Completion of Review for Certain Review Receivables Following the delivery of the list of the Review Receivables and before the delivery of the Review Report by the Asset Representations Reviewer, the Servicer may notify the Asset Representations Reviewer if a Review Receivable is paid in full by the Obligor or purchased from the Issuer in accordance with the terms of the Basic Documents. On receipt of such notice, the Asset Representations Reviewer will immediately terminate all Tests of the related Review Receivable, and the Review of such Review Receivables will be considered complete (a “Test Complete”). In this case, the related Review Report will indicate a Test Complete for such Review Receivable and the related reason.
Judicial Review Any determination made by NYSERDA pursuant to this Exhibit that prevents the commencement of the time in which interest will be paid is subject to judicial review in a proceeding pursuant to Article 78 of the Civil Practice Law and Rules. Such proceedings shall only be commenced upon completion of the review procedure specified in Section 504.9 of this Exhibit or any other review procedure that may be specified in this Agreement or by other law, rule, or regulation.
Independence of Asset Representations Reviewer The Asset Representations Reviewer will be an independent contractor and will not be subject to the supervision of the Issuer or the Owner Trustee for the manner in which it accomplishes the performance of its obligations under this Agreement. Unless authorized by the Issuer or the Owner Trustee, respectively, the Asset Representations Reviewer will have no authority to act for or represent the Issuer or the Owner Trustee and will not be considered an agent of the Issuer or the Owner Trustee. Nothing in this Agreement will make the Asset Representations Reviewer and either of the Issuer or the Owner Trustee members of any partnership, joint venture or other separate entity or impose any liability as such on any of them.
Request for Review Within sixty (60) days after receiving notice from the Plan Administrator that a claim has been denied (in part or all of the claim), then claimant (or their duly authorized representative) may file with the Plan Administrator, a written request for a review of the denial of the claim. The claimant (or his duly authorized representative) shall then have the opportunity to submit written comments, documents, records and other information relating to the claim. The Plan Administrator shall also provide the claimant, upon request and free of charge, reasonable access to, and copies of, all documents, records and other information relevant (as defined in applicable ERISA regulations) to the claimant’s claim for benefits.
Independent Review Contractor shall provide the Secretary of ADS/CIO an independent expert review of any Agency recommendation for any information technology activity when its total cost is $1,000,000.00 or greater or when CIO requires one. The State has identified two sub-categories for Independent Reviews, Standard and Complex. The State will identify in the SOW RFP the sub-category they are seeking. State shall not consider bids greater than the maximum value indicated below for this category. Standard Independent Review $25,000 Maximum Complex Independent Review $50,000 Maximum Per Vermont statute 3 V.S.A. 2222, The Secretary of Administration shall obtain independent expert review of any recommendation for any information technology initiated after July 1, 1996, as information technology activity is defined by subdivision (a) (10), when its total cost is $1,000,000 or greater or when required by the State Chief Information Officer. Documentation of this independent review shall be included when plans are submitted for review pursuant to subdivisions (a)(9) and (10) of this section. The independent review shall include: • An acquisition cost assessment • A technology architecture review • An implementation plan assessment • A cost analysis and model for benefit analysis • A procurement negotiation advisory services contract • An impact analysis on net operating costs for the agency carrying out the activity In addition, from time to time special reviews of the advisability and feasibility of certain types of IT strategies may be required. Following are Requirements and Capabilities for this Service: • Identify acquisition and lifecycle costs; • Assess wide area network (WAN) and/or local area network (LAN) impact; • Assess risks and/or review technical risk assessments of an IT project including security, data classification(s), subsystem designs, architectures, and computer systems in terms of their impact on costs, benefits, schedule and technical performance; • Assess, evaluate and critically review implementation plans, e.g.: • Adequacy of support for conversion and implementation activities • Adequacy of department and partner staff to provide Project Management • Adequacy of planned testing procedures • Acceptance/readiness of staff • Schedule soundness • Adequacy of training pre and post project • Assess proposed technical architecture to validate conformance to the State’s “strategic direction.” • Insure system use toolsets and strategies are consistent with State Chief Information Officer (CIO) policies, including security and digital records management; • Assess the architecture of the proposed hardware and software with regard to security and systems integration with other applications within the Department, and within the Agency, and existing or planned Enterprise Applications; • Perform cost and schedule risk assessments to support various alternatives to meet mission need, recommend alternative courses of action when one or more interdependent segment(s) or phase(s) experience a delay, and recommend opportunities for new technology insertions; • Assess the architecture of the proposed hardware and software with regard to the state of the art in this technology. • Assess a project’s backup/recovery strategy and the project’s disaster recovery plans for adequacy and conformance to State policy. • Evaluate the ability of a proposed solution to meet the needs for which the solution has been proposed, define the ability of the operational and user staff to integrate this solution into their work.
Audit of Asset Representations Reviewer The Asset Representations Reviewer will permit the Issuer and its authorized representatives to audit the Asset Representations Reviewer’s compliance with this Section 4.9 during the Asset Representations Reviewer’s normal business hours on reasonable advance notice to the Asset Representations Reviewer, and not more than once during any year unless circumstances necessitate additional audits. The Issuer agrees to make reasonable efforts to schedule any audit described in this Section 4.9 with the inspections described in Section 4.6. The Asset Representations Reviewer will also permit the Issuer and its authorized representatives during normal business hours on reasonable advance written notice to audit any service providers used by the Asset Representations Reviewer to fulfill the Asset Representations Reviewer’s obligations under this Agreement.
Period for Review and Consideration of Agreement Executive understands he/she has been given a period of 21 days to review and consider this Agreement before signing it. Executive further understands he/she may use as much of the 21 day period as he/she wishes prior to signing.
Engagement of Asset Representations Reviewer Servicer shall, at all times while any publicly-offered Series of Notes is Outstanding under the Indenture, ensure that an Asset Representations Reviewer has been engaged by Servicer and appointed by Issuer and if the Asset Representations Reviewer gives notice of its intent to resign or Servicer terminates the Asset Representation Reviewer pursuant to the terms of the Asset Representations Review Agreement or if a vacancy exists in the office of Asset Representations Reviewer for any reason (the Asset Representations Reviewer in such event being referred to herein as the retiring Asset Representations Reviewer), Servicer shall promptly appoint and designate a successor Asset Representations Reviewer in accordance with the provisions of the Asset Representations Review Agreement.
Recognition of U.S. Special Resolution Regimes (i) In the event a Covered Party becomes subject to a proceeding under a U.S. Special Resolution Regime, the transfer of this Agreement (and any interest and obligation in or under, and any property securing, this Agreement) from such Covered Party will be effective to the same extent as the transfer would be effective under the U.S. Special Resolution Regime if this Agreement (and any interest and obligation in or under, and any property securing, this Agreement) were governed by the laws of the United States or a State of the United States.
Independent Decision The Investor is not relying on the Issuer or on any legal or other opinion in the materials reviewed by the Investor with respect to the financial or tax considerations of the Investor relating to its investment in the Shares. The Investor has relied solely on the representations and warranties, covenants and agreements of the Issuer in this Agreement (including the exhibits and schedules hereto) and on its examination and independent investigation in making its decision to acquire the Shares.
