Payment Delay Notwithstanding any other terms of this Agreement, no payments will be made to CONTRACTOR until COUNTY is satisfied that work of such value has been rendered pursuant to this Agreement. However, COUNTY will not unreasonably withhold payment and, if a dispute exists, the withheld payment shall be proportional only to the item in dispute.
Act of God Days A. Scheduled days of student instruction which are not held because of conditions not within the control of school authorities, such as inclement weather, fires, epidemics, mechanical breakdowns, or health conditions (as defined by city, county, or state health authorities) will be rescheduled to ensure that there are a minimum number of days of student instruction as prescribed by Michigan law.
Operation Delays STATE shall have the authority to delay or suspend the operations of PURCHASER and contractors of PURCHASER, wholly or in part, under this contract for such period or periods necessary due to fire hazard conditions, severe weather occurrence, surveying for threatened or endangered species listed under the state or federal Endangered Species Act, or any other activity STATE determines to be necessary for identification, management, or protection of a threatened or endangered species. PURCHASER agrees to cooperate with surveying efforts of STATE or its contractors. In no event shall STATE be liable for any costs incurred by PURCHASER by reason of delay or suspension under this section, including but not limited to costs of additional move-in/move-out of equipment and personnel, extra fire and equipment security, and insurance or bonding expenses.
Concurrent Delay When the completion of the Work is simultaneously delayed by an excusable delay and a delay arising from a cause not designated as excusable, Contractor may not be entitled to a time extension for the period of concurrent delay.
Epidemic Failure Warranty Supplier warrants all Products against Epidemic Failure for a period of three years after DXC’s Acceptance. Epidemic Failure means the occurrence of the same failure, defect, or non-conformity with an Order in 2% or more of Products within any three-month period.
Industrial Accident Leave 5.8.1 Unit Members will be entitled to industrial accident leave according to the provision in Education Code Section 87787 for personal injury which has qualified for Worker's Compensation under the provisions of the State Compensation Insurance Fund.
Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:
Post-Accident a. The City may require a covered employee who was involved in an event that meets any of the following criteria to submit to drug and/or alcohol testing:
