Price and Rate Guarantee Period All prices and rates must be guaranteed for the initial term of the Master Agreement. Following the initial Master Agreement period, any request for price or rate adjustment must be for an equal guarantee period, and must be made at least 30 days prior to the effective date. Requests for price or rate adjustment must include sufficient documentation supporting the request. Any adjustment or amendment to the Master Agreement shall not be effective unless approved by the Lead State. No retroactive adjustments to prices or rates will be allowed.
Return of Performance Bank Guarantee Payment on Order Instrument
Rental Rates and Wage Rates for Change Orders As soon as is practical, but prior to the completion of the Construction Preparation Period and in any event prior to the commencement of any Work on the Site, the Contractor shall submit in accordance with the style and format of a specimen to be furnished by the Owner for consideration of the Owner the following: (1) a proposal for rental rates on heavy construction equipment that shall apply in the event Change Order Work is performed, and (2) a proposal for wage rates for the types of project labor that shall apply in the event of the execution of any Change Order Work. Under penalty of false swearing, a principal of the contracting firm shall certify that the proposal for rental rates and proposal for wage rates do not exceed current costs for like services. The Owner will in no event consider a rental rate in excess of eighty percent of the rate set forth in the latest edition of the "Compilation of Nationally Averaged Rental Rates for Construction Equipment" of the Associated Equipment Distributors unless the rates proposed in excess of eighty percent are supported by proof satisfactory to the Owner that the excess rates are reasonable. If the equipment is owned by the Contractor the costs shall be charged at a maximum of eighty percent of market monthly rental rates for the amount of time used. If applicable, transportation costs may be included. The decision of the Owner shall be final, binding and conclusive on all parties. Rental rates shall be payable only for the actual time the equipment is required on the Site.
INDIVIDUAL CASE BASIS PRICING 42.1. Individual Case Basis (ICB) pricing will be provided by Sprint upon request from the CLEC for customer specific rates or terms for network services and features for UNEs that are not otherwise provided for in this Agreement.
Rate Redetermination for Market Change In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.
CAISO Monthly Billed Fuel Cost [for Geysers Main only] The CAISO Monthly Billed Fuel Cost is given by Equation C2-1. CAISO Monthly Billed Fuel Cost Equation C2-1 = Billable MWh ◆ Steam Price ($/MWh) Where: • Steam Price is $16.34/MWh. • For purposes of Equation C2-1, Billable MWh is all Billable MWh Delivered after cumulative Hourly Metered Total Net Generation during the Contract Year from all Units exceeds the Minimum Annual Generation given by Equation C2-2. Equation C2-2 Minimum Annual Generation = (Annual Average Field Capacity ◆ 8760 hours ◆ 0.4) - (A+B+C) Where: • Annual Average Field Capacity is the arithmetic average of the two Field Capacities in MW for each Contract Year, determined as described below. Field Capacity shall be determined for each six-month period from July 1 through December 31 of the preceding calendar year and January 1 through June 30 of the Contract Year. Field Capacity shall be the average of the five highest amounts of net generation (in MWh) simultaneously achieved by all Units during eight-hour periods within the six-month period. The capacity simultaneously achieved by all Units during each eight-hour period shall be the sum of Hourly Metered Total Net Generation for all Units during such eight-hour period, divided by eight hours. Such eight-hour periods shall not overlap or be counted more than once but may be consecutive. Within 30 days after the end of each six-month period, Owner shall provide CAISO and the Responsible Utility with its determination of Field Capacity, including all information necessary to validate that determination. • A is the amount of Energy that cannot be produced (as defined below) due to the curtailment of a Unit during a test of the Facility, a Unit or the steam field agreed to by CAISO and Owner. • B is the amount of Energy that cannot be produced (as defined below) due to the retirement of a Unit or due to a Unit’s Availability remaining at zero after a period of ten Months during which the Unit’s Availability has been zero. • C is the amount of Energy that cannot be produced (as defined below) because a Force Majeure Event reduces a Unit’s Availability to zero for at least thirty (30) days or because a Force Majeure Event reduces a Unit’s Availability for at least one hundred eighty (180) days to a level below the Unit Availability Limit immediately prior to the Force Majeure Event. • The amount of Energy that cannot be produced is the sum, for each Settlement Period during which the condition applicable to A, B or C above exists, of the difference between the Unit Availability Limit immediately prior to the condition and the Unit Availability Limit during the condition.
Minimum Interest Charge If the interest charge for all balances on your Credit Card account is less than $1.00, we will charge you the Minimum Interest Charge shown on page 1. This charge is in lieu of any interest charge.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Dollar Limits Per Service Agreement Cost to diagnose, repair and/or replace - Geothermal and water source systems $1,500 Water cooled air conditioners, high velocity and hydronic systems $1,500 Concrete encased or concealed ductwork $500 Refrigerant lines $500 Appliances l Standard/Seller Coverage S Supreme Coverage l S Appliance color matchSM l S Built-in microwave l S Dishwasher l S Garbage disposal l S Range, oven, cooktop and vent hood l S Refrigerator - INCLUDING ICE MAKER! S Washer and dryer S Range, oven, cooktop, hood: handles, hinges, clocks, rotisseries, racks, knobs and dials, interior lining, glass/ceramic cooktops, self cleaning mechanisms and latch assemblies S Kitchen Refrigerator: handles, hinges, ice crusher, beverage dispenser and respective equipment S Built-in microwave: handles, hinges, interior lining, clocks and shelves, turntable platforms and rollers S Dishwasher: handles, hinges, racks, baskets, rollers, tub and interior lining, springs, latch assemblies and soap dispensers S Permits up to $250 per Service Agreement S Modifications up to $250 per Service Agreement S Haul away/disposal fees S Items under manufacturer’s warranty Excluded Items: ✖ Appliances not located in the primary kitchen (except washer and dryer) and duplicate appliances, unless additional refrigerator option(s) are purchased. ✖ Meat probe assemblies, door glass, sensi-heat burners will only be replaced with standard burners for range, oven, cooktop. ✖ Multimedia center including technology convenience items like LCD screens, Wi-Fi and cameras. ✖ Racks, hinges, shelves, interior thermal shells, food spoilage and freezers which are not an integral part of the kitchen refrigerator. ✖ Door glass, portable or counter top units, trim kits, meat probe assemblies, rotisseries for built-in microwave. ✖ Damage to clothing, plastic mini-tub, soap dispensers, filter screens, knobs, dials, hinges and lint screen for washer or dryer. ✖ Gas supply line to stove.
Manner of Conveyance; Limited Warranty; Nonrecourse; Etc THE CONVEYANCE OF ALL ASSETS, INCLUDING REAL AND PERSONAL PROPERTY INTERESTS, PURCHASED BY THE ASSUMING INSTITUTION UNDER THIS AGREEMENT SHALL BE MADE, AS NECESSARY, BY RECEIVER'S DEED OR RECEIVER'S XXXX OF SALE, "AS IS", "WHERE IS", WITHOUT RECOURSE AND, EXCEPT AS OTHERWISE SPECIFICALLY PROVIDED IN THIS AGREEMENT, WITHOUT ANY WARRANTIES WHATSOEVER WITH RESPECT TO SUCH ASSETS, EXPRESS OR IMPLIED, WITH RESPECT TO TITLE, ENFORCEABILITY, COLLECTIBILITY, DOCUMENTATION OR FREEDOM FROM LIENS OR ENCUMBRANCES (IN WHOLE OR IN PART), OR ANY OTHER MATTERS.
