Infringement Indemnification If notified promptly in writing of any judicial action brought against City based on an allegation that City’s use of the Licensed Software infringes a patent, copyright, or any right of a third party or constitutes misuse or misappropriation of a trade secret or any other right in intellectual property (Infringement), Contractor will hold City harmless and defend such action at its own expense. Contractor will pay the costs and damages awarded in any such action or the cost of settling such action, provided that Contractor shall have sole control of the defense of any such action and all negotiations or its settlement or compromise. If notified promptly in writing of any informal claim (other than a judicial action) brought against City based on an allegation that City’s use of the Licensed Software constitutes Infringement, Contractor will pay the costs associated with resolving such claim and will pay the settlement amount (if any), provided that Contractor shall have sole control of the resolution of any such claim and all negotiations for its settlement. In the event a final injunction is obtained against City’s use of the Licensed Software by reason of Infringement, or in Contractor’s opinion City’s use of the Licensed Software is likely to become the subject of Infringement, Contractor may at its option and expense: (a) procure for City the right to continue to use the Licensed Software as contemplated hereunder, (b) replace the Licensed Software with a non-infringing, functionally equivalent substitute Licensed Software, or (c) suitably modify the Licensed Software to make its use hereunder non-infringing while retaining functional equivalency to the unmodified version of the Licensed Software. If none of these options is reasonably available to Contractor, then the Agreement may be terminated at the option of either Party hereto and Contractor shall refund to City all amounts paid under this Agreement for the license of such infringing Licensed Software. Any unauthorized modification or attempted modification of the Licensed Software by City or any failure by City to implement any improvements or updates to the Licensed Software, as supplied by Contractor, shall void this indemnity unless City has obtained prior written authorization from Contractor permitting such modification, attempted modification or failure to implement. Contractor shall have no liability for any claim of Infringement based on City’s use or combination of the Licensed Software with products or data of the type for which the Licensed Software was neither designed nor intended to be used.
Indemnification by Supplier Supplier covenants and agrees to indemnify, defend and hold harmless Eargo, its Affiliate(s), Approved Buyer(s), and their respective agents, contractors, officers, directors, employees and Representatives (including any combination of the Eargo, its Affiliate(s), Approved Buyer(s) or their respective agents, contractors, officers, directors, employees and Representatives) (collectively, the “Indemnified Parties”) from and against any and all claims, allegations, losses, damages, settlements, governmental fines and penalties, and all other liabilities, including attorneys’ and other professional fees and court costs, and all costs and expenses, arising out of or related to: (a) the Units, or any portion thereof, on their own or in combination with any other goods and services, infringe any rights or IPR of a third party (collectively, “Third Party IPR”) where such Third Party IPR relates to Supplier’s Manufacturing Process, or manufacturing, packaging, testing, or other Services provided under this Agreement, excluding Product design and materials or equipment consigned to Supplier by Eargo; (b) personal injury or property damage resulting, directly or indirectly from the Units or Services (including any Hazard), the performance of Supplier’s obligations hereunder, or the fault or negligence of Supplier or the Supplier Parties; (c) negligent, willful or reckless acts or omissions, dishonesty or fraud of or by Supplier or any Supplier Parties; (d) a breach or alleged breach by Supplier or any Supplier Parties of any provision or clause (e.g., Supplier or Supplier Parties act in contravention of any clause or perform acts contrary to the terms specified in this Agreement) of this Agreement; (e) any claim or cause of action anywhere in the world asserted against Eargo or any of the Indemnified Parties alleging or in connection with alleged defects in the assembly or manufacturing of the Product(s); or (f) violations of law in the manufacture of the Products; (each a “Claim” and collectively, “Claims”).
Infringement Indemnity Except as specifically provided below, Ricoh will indemnify, defend and hold Subscriber harmless from and against any and all liabilities, damages, costs and expenses (including reasonable attorneys fees) incurred by Subscriber arising from a third party claim that the Services or Application, as delivered by Ricoh and used within the scope of this Agreement, infringe any existing domestic patent, copyright or trademark, but only if, (i) Subscriber notifies Ricoh in writing within thirty (30) days of any such claim, (ii) Ricoh shall have full control of the defense and all related settlement negotiations, and (iii) Subscriber shall provide Ricoh with assistance, information and authority necessary to perform the above. Notwithstanding the foregoing, Ricoh shall have no indemnity obligation for any claim relating to (i) any software of third parties, including without limitation, any embedded open source or similar software, (ii) any modifications to the Services or Application made by any entity other than Ricoh, (iii) combination or use of the Services or Application with other products, (iv) use of an outdated version of the Ancillary Software when Ricoh has made available an updated version that does not infringe, or (v) any addition, change or modification of the functionality of the Services or Application made at Subscriber’s request, if such claim would not have arisen but for such functionality. In the event of an infringement claim, if it is commercially reasonable to do so, and at its option, Ricoh will either obtain the right for Subscriber to use the Services or will modify the Services to make them non-infringing, and failing these options, Ricoh may terminate the license and Subscriber will return any Ancillary Software. THE REMEDIES ABOVE ARE THE SOLE AND EXCLUSIVE REMEDIES FOR RICOH’S BREACH OF ANY INTELLECTUAL PROPERTY WARRANTY CONTAINED IN THIS AGREEMENT OR IMPOSED OR IMPLIED BY LAW.
Intellectual Property Infringement Indemnification 1.1 We will defend you against any third party claim(s) that the Tyler Software or Documentation infringes that third party’s patent, copyright, or trademark, or misappropriates its trade secrets, and will pay the amount of any resulting adverse final judgment (or settlement to which we consent). You must notify us promptly in writing of the claim and give us sole control over its defense or settlement. You agree to provide us with reasonable assistance, cooperation, and information in defending the claim at our expense.
1.2 Our obligations under this Section G(1) will not apply to the extent the claim or adverse final judgment is based on your use of the Tyler Software in contradiction of this Agreement, including with non-licensed third parties, or your willful infringement.
1.3 If we receive information concerning an infringement or misappropriation claim related to the Tyler Software, we may, at our expense and without obligation to do so, either: (a) procure for you the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent, in which case you will stop running the allegedly infringing Tyler Software immediately. Alternatively, we may decide to litigate the claim to judgment, in which case you may continue to use the Tyler Software consistent with the terms of this Agreement.
1.4 If an infringement or misappropriation claim is fully litigated and your use of the Tyler Software is enjoined by a court of competent jurisdiction, in addition to paying any adverse final judgment (or settlement to which we consent), we will, at our option, either: (a) procure the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent. This section provides your exclusive remedy for third party copyright, patent, or trademark infringement and trade secret misappropriation claims.
PATENT INDEMNIFICATION The Contractor agrees to assume the defense of and shall indemnify and save harmless the Owner and all persons acting for or on behalf of it from all suits and claims against them, or any of them, arising from or occasioned by the use of any material, Equipment or apparatus, or any part thereof which infringes or is alleged to infringe on any patent rights. In case such material, equipment or apparatus, or any part thereof, in any such suit is held to constitute infringement, the Contractor, within a reasonable time, shall at its own expense, and as the Owner may elect, replace such material, Equipment or apparatus with non-infringing material, Equipment or apparatus, or remove the material, equipment, or apparatus and refund the sums paid therefor.
Intellectual Property Indemnification by Vendor Procedures Related to Indemnification. In the event that an indemnity obligation arises, Vendor shall pay all amounts set forth in Section 14 and 15 above (including any settlements) and – if it has accepted its indemnity obligation without qualification – control the legal defense to such claim or cause of action, including without limitation attorney selection, strategy, discovery, trial, appeal, and settlement, and TIPS shall, at Vendor’s cost and expense (with respect to reasonable out of pocket costs and expenses incurred by TIPS which shall be reimbursed to TIPS by Vendor), provide all commercially reasonable assistance requested by Vendor. In controlling any defense, Vendor shall ensure that all assertions of governmental immunity and all applicable pleas and defenses shall be promptly asserted.
Indemnification for Third Party Claims
(a) Seller shall defend, indemnify and hold harmless Buyer, its shareholders and Affiliates, and their respective directors, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance by any Project Party of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Seller, the Contractor, any Subcontractor, and its respective employees or agents.
(b) Buyer shall defend, indemnify and hold harmless Seller and its managers, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Buyer, its employees or agents.
(c) Either Party seeking indemnification under this Agreement (the “Indemnified Party”) shall give notice to the Party required to provide indemnification hereunder (the “Indemnifying Party”) promptly after the Indemnified Party has actual knowledge of any Claim as to which indemnity may be sought hereunder, and the Indemnified Party shall permit the Indemnifying Party (at the expense of the Indemnifying Party) to assume the defense of any Claim or litigation resulting therefrom; provided that:
(i) counsel for the Indemnifying Party who shall conduct the defense of such Claim or litigation shall be reasonably satisfactory to the Indemnified Party;
(ii) the Indemnified Party may participate in such defense at its own expense, except the Indemnifying Party shall reimburse the Indemnified Party for its participation in such defense to the extent that the Indemnifying Party requests the Indemnified Party to participate in its own defense; and
(iii) the omission by the Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligations hereunder except to the extent that such omission results in a failure of actual notice to the Indemnifying Party and Indemnifying Party is damaged as a result of such failure to give notice. Notwithstanding the foregoing, the Indemnifying Party may not settle any Claim related to the indemnity being provided hereunder without the consent of the Indemnified Party, such consent not to be unreasonably withheld.
(d) With regard to any Claim or Liability which is the result of the joint or concurrent fault or negligence of Seller and Buyer, the Parties agree to jointly defend any Claim with respect thereto that is based on such joint or concurrent fault or negligence of Buyer and Seller. Any Claim of contribution or indemnification between Buyer and Seller relating to such Claims shall be resolved on the basis of the percentage of fault or negligence and the Parties agree to reserve the determination of such percentage until after resolution of such Claim. Such pro rata share shall be based upon a final judicial determination of the Parties’ comparative fault or negligence or, in the absence of such determination, by mutual agreement.
(e) Nothing in this Section 26.1 is intended to allow any Indemnified Party to be indemnified from and against any third party Claims and Liabilities caused by, arising out of, or in connection with the performance of this Agreement to the extent any of such Claims or Liabilities were caused by, arose out of, or were in any way incidental to or in connection with its own negligence or intentional misconduct.
Indemnification by Licensor Licensor shall defend, indemnify and hold harmless Licensee and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensee Parties”) from and against any claim, suit, demand or action (“Action”), and any and all direct losses suffered or incurred by Licensee in connection with any third party claims (a) arising out of or resulting from any breach by Licensor of any provision of this Agreement or (b) that use of the Licensed Marks by Licensee in accordance with the terms and conditions of this Agreement infringes or otherwise violates a third party’s Trademarks. Licensor’s obligation to indemnify Licensee shall be conditioned on (a) Licensee’s provision to Licensor of prompt notice of such an Action (except where any delay does not materially prejudice Licensor); (b) Licensee’s reasonable cooperation with Licensor in the defense and settlement of such an Action at Licensor’s cost; and (c) Licensor having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensor may not settle any Action in a manner that adversely affects Licensee without Licensee’s prior written consent, not to be unreasonably withheld or delayed).
Indemnification by Licensee Licensee shall defend, indemnify and hold harmless the INFI Indemnitees from and against any and all losses, damages, fees, expenses, settlement amounts or costs (including reasonable legal expense, attorneys’ fees and witness fees) (“Losses”) relating to or in connection with a Third Party claim to the extent arising out of (a) the research, development, manufacture or commercialization of the IPI-145 Compound or the IPI-145 Product by Licensee, any Licensee Affiliate, any Sublicensee, INFI (to the extent properly acting in accordance with Licensee’s express direction) or any of their respective employees, consultants, contractors, subcontractors or agents after the Effective Date, including any actual or alleged death, personal bodily injury or damage to real or tangible personal property, or other product liability claimed to result from the IPI-145 Product Researched, Developed, Manufactured or Commercialized by or on behalf of Licensee or any of its Affiliates or any Sublicensee, (b) any breach by Licensee of any of its representations, warranties, covenants or obligations under this Agreement, or (c) any negligent act or omission or willful misconduct of Licensee, any of its Affiliates or any Sublicensee, or any of their respective employees, consultants, contractors, subcontractors or agents, in performing Licensee’s obligations or exercising Licensee’s rights under this Agreement; except that the foregoing indemnity shall not apply with respect to any INFI Indemnitee to the extent that any such Losses (x) are caused by the gross negligence or willful misconduct of any INFI Indemnitee, or (y) are otherwise subject to an obligation by INFI to indemnify the Licensee Indemnitees under Section 10.2.
Indemnification; Third Party Claims The Master Servicer agrees to indemnify the Depositor, the Sponsor and the Trustee, and their respective officers, directors, agents and affiliates, and hold each of them harmless against any and all claims, losses, penalties, fines, forfeitures, reasonable legal fees and related costs, judgments, and any other costs, liability, fees and expenses that the Depositor, the Sponsor or the Trustee may sustain as a result of (a) any material breach by the Master Servicer of any if its obligations hereunder, including particularly its obligations to provide any reports under Section 9.25(a), Section 9.25(b), Section 9.26 or any information, data or materials required to be included in any Exchange Act report, (b) any material misstatement or omission in any information, data or materials provided by the Master Servicer, or (c) the negligence, bad faith or willful misconduct of the Master Servicer in connection with its performance hereunder, provided, however, that in no event shall the Master Servicer be liable for any special, consequential, indirect or punitive damages pursuant to this Section 9.31, even if advised of the possibility of such damages. The Depositor, the Sponsor and the Trustee shall immediately notify the Master Servicer if a claim is made by a third party with respect to this Agreement or the Mortgage Loans entitling the Depositor, the Sponsor or the Trustee to indemnification hereunder, whereupon the Master Servicer shall assume the defense of any such claim and pay all expenses in connection therewith, including counsel fees, and promptly pay, discharge and satisfy any judgment or decree which may be entered against it or them in respect of such claim. Notwithstanding anything to the contrary contained herein, the Master Servicer shall not settle any claim involving any of the other parties hereto without such party’s prior written consent unless such settlement involves a complete and absolute release of such party from any and all liability in connection with such claim. This indemnification shall survive the termination of this Agreement or the termination of the Master Servicer as a party to this Agreement.
