Intellectual Property Indemnification by Vendor Procedures Related to Indemnification. In the event that an indemnity obligation arises, Vendor shall pay all amounts set forth in Section 13 and 14 above (including any settlements) and – if it has accepted its indemnity obligation without qualification – control the legal defense to such claim or cause of action, including without limitation attorney selection, strategy, discovery, trial, appeal, and settlement, and TIPS shall, at Vendor’s cost and expense (with respect to reasonable out of pocket costs and expenses incurred by TIPS which shall be reimbursed to TIPS by Vendor), provide all commercially reasonable assistance requested by Vendor. In controlling any defense, Vendor shall ensure that all assertions of governmental immunity and all applicable pleas and defenses shall be promptly asserted.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
Intellectual Property Warranty and Indemnification Contractor represents and warrants that any materials or deliverables, including all Deliverable Materials, provided under this Contract are either original, or not encumbered, and do not infringe upon the copyright, trademark, patent or other intellectual property rights of any third party, or are in the public domain. If Deliverable Materials provided hereunder become the subject of a claim, suit or allegation of copyright, trademark or patent infringement, City shall have the right, in its sole discretion, to require Contractor to produce, at Contractor’s own expense, new non-infringing materials, deliverables or works as a means of remedying any claim of infringement in addition to any other remedy available to the City under law or equity. Contractor further agrees to indemnify, defend, and hold harmless the City, its officers, employees and agents from and against any and all claims, actions, costs, judgments or damages, of any type, alleging or threatening that any Deliverable Materials, supplies, equipment, services or works provided under this contract infringe the copyright, trademark, patent or other intellectual property or proprietary rights of any third party (Third Party Claim of Infringement). If a Third Party Claim of Infringement is threatened or made before Contractor receives payment under this Contract, City shall be entitled, upon written notice to Contractor, to withhold some or all of such payment.
Obligation to Notify Owner of Existing Hazardous Materials The Contractor shall immediately notify the Owner and the Design Professional, both orally and in writing, of the presence and location of any physical evidence of, or information regarding the presence of Hazardous Materials at the Site of which it becomes aware. If the Contractor encounters Hazardous Materials on the Site the Contractor shall (i) immediately stop performance of Work or that portion of the Work affected by or affecting such Hazardous Materials; (ii) secure the contaminated area against intrusion; (iii) not disturb or remove the Hazardous Materials; (iv) not proceed, or allow any subcontractor or supplier to proceed, with any Work or other activities in the area affected by such Hazardous Materials until such materials have been properly remediated and until directed in writing to do so by the Owner; and, (v) take any other steps necessary to protect life and health and the surrounding environment. The Contractor shall be entitled to adjustment of the Contract Time and the Contract Sum pursuant to Section 5, Part 2 of these General Conditions in order to compensate for the impact of any required demolition, re-work, shutdown, delay, protection of work, disruption, and start-up resulting from the encountering of such Hazardous Materials on the Site for which the Contractor is not responsible.
Intellectual Property Indemnification Supplier agrees to defend, indemnify, and hold harmless DXC and its affiliates, subsidiaries, assigns, agents, subcontractors, distributors and customers (collectively “Indemnitees”) from and against all claims, losses, demands, fees, damages, liabilities, costs, expenses, obligations, causes of action, suits, or injuries, of any kind or nature, arising from: (i) any claim that Supplier’s Products or Services, or the use, sale or importation of them, infringes any intellectual property right. Without limiting the foregoing, Supplier will pay all costs, damages and expenses (including reasonable attorneys’ fees) incurred by DXC and/or its Indemnitees and will pay any award with respect to any such claim or agreed to in settlement of that claim.
Licensee Indemnification Licensee will indemnify, defend and hold harmless UM, its trustees, officers, agents and employees (collectively, the “Indemnified Parties”), from and against any and all liability, loss, damage, action, claim or expense suffered or incurred by the Indemnified Parties which results from or arises out of third party claims in connection with (individually, a “Liability” and collectively, the “Liabilities”):
Intellectual Property Infringement Indemnification 1.1 We will defend you against any third party claim(s) that the Tyler Software or Documentation infringes that third party’s patent, copyright, or trademark, or misappropriates its trade secrets, and will pay the amount of any resulting adverse final judgment (or settlement to which we consent). You must notify us promptly in writing of the claim and give us sole control over its defense or settlement. You agree to provide us with reasonable assistance, cooperation, and information in defending the claim at our expense.
POSSESSION OF GAS AN INDEMNIFICATION 1. As between the parties hereto, Seller shall be deemed to be in control and possession of the gas deliverable hereunder until it shall have been delivered to Buyer at the Point of Delivery after which Buyer shall be deemed to be in control and possession thereof.
Licensee Indemnity Licensee shall jointly and severally indemnify, hold harmless and defend Gilead, MPP and Gilead’s subsidiaries, Affiliates, licensors, directors, officers, employees and agents (together, the “Indemnitees”), from and against any and all losses, damages, expenses, cost of defense (including, without limitation, attorneys’ fees, witness fees, damages, judgments, fines and amounts paid in settlement) and any amounts an Indemnitee becomes legally obligated to pay because of any claim against it (i) arising out of any breach by Licensee of the terms and conditions of this Agreement, or (ii) for any product liability, liability for death, illness, personal injury or improper business practice, or any other statutory liability or any other liability under any law or regulation, to the extent that such claim or claims are due to reasons caused by or on behalf of Licensee related to API or Product (including, without limitation, their manufacture, use or sale). The indemnification obligations of Licensee stated in this Section 8(a) shall apply only in the event that Gilead or MPP, as applicable, provides Licensee with prompt written notice of such claims, grants Licensee the right to control the defense or negotiation of settlement, and makes available all reasonable assistance in defending the claims. Licensee shall not agree to any final settlement or compromise with respect to any such claim that adversely affects Gilead or MPP without obtaining Gilead’s or MPP’s consent.
Program Requirements Provided At No Charge to the Judicial Council A. The Contractor shall provide the following items during the Program at no charge to the Judicial Council:
