Audits by The District and Correction of Accounts During the term of this Agreement and for a period of six (6) years following the termination of this Agreement, the District may begin an audit of Contractor’s provision of goods and/or services under this Agreement. Contractor agrees to retain and make available for inspection all of its records pertaining to its performance of this Agreement, including billing records and any banking records that may reflect proceeds from any transactions with the District, during the term of this Agreement and for at least six (6) years following the termination of this Agreement. If Contractor receives notice that The District is auditing its performance under this Agreement or litigation results from this Agreement, then Contractor agrees to retain and make available for inspection all of its records pertaining to its performance of this Agreement, including billing records and any banking records that may reflect proceeds from any transactions with the District, for an additional three (3) years following the conclusion of the audit or the entry of a final judgment in any such litigation and the final resolution of any possible appeals of a final judgment in any such litigation. If the District determines as result of its audit, that Contractor has failed to satisfy the invoicing or documentation requirements of this Agreement, has improperly billed the District for goods and/or services that were not actually provided, or has overcharged the District for goods and/or services that were actually provided by Contractor, then Contractor shall repay the District, without interest, for any improper payments or overpayments made by the District to Contractor within thirty (30) days of a written demand by the District. If Contractor fails to repay the District for any improper payments or overpayments within thirty (30) days of the District’s written demand, then Contractor will owe the District interest accrued daily at the rate of 7.0% per annum from the date of the District’s written demand until the improper payment and/or overpayment is repaid in full by Contractor. Conversely, if an audit initiated by the District reveals that the District owes additional compensation to Contractor pursuant to the terms of this Agreement, then the District will pay the additional compensation to Contractor, without interest, within thirty (30) days of the completion of its audit. If the District fails to pay Contractor for any additional compensation owed under this Agreement within thirty (30) days after completion of its audit, then the District will pay Contractor interest on the additional compensation accrued daily at the rate of 7.0% per annum from the date of the completion of the District’s audit.
Release by the Contractor The acceptance by the Contractor of final payment shall release NYSERDA from all claims and liability that the Contractor, its representatives and assigns might otherwise have relating to this Agreement.
Determinations by the Director All determinations required by the Director under this Agreement are subject to an HSP’s rights of review and appeal under the Act.
Maintenance by the Manager Throughout the Term the Manager will inspect, maintain, repair and replace elements of the Residence in order to keep the Residence in a good condition and state of repair, complying with health, safety and fire standards required by law. This includes, but is not limited to, inspecting and testing fire safety equipment, major appliances, electrical, bathroom fixtures and plumbing.
Damages for delay by the Concessionaire In the event that (i) the Concessionaire does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.3 within a period of 180 (one hundred and eighty) days from the date of this Agreement, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Clause 4.1.2 or other breach of this Agreement by the Authority, or due to Force Majeure, the Concessionaire shall pay to the Authority Damages in an amount calculated at the rate of 0.2% (zero point two per cent) of the Performance Security for each day's delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.
Inspection and Tests 3.8.1 The Procuring entity or its representative shall have the right to inspect and/or to test the goods to confirm their conformity to the Contract specifications. The Procuring entity shall notify the tenderer in writing in a timely manner, of the identity of any representatives retained for these purposes.
Inspection of Facilities In order to meet their respective obligations under this Agreement, any Party may view or inspect facilities owned by another Party. Provided that reasonable notice is given, a Party shall not unreasonably deny access to relevant facilities for viewing or inspection by the requesting Party.
Inspection of Property The Borrower and each of its Subsidiaries will keep proper books and records in accordance with GAAP and will permit reasonable examinations of its books and records and reasonable inspections of its property (subject to reasonable procedures relating to safety and security), accompanied by personnel of the Borrower, by the Administrative Agent and any Lender and/or their respective accountants or other professional advisers; provided that such examinations and inspections (a) will occur not more frequently than once in any calendar year, with reasonable efforts to make combined visits (unless a Default or an Event of Default has occurred and is continuing in which case such examinations may occur as frequently as reasonably determined by the Administrative Agent or any Lender, with no obligation to combine visits), (b) will be at the sole expense of the Administrative Agent and/or requesting Lender, as the case may be (unless a Default or an Event of Default has occurred and is continuing in which case such examinations will be at the expense of the Borrower), (c) will be undertaken at reasonable times following the provision of written notice in advance to the Borrower, and (d) will not unduly interfere with the operations or management of the Borrower’s business. Notwithstanding anything set forth herein to the contrary, under no circumstances shall the Borrower or any Subsidiary be required to disclose, permit the inspection, examination or making copies or abstracts of, or discussion of, any document, information or other matter (i) that constitutes non−financial trade secrets or non-financial confidential proprietary information, (ii) in respect of which disclosure to the Administrative Agent or any Lender (or their respective Affiliates, representatives, contractors, accountants or other professionals) is prohibited by any Governmental Rule or binding confidentiality agreement with a Person that is not an Affiliate of the Borrower and that was not entered into in contemplation of this Agreement, (iii) that is subject to attorney−client or similar privilege or constitutes attorney work product, or (iv) in the case of any discussions with accountants, only if the Borrower has been given the opportunity to participate in the discussions.
Termination for Convenience by The District The District may terminate this Agreement for convenience, for any reason or no reason at all, on fourteen (14) days advance written notice to Contractor. This advance written notice shall be deemed to have been given on the date the notice is sent by the District to the address for written notices provided below by hand delivery, U.S. Mail, commercial delivery service, such as Fed Ex or UPS, or fax. If this Agreement is so terminated, then the District shall only pay Contractor for goods and/or services provided by Contractor and accepted by the District up to, through, and including the date of termination. Following the termination of this Agreement under this Section, the parties’ duties to one another shall cease except for those obligations that shall survive the termination of this Agreement, including, but not limited to, the District’s payment obligations for goods and/or services accepted by the District before the date of termination, and the Contractor’s duties to insure and/or indemnify the District and to cooperate with any audit. Termination of this Agreement pursuant to this Section shall not limit either of the parties’ remedies for any breach of this Agreement.
Inspection and Testing Each Constructing Entity shall cause inspection and testing of the Interconnection Facilities that it constructs in accordance with the provisions of this section. The Construction Parties acknowledge and agree that inspection and testing of facilities may be undertaken as facilities are completed and need not await completion of all of the facilities that a Constructing Entity is building.
