Project Completion Within five (5) days after the delivery by Supplier to Purchaser of a Commissioning Certificate for the Project’s final Turbine, Supplier shall also deliver to Purchaser a completion certificate for all Turbines in the Project (the “Project Completion Certificate”), in the form attached hereto as Exhibit N, together with a list of any remaining Punch List Work on any Turbine, a schedule for completing the Punch List Work and an estimate of the cost of each item of Punch List Work. Supplier shall thereafter promptly complete all Punch List Work.
Feasibility Study Buyer is granted the right to conduct engineering and/or market and economic feasibility studies of the Property and a physical inspection of the Property, including studies or inspections to determine the existence of any environmental hazards or conditions (collectively, the “Feasibility Study”) during the period (the “Feasibility Period”) commencing on the Effective Date and ending at 5:00 p.m., Central Time, on the June 3, 2010. With Seller’s permission, after Seller has received advance notice sufficient to permit it to schedule in an orderly manner Buyer’s examination of the Property and to provide at least 24-hours’ advance written notice to any affected tenants, Buyer or its designated agents may enter upon the Property during normal business hours for purposes of analysis or other tests and inspections which may be deemed necessary by Buyer for the Feasibility Study. Buyer or its designated representative must be accompanied by a designated representative of Seller or have received Seller’s written permission prior to entering upon the Property in connection with Buyer’s Feasibility Study; provided, however, Buyer may not enter into any space leased by any tenant without being accompanied by a designated representative of Seller. Seller agrees to make its representative reasonably available during normal business hours. Buyer will not alter the physical condition of the Property or conduct invasive testing without notifying Seller of its requested tests, and obtaining the written consent of Seller to any physical alteration of the Property or invasive testing. Buyer will utilize commercially reasonable diligence to conduct or cause to be conducted all inspections and tests in a manner and at times which will not unreasonably interfere with any tenant’s use and occupancy of the Property. If Buyer determines, in its sole judgment, that the Property is not suitable for any reason for Buyer’s intended use or purpose, or is not in satisfactory condition, then Buyer may terminate this Contract by written notice to Seller prior to expiration of the Feasibility Period, in which case the Xxxxxxx Money (other than the Option Money) will be returned to Buyer, and neither party shall have any further right or obligation hereunder other than as set forth herein with respect to rights or obligations which survive termination. If this Contract is not terminated pursuant to this Section 5(a), then after expiration of the Feasibility Period, after Seller has received advance notice sufficient to permit it to schedule in an orderly manner Buyer’s examination of the Property and to provide at least 24-hours’ advance written notice to any affected tenants, Buyer or its designated agents may enter upon the Property during normal business hours. Buyer or its designated representative must be accompanied by a designated representative of Seller or have received Seller’s written permission prior to entering upon the Property; provided, however, Buyer may not enter into any space leased by any tenant without being accompanied by a designated representative of Seller. If this Contract is not timely terminated pursuant to this Section 5(a), Buyer’s right to terminate this Contract pursuant to this Section 5(a) and any and all objections with respect to the Feasibility Study will be deemed to have been waived by Buyer for all purposes.
Phase II The parties acknowledge that this Agreement is not exclusive and GPPC shall have the right to provide consulting services regarding the marketing of the DCC services of Member, GPPC, any of GPPC’s Affiliates, or of any third party, subject to the provisions of Section 5.4 above. During the Term of this Agreement, GPPC may choose to develop the functionality of its own processing platform, or use a third person’s processing platform to enable GPPC to support certain functions in the clearing and settlement of DCC Transactions (“Phase II”). At such time as it is ready to begin implementing Phase II, GPPC shall inform Planet Payment of its plans and the parties shall discuss how Phase II may be integrated into the Acquirer Program. Nothing herein shall prohibit GPPC from implementing Phase II, and Planet Payment agrees that it will use its commercially reasonable efforts to provide assistance to GPPC to implement Phase II, provided that Planet Payment shall not have any obligation whatsoever to assist GPPC in any way in specifying, designing or implementing functions similar to any of Planet Payment’s functions provided hereunder relating to the conversion, calculation, reporting or reconciliation of cross-currency Transactions. Nothing herein shall oblige Planet Payment to disclose, transfer or license any of its IP to GPPC for the purposes of Phase II. Planet Payment shall not charge GPPC for such assistance, unless GPPC requests modifications or enhancements to the Planet Payment Platform to facilitate Phase II, in which case Planet Payment shall only charge GPPC for its actual and out of pocket costs incurred in connection with such modifications or enhancements. The parties shall use good faith efforts to modify the parties’ respective obligations under this Agreement relating to processing of Transactions (but without any change to their respective Revenue Shares) to reflect the reallocation of their respective functions following implementation of Phase II.
Completion Date Completion date" shall be the date on which the improvements erected and to be erected upon the leased premises shall have been completed in accordance with the plans and specifications described in article 6.00. The completion date shall constitute the commencement of the term of this Lease for all purposes, whether or not Lessee has actually taken possession. Lessor shall use its best efforts to establish the completion date as the date set forth in section 1.03. In the event that the improvements have not in fact been completed as of that date, Lessee shall notify Lessor in writing of its objections. Lessor shall have a reasonable time after delivery of the notice in which to take such corrective action as may be necessary and shall notify Lessee in writing as soon as it deems such corrective action has been completed and the improvements are ready for occupancy. Upon completion of construction, Lessee shall deliver to Lessor a letter accepting the leased premises as suitable for the purposes for which they are let and the date of such letter shall constitute the commencement of the term of this Lease. Whether or not Lessee has executed such letter of acceptance, taking possession of the leased premises by Lessee shall be deemed to establish conclusively that the improvements have been completed in accordance with the plans and specifications, are suitable for the purposes for which the leased premises are let, and that the leased premises are in good and satisfactory condition as of the date possession was so taken by Lessee, except for latent defects, if any.
Post-Closing Deliverables On or before the Closing Date, the applicable Seller shall deliver to Buyer the following:
Possession; Estoppel Certificates Possession of the Property, subject only to rights of guests in possession and tenants pursuant to written leases included in the Leases, and estoppel certificates from tenants under Leases and the lessors under FF&E Leases in form and substance acceptable to Buyer.
Additional Filings Unless filed pursuant to Rule 462(c) as part of the Additional Registration Statement in accordance with the next sentence, the Company will file the Final Prospectus, in a form approved by the Representatives, with the Commission pursuant to and in accordance with subparagraph (1) (or, if applicable and if consented to by the Representatives, subparagraph (4)) of Rule 424(b) not later than the earlier of (A) the second business day following the execution and delivery of this Agreement or (B) the fifteenth business day after the Effective Time of the Initial Registration Statement. The Company will advise the Representatives promptly of any such filing pursuant to Rule 424(b) and provide satisfactory evidence to the Representatives of such timely filing. If an Additional Registration Statement is necessary to register a portion of the Offered Securities under the Act but the Effective Time thereof has not occurred as of the execution and delivery of this Agreement, the Company will file the additional registration statement or, if filed, will file a post-effective amendment thereto with the Commission pursuant to and in accordance with Rule 462(b) on or prior to 10:00 P.M., New York time, on the date of this Agreement or, if earlier, on or prior to the time the Final Prospectus is finalized and distributed to any Underwriter, or will make such filing at such later date as shall have been consented to by the Representatives.
Punch List If, at any time after the Project has been Physically Completed, there shall exist any item or items requiring completion or correction, then the Developer agrees to use all reasonable diligence to complete or correct such item or items so that each conforms to the Final Plans. The parties shall make a Punch-List of the items requiring completion or correction (the "Punch List"). Each item on the Punch-List shall be assigned a reasonable value based upon the reasonable cost of completion or correction of the same or such other value as may be required by the Owner's lender ("Punch-List Amount"). The Developer shall give its written undertaking to complete each such item within forty-five (45) days (or such other period of time as is mutually agreed upon by the parties).
Tenant Estoppel Certificates (a) Seller agrees from and after receipt of the Assumption Approval as set forth in Section 9.1 and provided this Agreement is in full force and effect, within five (5) business days after being requested by Purchaser to do so, to deliver to all tenants of the Property a request for an estoppel certificate in the form of EXHIBIT D attached hereto, which form may be revised if so requested by the Existing Lender. The parties agree that, subject to the provisions of subparagraph (b) below, it shall be a condition to Purchaser's obligation to close under this Agreement that an estoppel certificate either substantially in the form of EXHIBIT D or in the form required by a tenant's Lease, dated not earlier than ten (10) business days prior to the Closing Date, be delivered to Purchaser no later than five (5) business days before Closing from tenants under the Leases occupying, in the aggregate, not less than 75% of the rentable area of the Property, including all tenants occupying at least a full floor or more of space (a "TENANT ESTOPPEL"), Seller agrees to use good faith efforts to obtain such Tenant Estoppels, provided however, Seller shall not be obligated to pay tenants in order to do so. Notwithstanding the foregoing, if at Closing Seller delivers such Tenant Estoppels from tenants occupying at least 60% of the rentable area of the Property, Seller may execute and deliver to Purchaser, at Closing, its own certificate with respect to tenants occupying up to an additional 15% of the rentable area of the Property (substantially in the form of EXHIBIT D or in the form required by a tenant's Lease, appropriately modified to reflect that they are certificates of Seller and made to Seller's knowledge; hereinafter, the "SELLER'S ESTOPPEL CERTIFICATE") and the statements of Seller contained therein shall survive the Closing until the earlier of (a) one hundred and eighty (180) days after Closing, or (b) the date Purchaser obtains an estoppel certificate from a tenant for whom Seller delivered a Seller's Estoppel Certificate.
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 90 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenants’ Work,” and “Force Majeure Delays” shall have the meanings set forth for such terms in the Work Letter. If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 90 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect; provided, however, that if Landlord does not Deliver the Premises within 150 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, in which case subsections (a) and (b) of this paragraph shall apply. If Tenant does not elected to void this Lease within 10 business days of the lapse of such 150 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect.
