Execution of the Project (a) The Recipient declares its commitment to the objectives of the Project as set forth in Schedule 2 to this Agreement, and, to this end, shall carry out the Project through its MoE with due diligence and efficiency and in conformity with appropriate financial, economic, environmental and administrative practices, and shall provide, promptly as needed, the funds, facilities, services and other resources required for the Project. (b) Without limitation upon the provisions of paragraph (a) of this Section and except as the Recipient and the Association shall otherwise agree, the Recipient shall carry out the Project in accordance with the Implementation Program set forth in Schedule 4 to this Agreement. (a) Except as the Association shall otherwise agree, procurement of the goods, works and consultants’ services required for the Project and to be financed out of the proceeds of the Grant shall be governed by the provisions of Schedule 3 to this Agreement, as said provisions may be further elaborated in the Procurement Plan. (b) The Recipient shall update the Procurement Plan in accordance with terms of reference acceptable to the Association, and furnish such update to the Association not later than twelve (12) months after the date of the preceding Procurement Plan, for the Association’s approval. Section 3.03. Without limitation upon any of its obligations under paragraph (a) of Section 3.01 of this Agreement and except as the Recipient and the Association shall otherwise agree, the Recipient shall: (i) not later than by the effectiveness of this Agreement open a separate project account (the Project Account) in a commercial bank acceptable to the Association; (ii) thereafter maintain the Project Account during the entire Project implementation period, and replenish said Account regularly with funds sufficient to ensure the Recipient’s Project co-financing obligations; and (iii) use the amount in the Project Account exclusively for financing the Recipient’s contribution to Project expenditures. Section 3.04. For the purposes of Section 6.09 of the General Conditions and without limitation thereto, the Recipient shall: (a) prepare, on the basis of guidelines acceptable to the Association, and furnish to the Association not later than six (6) months after the Closing Date or such later date as may be agreed for this purpose between the Recipient and the Association, a plan designed to ensure the continued achievement of the Project’s objectives; and (b) afford the Association a reasonable opportunity to exchange views with the Recipient on said plan.
Collateral in the Possession of a Bailee If any Inventory or other Goods are at any time in the possession of a bailee, such Assignor shall promptly notify the Collateral Agent thereof and, if requested by the Collateral Agent, shall use its commercially reasonable efforts to promptly obtain an acknowledgment from such bailee, in form and substance reasonably satisfactory to the Collateral Agent, that the bailee holds such Collateral for the benefit of the Collateral Agent and shall act upon the instructions of the Collateral Agent, without the further consent of such Assignor. The Collateral Agent agrees with such Assignor that the Collateral Agent shall not give any such instructions unless an Event of Default has occurred and is continuing or would occur after taking into account any action by the respective Assignor with respect to any such bailee.
Possession of the Property The Parties hereby agree that the exclusive possession of the Property shall be delivered by the Seller to the Buyer on
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Establishment of Escrow Accounts; Deposits in Escrow Accounts The Company shall segregate and hold all funds collected and received pursuant to each Mortgage Loan which constitute Escrow Payments separate and apart from any of its own funds and general assets and shall establish and maintain one or more Escrow Accounts. The Escrow Account shall be an Eligible Account. Funds deposited in each Escrow Account shall at all times be insured in a manner to provide maximum insurance under the insurance limitations of the FDIC, or must be invested in Permitted Investments. Funds deposited in the Escrow Account may be drawn on by the Company in accordance with Section 4.07. The creation of any Escrow Account shall be evidenced by a letter agreement in the form shown in Exhibit C. The original of such letter agreement shall be furnished to the Purchaser on the Closing Date, and upon request to any subsequent purchaser. The Company shall deposit in the Escrow Account or Accounts on a daily basis, and retain therein: (i) all Escrow Payments collected on account of the Mortgage Loans, for the purpose of effecting timely payment of any such items as required under the terms of this Agreement; (ii) all Insurance Proceeds which are to be applied to the restoration or repair of any Mortgaged Property; and (iii) all Servicing Advances for Mortgagors whose Escrow Payments are insufficient to cover escrow disbursements. The Company shall make withdrawals from the Escrow Account only to effect such payments as are required under this Agreement, and for such other purposes as shall be as set forth or in accordance with Section 4.07. The Company shall be entitled to retain any interest paid on funds deposited in the Escrow Account by the depository institution other than interest on escrowed funds required by law to be paid to the Mortgagor and, to the extent required by law, the Company shall pay interest on escrowed funds to the Mortgagor notwithstanding that the Escrow Account is non-interest bearing or that interest paid thereon is insufficient for such purposes. The Purchaser shall not be responsible for any losses suffered with respect to investment of funds in the Escrow Account.
Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.
Deposits in the Escrow Account During the Escrow Period, persons subscribing to purchase Shares will be instructed by the Company, the Dealer Manager and the Selected Dealers to make checks for subscriptions payable to the order of “UMB Bank, N.A., as Escrow Agent for Terra Income Fund 6, Inc.” When a Selected Dealer’s internal supervisory procedures are conducted at the site at which the subscription agreement and check were initially received by the Selected Dealer from the subscriber, the Selected Dealer shall transmit the subscription agreement and check to the Escrow Agent by the end of the next business day following receipt of the check and subscription agreement. When, pursuant to the Selected Dealer’s internal supervisory procedures, the Selected Dealer’s final internal supervisory procedures are conducted at a different location (the “Final Review Office”), the Selected Dealer shall transmit the check and subscription agreement to the Final Review Office by the end of the next business day following the Selected Dealer’s receipt of the subscription agreement and check. The Final Review Office will, by the end of the next business day following its receipt of the subscription agreement and check, forward both the subscription agreement and check to the Escrow Agent. If any subscription agreement solicited by the Selected Dealer is rejected by the Dealer Manager or the Company, then the subscription agreement and check will be returned to the rejected subscriber within ten business days from the date of rejection. The Escrow Agent shall have no liability or responsibility regarding a Selected Dealer’s internal supervisory procedures. Completed subscription agreements and checks in payment for the purchase price shall be remitted to the Escrow Agent’s address in Exhibit B designated for the receipt of such agreements and funds, and wires or Automated ClearingHouse (ACH) payments shall be transmitted directly to the Escrow Account. Subscription agreements received by the Escrow Agent shall be scanned and emailed by the Escrow Agent to DST Systems, Inc. the "Transfer Agent") within 24 hours of receipt by the Escrow Agent. The Escrow Agent shall also deliver the original subscription agreements to the Transfer Agent. Deposits shall be held in the Escrow Account until such funds are disbursed in accordance with this Agreement. Prior to disbursement of the funds deposited in the Escrow Account (the "Escrowed Funds"), such funds shall not be subject to claims by creditors of the Company or any of its affiliates. If any of the instruments of payment are returned to the Escrow Agent for nonpayment prior to receipt of the Break Escrow Affidavit (as described below), the Escrow Agent shall promptly notify the Company in writing via mail, email or facsimile of such nonpayment, and the Escrow Agent is authorized to debit the Escrow Account in the amount of such returned payment and the Escrow Agent shall delete the appropriate account from the records maintained by the Escrow Agent. The Escrow Agent will maintain a written account of each sale, which account shall set forth, among other things, the following information: (i) the subscriber’s name and address, (ii) the subscriber’s social security number or tax identification number, (iii) the number of Shares purchased by such subscriber, (iv) the amount paid by such subscriber for such Shares and (v) the state of residence. During the Escrow Period, neither the Company nor the Dealer Manager will be entitled to any principal funds received into the Escrow Account.
Operation of the Property Between June 1, 1998 and the Closing Date, Seller shall (a) lease, operate, manage and enter into contracts with respect to the Property, in the same manner done by Seller prior to the date hereof (provided, however, that without the prior consent of Purchaser, which as to (i) and (ii) shall not be unreasonably delayed, conditioned or withheld, (i) Seller shall not enter into any Service Contract that cannot be terminated with thirty (30) days notice or materially modify any existing Service Contracts to be assumed by Purchaser at Closing, and (ii) after June 1, 1998, Seller shall not materially modify or terminate any existing Tenant Lease or grant any material consents under any existing Tenant Lease (except as otherwise required pursuant to the terms and conditions of such Tenant Lease), or enter into any new Tenant Lease, and (iii) Seller shall not apply any then unapplied Deposits (as reflected on the Rent Roll delivered by Seller to Purchaser pursuant to Schedule 5.3(vii) hereof) under Tenant Leases); and (b) advise Purchaser of the commencement of any litigation, condemnation or other judicial or administrative proceedings affecting the Property of which Seller has current actual knowledge. Notwithstanding anything to the contrary set forth in this Contract, Purchaser acknowledges that after June 1, 1998 and prior to Closing, Seller will enter into contracts for the completion of Tenant improvements under Tenant Leases entered into after June 1, 1998 pursuant to the terms of Section 12.1 hereof (collectively, the "Tenant Finish Contracts"). Purchaser and Seller agree that at Closing, Purchaser shall assume the obligations of Seller under all such Tenant Finish Contracts including, without limitation, the obligations to pay any costs and expenses charged with respect to construction of improvements in the space subject to such Tenant Leases. At Closing, Purchaser shall execute and deliver to the Seller an Assignment, Assumption and Indemnity Agreement in the form attached hereto as Exhibit H and made a part hereof for all purposes.
Possession and Assembly of Collateral Secured Party may, without notice, demand or initiate legal process of any kind, take possession of any or all of the Collateral (in addition to Collateral of which Secured Party already has possession), wherever it may be found, and for that purpose may pursue the same wherever it may be found, and may at any time enter into any of Grantor's premises where any of the Collateral may be or is supposed to be, and search for, take possession of, remove, keep and store any of the Collateral until the same shall be sold or otherwise disposed of and Secured Party shall have the right to store and conduct a sale of the same in any of Grantor's premises without cost to Secured Party. At Secured Party's request, Grantor will, at Grantor’s sole expense, assemble the Collateral and make it available to Secured Party at a place or places to be designated by Secured Party which is reasonably convenient to Secured Party and Grantor.
Escrow Accounts An account maintained in The Bahamas established in connection with any of the following: 1. A court order or judgment. 2. A sale, exchange, or lease of real or personal property, provided that the account satisfies the following requirements: a) The account is funded solely with a down payment, xxxxxxx money, deposit in an amount appropriate to secure an obligation directly related to the transaction, or a similar payment, or is funded with a financial asset that is deposited in the account in connection with the sale, exchange, or lease of the property; b) The account is established and used solely to secure the obligation of the purchaser to pay the purchase price for the property, the seller to pay any contingent liability, or the lessor or lessee to pay for any damages relating to the leased property as agreed under the lease; c) The assets of the account, including the income earned thereon, will be paid or otherwise distributed for the benefit of the purchaser, seller, lessor, or lessee (including to satisfy such person’s obligation) when the property is sold, exchanged, or surrendered, or the lease terminates; d) The account is not a margin or similar account established in connection with a sale or exchange of a financial asset; and e) The account is not associated with a credit card account. 3. An obligation of a Financial Institution servicing a loan secured by real property to set aside a portion of a payment solely to facilitate the payment of taxes or insurance related to the real property at a later time. 4. An obligation of a Financial Institution solely to facilitate the payment of taxes at a later time.
