paid therefor.
Indemnification for Third Party Claims
(a) Seller shall defend, indemnify and hold harmless Buyer, its shareholders and Affiliates, and their respective directors, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance by any Project Party of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Seller, the Contractor, any Subcontractor, and its respective employees or agents.
(b) Buyer shall defend, indemnify and hold harmless Seller and its managers, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Buyer, its employees or agents.
(c) Either Party seeking indemnification under this Agreement (the “Indemnified Party”) shall give notice to the Party required to provide indemnification hereunder (the “Indemnifying Party”) promptly after the Indemnified Party has actual knowledge of any Claim as to which indemnity may be sought hereunder, and the Indemnified Party shall permit the Indemnifying Party (at the expense of the Indemnifying Party) to assume the defense of any Claim or litigation resulting therefrom; provided that:
(i) counsel for the Indemnifying Party who shall conduct the defense of such Claim or litigation shall be reasonably satisfactory to the Indemnified Party;
(ii) the Indemnified Party may participate in such defense at its own expense, except the Indemnifying Party shall reimburse the Indemnified Party for its participation in such defense to the extent that the Indemnifying Party requests the Indemnified Party to participate in its own defense; and
(iii) the omission by the Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligations hereunder except to the extent that such omission results in a failure of actual notice to the Indemnifying Party and Indemnifying Party is damaged as a result of such failure to give notice. Notwithstanding the foregoing, the Indemnifying Party may not settle any Claim related to the indemnity being provided hereunder without the consent of the Indemnified Party, such consent not to be unreasonably withheld.
(d) With regard to any Claim or Liability which is the result of the joint or concurrent fault or negligence of Seller and Buyer, the Parties agree to jointly defend any Claim with respect thereto that is based on such joint or concurrent fault or negligence of Buyer and Seller. Any Claim of contribution or indemnification between Buyer and Seller relating to such Claims shall be resolved on the basis of the percentage of fault or negligence and the Parties agree to reserve the determination of such percentage until after resolution of such Claim. Such pro rata share shall be based upon a final judicial determination of the Parties’ comparative fault or negligence or, in the absence of such determination, by mutual agreement.
(e) Nothing in this Section 26.1 is intended to allow any Indemnified Party to be indemnified from and against any third party Claims and Liabilities caused by, arising out of, or in connection with the performance of this Agreement to the extent any of such Claims or Liabilities were caused by, arose out of, or were in any way incidental to or in connection with its own negligence or intentional misconduct.
Indemnification of Third Party Claims The obligations and liabilities of any party to indemnify any other under this Article 6 with respect to Claims relating to third parties shall be subject to the following terms and conditions:
Infringement Claims You may submit an infringement claim notice to us at our Contact Formavailable here if you have a good faith belief that Your Content has been copied and made accessible through the Services (including as a part of the Service Content or Third Party Content) in violation of your Inte lectual Property Rights. A copyright infringement claims notice must include at (i) the identification of such a legedly infringing materials, including information su ficient for us to locate it within our Services, ( i) a demand that such a legedly infringing materials be removed or access disabled, ( i) a statement that you have a good faith belief that use of the material in the manner complained of is not authorized by the copyright owner, its agent, or the law; (iv) a statement that the information in the notification is accurate, and under penalty of perjury, that you are authorized to act on behalf of the owner of an exclusive right that is a legedly infringed; (v) contact information for you, such as address, phone number, and, if available, an email address; and (vi) must be signed by you or the person authorized to act on behalf of the owner of the a legedly infringed work (the “Notice Requirements”). Pursuant to 17 U.S.C. 512(c)(3), if the above Notice Requirements are not met, we may disregard the notice. Pursuant 17 U.S.C. 512(f), be advised that knowingly making a material misrepresentation that online material or activity is infringing or that material or activity was removed or disabled by mistake or misidentification, may subject you to heavy civil penalties. These penalties include monetary damages, including costs and attorneys' fees, incurred by the a leged infringer, by any copyright owner or copyright owner's authorized licensee, or by a service provider who is injured by your misrepresentation. If we make a decision to remove Your Content in response to a complaint, we may notify you and provide you with contact information for the complaining party. You may also object to such determination by writing to our designated agent, which must contain the fo lowing information pursuant to 17 U.S.C. 512(g)(3), (i) your physical or electronic signature; ( i) identification of the material that has been removed or to which access has been disabled and the location at which the material appeared before it was removed or access to it was disabled; ( i) a statement under penalty of perjury that the you have a good faith belief that the material was removed or disabled as a result of mistake or misidentification of the material to be removed or disabled; and (iv) your name, address, phone number, and a statement that you consent to the jurisdiction of Federal District Court for the judicial district in which the address is located, or if you are located outside of the United States, for any judicial district in which the service provider may be found, and that you wil accept service of process from the person who provided notification under subsection 17 U.S.C. 512(c)(1)(C) or an agent of such person.
Indemnification Against Third-Party Claims Each Party (the Indemnifying Party) agrees to indemnify, defend, and hold harmless the other Party (the Indemnified Party) and the other Party’s Subsidiaries, predecessors, successors, Affiliates, and assigns, and all current and former officers, directors, members, shareholders, agents, contractors and employees of all such persons and entities (collectively, with Indemnified Party, the “Indemnitee Group”), from any and all Claims (as hereinafter defined).
22.1.1 For purposes of this Section 22, Claim means any action, cause of action, suit, proceeding, claim, or demand of any third party (and all resulting judgments, bona fide settlements, penalties, damages, losses, liabilities, costs, and expenses including, but not limited to, reasonable costs and attorneys’ fees),
(a) based on allegations that, if true, would establish
(i) the Indemnifying Party’s breach of this Agreement;
(ii) the Indemnifying Party’s misrepresentation, fraud or other misconduct;
(iii) the Indemnifying Party’s negligent or willful misconduct or omissions;
(iv) infringement by the Indemnifying Party or by any Indemnifying Party product or service of any patent, copyright, trademark, service mark, trade name, right of publicity or privacy, trade secret, or any other proprietary right of any third party;
(v) the Indemnifying Party’s liability in relation to any wrongful disclosure of private or personal matters or material which is defamatory; or
(vi) the Indemnifying Party’s wrongful use or unauthorized disclosure of data; or
(b) that arises out of:
(i) any act or omission of the Indemnifying Party or its subcontractors or agents relating to the Indemnifying Party’s performance or obligations under this Agreement or the Indemnifying Party’s use of any services or facilities obtained from or provided by the other Party under this Agreement;
(ii) any act or omission of the Indemnifying Party’s customer(s) or End User(s) pertaining to the services or facilities provided under this Agreement;
(iii) the bodily injury or death of any person, or the loss or disappearance of or damage to the tangible property of any person, relating to the Indemnifying Party’s performance or obligations under this Agreement;
(iv) the Indemnifying Party’s design, testing, manufacturing, marketing, promotion, advertisement, distribution, lease or sale of services and/or products to its customers, or such customers’ use, possession, or operation of those services and/or products; or
(v) personal injury to or any unemployment compensation claim by one or more of the Indemnifying Party’s employees, notwithstanding any protections the Indemnifying Party might otherwise have under applicable workers’ compensation or unemployment insurance law, which protections the Indemnifying Party waives, as to the Indemnified Party and other persons and entities to be indemnified under this Section (other than applicable employee claimant(s)).
22.1.2 For purposes of this Section, Reasonable costs and attorneys’ fees, as used in this Section, includes without limitation fees and costs incurred to interpret or enforce this Section.
22.1.3 The Indemnified Party will provide the Indemnifying Party with reasonably prompt written notice of any Claim. At the Indemnifying Party’s expense, the Indemnified Party will provide reasonable cooperation to the Indemnifying Party in connection with the defense or settlement of any Claim. The Indemnified Party may, at its expense, employ separate counsel to monitor and participate in the defense of any Claim.
