Indemnification by Subcontractors To the fullest extent permitted by law, an Interconnection Party that uses a subcontractor to carry out any of the Interconnection Party’s obligations under this Appendix 2 shall require each of its subcontractors to indemnify, hold harmless and defend each other Interconnection Party, its representatives and assigns from and against any and all claims and/or liability for damage to property, injury to or death of any person, including the employees of any Interconnection Party or of any Affiliate of any Interconnection Party, or any other liability incurred by the other Interconnection Party or any of its Affiliates, including all expenses, legal or otherwise, to the extent caused by any act or omission, negligent or otherwise, by such subcontractor and/or its officers, directors, employees, agents and assigns, that arises out of or is connected with the operation of the facilities of either Interconnected Entity described in this Appendix 2; provided, however, that no Interconnection Party or Affiliate thereof shall be entitled to indemnity under this Section 18.3 in respect of any injury, loss, or damage to the extent that such loss, injury, or damage results from the negligence or willful misconduct of the Interconnection Party or Affiliate seeking indemnity.
Claims Excluded from Arbitration The following matters will not be subject to arbitration but will instead be adjudicated in the courts of Xxxxxx County, Texas or such other court in which jurisdiction and venue are proper: (a) an action for possession or for injunctive remedies provided under applicable landlord-tenant laws or to enforce intellectual property rights; (b) a suit by Owner or its assignee for collection of amounts owed by Resident under this Agreement; and (c) any claim or dispute for which applicable law (as determined by a binding court decision) or the applicable arbitration rules do not permit arbitration and require adjudication in a specific civil court. Matters within the jurisdiction of an applicable small claims court may also be brought in that court in lieu of arbitration.
Modified Indemnity Where Agreement Involves Design Professional Services Notwithstanding the forgoing, if the services provided under this Agreement are design professional services, as defined by California Civil Code section 2782.8, as may be amended from time to time, the defense and indemnity obligation under Section 1, above, shall be limited to the extent required by California Civil Code section 2782.8.
Indemnification by Contractor (a) Contractor shall defend, indemnify and hold harmless District, its officers, directors, employees, agents, volunteers, and Affiliates and District’s Board of Education from any and all damages, costs and expenses, including attorneys’ fees, arising out of any third party claims for damages for bodily injury (including death) or for damage to real property or tangible personal property resulting from, arising out of or otherwise related to Contractor’s performance of this Agreement.
Indemnity for Personality Agreements Vendor agrees to indemnify and hold harmless and defend TIPS, TIPS Member(s), officers and employees, from and against all claims and suits for damages, injuries to persons (including death), property damages, losses, and expenses including court costs and attorney’s fees, arising out of, or resulting from, Vendor’s performance of this Agreement or sales made to TIPS Members under this agreement , including all such causes of action based upon common, constitutional, or statutory law, or based in whole or in part, upon allegations of negligent or intentional acts on the part of the Vendor, its officers, employees, agents, subcontractors, licensees, invitees, unless such claims are based in whole upon the negligent acts or omissions of the TIPS, TIPS Member(s), officers, employees, or agents. If based in part upon the negligent acts or omissions of the TIPS, TIPS Member(s), officers, employees, or agents, Vendor shall be responsible for their proportional share of theclaim.
Accountholder’s Indemnification Obligation You understand and agree that you are required to indemnify us and hold us harmless against any and all claims, actions, damages, liabilities, costs and expenses, including reasonable attorneys’ fees and expenses, arising out of your use of the Services and/or breach of this Agreement. You understand and agree that this paragraph shall survive termination of this Agreement.
Indemnity for Personality Contracts Vendor agrees to indemnify and hold harmless and defend TIPS, TIPS member(s), officers and employees, from and against all claims and suits for damages, injuries to persons (including death), property damages, losses, and expenses including court costs and attorney’s fees, arising out of, or resulting from, Vendor’s performance of this contract, including all such causes of action based upon common, constitutional, or statutory law, or based in whole or in part, upon allegations of negligent or intentional acts on the part of the Vendor, its officers, employees, agents, subcontractors, licensees, invitees, whether or not such claims are based in whole or in part upon the negligent acts or omissions of the TIPS, TIPS member(s), officers, employees, or agents.
Indemnity for Professional Liability When the law establishes a professional standard of care for CONTRACTOR’s services or if the services or a portion of the services performed by the CONTRACTOR involves the use of professional knowledge, and to the fullest extent permitted by law, CONTRACTOR shall defend, indemnify and hold harmless COMMISSION, its officials, officers, directors, employees, servants, designated volunteers and agents serving as independent contractors in the role of COMMISSION officials (collectively “Indemnitees”), from and against any liability, claim, damage, demand, suit, cause of action, proceeding, judgment, penalty, lien, loss, expense or cost of any kind, including reasonable fees of accountants, attorneys and other professionals, and all costs associated therewith (collectively, “damages”), whether actual, alleged or threatened, arising out of, pertaining to, or relating to any negligent or wrongful act, error or omission of CONTRACTOR, its officials, officers, directors, agents, employees, subcontractors, or any entity or individual that CONTRACTOR bears legal liability thereof, in the performance of professional services under this Contract. CONTRACTOR shall defend Indemnitees in any action or actions filed in connection with any such damages with counsel of COMMISSION’s choice and shall pay all costs and expenses, including actual attorney’s fees, incurred in connection with such defense.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
Matters Excluded from Arbitration The following matters will not be subject to arbitration but will instead be adjudicated in the courts of Alachua County, Florida or such other court in which jurisdiction and venue are proper: (a) an action for possession or for injunctive remedies provided under applicable landlord-tenant laws or to enforce intellectual property rights; (b) a suit by Owner or its assignee for collection of amounts owed by Resident under this Agreement; and (c) any claim or dispute for which applicable law (as determined by a binding court decision) or the applicable arbitration rules do not permit arbitration and require adjudication in a specific civil court. Matters within the jurisdiction of an applicable small claims court may also be brought in that court in lieu of arbitration. The parties agree that if any claim brought in court arises out of an underlying dispute that is subject to arbitration, at either party’s request the judicial action will be stayed pending completion of the arbitration.
