Interim Lien and Claim Waivers Sample Clauses

Interim Lien and Claim Waivers. Each Invoice received by Owner prior to Final Completion shall be accompanied by (i) a fully executed Interim Waiver and Release of Liens from Contractor in the form of Schedule K-1, and a fully executed Interim Claim Waiver from Contractor in the form of Schedule K-2, for all Work performed through the date for which payment is requested, (ii) fully executed Interim Waiver and Release of Liens from each Major Subcontractor in the form set forth in Schedule K-3, and fully executed Interim Claim Waivers from each Major Subcontractor in the form set forth in Schedule K-4, for all Work performed through the date for which payment is requested and (iii) if requested by Owner, fully executed Interim Waiver and Release of Liens from all Major Sub-subcontractors requested substantially in the form set forth in Schedule K-3 (but nevertheless conforming with Applicable Law), and fully executed Interim Claim Waivers from all Major Sub-subcontractors requested in substantially the form set forth in Schedule K-4, for all Work performed through the date for which payment is requested; provided, however, with respect Siemens, receipt of Interim Waiver and Release of Liens and Interim Claim Waivers from Siemens will be in accordance with the form and content requirements set forth in the Siemens Contract; provided further, however, with respect to Major Sub-subcontractors under Siemens, receipt of Interim Waiver and Release of Liens and Interim Claim Waivers from such Major Sub-subcontractors will be in accordance with the form, content and timing requirements set forth in the Siemens Contract. Interim Waiver and Release of Liens and Interim Claim Waivers, however, shall not be required from Major Subcontractors or Major Sub-subcontractors until they have performed Work, and Major Subcontractors and Major Sub-subcontractors shall be required to submit additional Interim Waiver and Release of Liens and Interim Claim Waivers only if they have performed Work not covered by a previous Interim Waiver and Release of Liens and Interim Claim Waiver. Submission of all Interim Waiver and Release of Liens and Interim Claim Waivers in accordance with this Section 7.2C is a condition precedent to payment of any Invoice.
Sample 1Sample 2See All (8)
AutoNDA by SimpleDocs
Interim Lien and Claim Waivers. Each Invoice received by Owner prior to Final Completion of the Project shall be accompanied by (i) a fully executed Interim Lien and Claim Waiver from Contractor in the form of Schedule I-1 for all Work performed through the date for which payment is requested, (ii) if requested, fully executed Interim Lien and Claim Waivers from Major Subcontractors in the form set forth in Schedule I-2 for all Work performed through the date of the last payment and conditional on payment of the invoice being submitted.
Sample 1Sample 2
Interim Lien and Claim Waivers. Each Invoice received by Owner prior to Final Completion of the Project shall be accompanied by (i) a fully executed Interim Lien and Claim Waiver from Contractor in the form of Schedule I-1 for all Work performed through the date for which payment is requested, (ii) fully executed Interim Lien and Claim Waivers from each Subcontractor in the form set forth in Schedule I-2 for all Work performed through the date for which payment is requested and (iii) if requested by Owner, fully executed Interim Lien and Claim Waivers from all Sub-subcontractors requested in substantially the form set forth in Schedule I-2 for all Work performed through the date for which payment is requested. Interim Lien and Claim Waivers, however, shall not be required from Subcontractors or Sub-subcontractors until they have performed Work, and Subcontractors and Sub-subcontractors shall be required to submit additional Interim Lien and Claim Waivers only if they have performed Work not covered by a previous Interim Lien and Claim Waiver. Submission of all Interim Lien and Claim Waivers is a condition precedent to payment of any Invoice.
Sample 1

Related to Interim Lien and Claim Waivers

  • Indemnification Claims An Indemnified Party shall give written notification to the Indemnifying Party of the commencement of any Third Party Action. Such notification shall be given within 20 days after receipt by the Indemnified Party of notice of such Third Party Action, and shall describe in reasonable detail (to the extent known by the Indemnified Party) the facts constituting the basis for such Third Party Action and the amount of the claimed damages; provided, however, that no delay or failure on the part of the Indemnified Party in so notifying the Indemnifying Party shall relieve the Indemnifying Party of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Party may, upon written notice thereof to the Indemnified Party, assume control of the defense of such Third Party Action with counsel reasonably satisfactory to the Indemnified Party; provided that the Indemnifying Party may not assume control of the defense of Third Party Action involving criminal liability or in which equitable relief is sought against the Indemnified Party. If the Indemnifying Party does not, or is not permitted under the terms hereof to, so assume control of the defense of a Third Party Action, the Indemnified Party shall control such defense. The Non-controlling Party may participate in such defense at its own expense. The Controlling Party shall keep the Non-controlling Party advised of the status of such Third Party Action and the defense thereof and shall consider in good faith recommendations made by the Non-controlling Party with respect thereto. The Non-controlling Party shall promptly furnish the Controlling Party with such information as it may have or receive with respect to such Third Party Action (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party in the defense of such Third Party Action. The fees and expenses of counsel to the Indemnified Party with respect to a Third Party Action shall be considered Damages for purposes of this Agreement if (x) the Indemnified Party controls the defense of such Third Party Action pursuant to the terms of this Section 5.3 or (y) the Indemnifying Party assumes control of such defense and the Indemnified Party reasonably concludes that the Indemnifying Party and the Indemnified Party have conflicting interests with respect to such Third Party Action. The Indemnifying Party shall not agree to any settlement of, or the entry of any judgment arising from, any Third Party Action without the prior written consent of the Indemnified Party, which shall not be unreasonably withheld, conditioned or delayed. The Indemnified Party shall not agree to any settlement of, or the entry of any judgment arising from, any such Third Party Action without the prior written consent of the Indemnifying Party, which shall not be unreasonably withheld, conditioned or delayed.

  • Litigation and Claims No litigation, claim, investigation, administrative proceeding or similar action (including those for unpaid taxes) against Borrower is pending or threatened, and no other event has occurred which may materially adversely affect Borrower’s financial condition or properties, other than litigation, claims, or other events, if any, that have been disclosed to and acknowledged by Lender in writing.

  • Litigation Matters If the FDIC Party and the Assuming Institution do not agree to submit the Dispute Item to arbitration, the Dispute Item may be resolved by litigation in accordance with Federal or state law, as provided in Section 13.10 of the Purchase and Assumption Agreement. Any litigation shall be filed in a United States District Court in the proper district.

  • RELEASE OF LIABILITY, WAIVER OF CLAIMS AND INDEMNITY AGREEMENT In consideration of the Releasees allowing me to participate in wilderness activities I hereby agree as follows:

  • AMENDMENTS; WAIVERS; REMEDIES This Agreement may not be amended or waived except by a writing signed by Executive and by a duly authorized representative of the Company other than Executive. Failure to exercise any right under this Agreement shall not constitute a waiver of such right. Any waiver of any breach of this Agreement shall not operate as a waiver of any subsequent breaches. All rights or remedies specified for a party herein shall be cumulative and in addition to all other rights and remedies of the party hereunder or under applicable law.

  • Indemnification Process and Appeal (a) To obtain indemnification under this Agreement, Indemnitee shall submit to the Company a written request to the Secretary of the Company, including therein or therewith such documentation and information as is reasonably available to Indemnitee and is reasonably necessary to determine whether and to what extent Indemnitee is entitled to indemnification. The Secretary of the Company shall, promptly upon receipt of such a request for indemnification, advise the Board in writing that Indemnitee has requested indemnification. (b) Upon written request by Indemnitee for indemnification pursuant to the first sentence of Section 4(a) hereof, a determination, if required by applicable law, with respect to Indemnitee's entitlement thereto shall be made in the specific case: (i) if a Change in Control shall have occurred, by Independent Counsel in a written opinion to the Board, a copy of which shall be delivered to Indemnitee; or (ii) if a Change of Control shall not have occurred, (A) by a majority vote of the Disinterested Directors, even though less than a quorum of the Board, or (B) if there are no such Disinterested Directors and, if required by applicable law, or, if such Disinterested Directors so direct, by Independent Counsel in a written opinion to the Board, a copy of which shall be delivered to Indemnitee or (C) if so directed by the Board, by the stockholders of the Company (any such party referenced in (A), (B) or (C) above is referred to herein as the "Reviewing Party"); and, if it is so determined that Indemnitee is entitled to indemnification, payment to Indemnitee shall be made within ten (10) days after such determination. Indemnitee shall cooperate with the person, persons or entity making such determination with respect to Indemnitee's entitlement to indemnification, including providing to such person, persons or entity upon reasonable advance request any documentation or information which is not privileged or otherwise protected from disclosure and which is reasonably available to Indemnitee and reasonably necessary to such determination. Such determination shall be made as promptly as is reasonably practicable, taking into account all facts and circumstances. Any reasonable costs or expenses (including reasonable attorneys' fees and disbursements) actually incurred by Indemnitee in so cooperating with the person, persons or entity making such determination shall be borne by the Company (irrespective of the determination as to Indemnitee's entitlement to indemnification) and the Company hereby indemnifies and agrees to hold Indemnitee harmless therefrom. (c) In the event the determination of entitlement to indemnification is to be made by Independent Counsel pursuant to Section 4(b) hereof, the Independent Counsel shall be selected as provided in this Section 4(c). If a Change of Control shall not have occurred, the Board shall select the Independent Counsel, and the Company shall give written notice to Indemnitee advising him of the identity of the Independent Counsel so selected. If a Change of Control shall have occurred, the Independent Counsel shall be selected by Indemnitee (unless Indemnitee shall request that such selection be made by the Board, in which event the preceding sentence shall apply), and Indemnitee shall give written notice to the Company advising it of the identity of the Independent Counsel so selected. In either event, Indemnitee or the Company, as the case may be, may, within ten (10) days after such written notice of selection shall have been given, deliver to the Company or to Indemnitee, as the case may be, a written objection to such selection; provided, however, that such objection may be asserted only on the ground that the Independent Counsel so selected does not meet the requirements of "Independent Counsel" as defined in Section 1 of this Agreement, and the objection shall set forth with particularity the factual basis of such assertion. If such written objection is so made and substantiated, the Independent Counsel so selected may not serve as Independent Counsel unless and until such objection is withdrawn or a court has determined that such objection is without merit. If, within 20 days after submission by Indemnitee of a written request for indemnification pursuant to Section 4(a) hereof, no Independent Counsel shall have been selected and not objected to, either the Company or Indemnitee may petition any court of competent jurisdiction for resolution of any objection which shall have been made by the Company or Indemnitee to the other's selection of Independent Counsel and/or for the appointment as Independent Counsel of a person selected by the court or by such other person as the court shall designate, and the person with respect to whom all objections are so resolved or the person so appointed shall act as Independent Counsel under Section 4(b) hereof. The Company shall pay any and all reasonable fees and Expenses of Independent Counsel incurred by such Independent Counsel in connection with acting pursuant to Section 4(b) hereof, and the Company shall pay all reasonable fees and Expenses incident to the procedures of this Section 4(c), regardless of the manner in which such Independent Counsel was selected or appointed. Upon the due commencement of any judicial proceeding or arbitration pursuant to Section 4(d) of this Agreement, Independent Counsel shall be discharged and relieved of any further responsibility in such capacity (subject to the applicable standards of professional conduct then prevailing).

  • WAIVER OF CLAIMS AND INDEMNITY AGREEMENT In consideration of the Releasees accepting my application for a Season Pass and permitting my use of the lifts, ski runs, trails, terrain parks, race courses, restaurants, day lodge, parking, access roads and other ski area facilities (hereinafter “the premises”), I hereby agree as follows:

  • Litigation; Claims Any rights (including indemnification) and claims and recoveries under litigation of Seller against third parties arising out of or relating to events prior to the Closing Date;

  • Indemnification Proceedings In the event that any claim or demand for which a party (an “Indemnifying Party”), would be liable to the another party under Section 11.2 or Section 11.3 (an “Indemnified Party”) is asserted against or sought to be collected from an Indemnified Party by a third party, the Indemnified Party shall with reasonable promptness notify the Indemnifying Party of such claim or demand, but the failure so to notify the Indemnifying Party shall not relieve the Indemnifying Party of its obligations under this Article XI, except to the extent the Indemnifying Party demonstrates that the defense of such claim or demand is materially prejudiced thereby. The Indemnifying Party shall have 30 days from receipt of the above notice from the Indemnified Party (in this Section 11.5, the “Notice Period”) to notify the Indemnified Party whether or not the Indemnifying Party desires, at the Indemnifying Party’s sole cost and expense, to defend the Indemnified Party against such claim or demand; provided, that the Indemnified Party is hereby authorized prior to and during the Notice Period to file any motion, answer or other pleading that it shall deem necessary or appropriate to protect its interests or those of the Indemnifying Party and not prejudicial to the Indemnifying Party. If the Indemnifying Party elects to assume the defense of any such claim or demand, the Indemnified Party shall have the right to employ separate counsel at its own expense and to participate in the defense thereof. If the Indemnifying Party elects not to assume the defense of such claim or demand (or fails to give notice to the Indemnified Party during the Notice Period), the Indemnified Party shall be entitled to assume the defense of such claim or demand with counsel of its own choice, at the expense of the Indemnifying Party. If the claim or demand is asserted against both the Indemnifying Party and the Indemnified Party and based on the advice of counsel reasonably satisfactory to the Indemnifying Party it is determined that there is a conflict of interest which renders it inappropriate for the same counsel to represent both the Indemnifying Party and the Indemnified Party, the Indemnifying Party shall be responsible for paying separate counsel for the Indemnified Party; provided, however, that the Indemnifying Party shall not be responsible for paying for more than one separate firm of attorneys to represent all of the Indemnified Parties, regardless of the number of Indemnified Parties. If the Indemnifying Party elects to assume the defense of such claim or demand, (i) no compromise or settlement thereof may be effected by the Indemnifying Party without the Indemnified Party’s written consent (which shall not be unreasonably withheld) unless the sole relief provided is monetary damages that are paid in full by the Indemnifying Party and (ii) the Indemnifying Party shall have no liability with respect to any compromise or settlement thereof effected without its written consent (which shall not be unreasonably withheld).

  • Certain Litigation Matters The Owner Trustee shall provide prompt written notice to the Depositor, the Seller and the Servicer of any action, proceeding or investigation known to the Owner Trustee that could reasonably be expected to adversely affect the Trust or the Owner Trust Estate.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!