Sale of Premises by Landlord In the event of any sale of the Building, Landlord shall be and is hereby entirely freed and relieved of all liability under any and all of its covenants and obligations contained in or derived from this Lease arising out of any act, occurrence or omission occurring after the consummation of such sale; and the purchaser, at such sale or any subsequent sale of the Premises shall be deemed, without any further agreement between the parties or their successors in interest or between the parties and any such purchaser, to have assumed and agreed to carry out any and all of the covenants and obligations of the Landlord under this Lease.
Sublease Term The term of the Sublease (“Sublease Term”) commences on the later to occur of (1) Sublandlord’s receipt of Prime Landlord’s written consent to this Sublease, and (2) October 1, 2009 (“Sublease Commencement Date”); and expires on January 28, 2018 (“Sublease Expiration Date”; i.e., the day prior to the Termination Date pursuant to the Prime Lease). Sublandlord shall deliver the Subleased Premises “broom clean” and free of all of Sublandlord’s personal property (other than the F&F (defined in Section 2(f))) and debris, but otherwise in “AS IS, WHERE IS” condition on the Sublease Commencement Date; provided that Subtenant shall not be responsible for, or required to remedy, any violation of any applicable law, or any condition or state of facts, with respect to the Subleased Premises, the Building or the Land existing on or prior to the Sublease Commencement Date. Sublandlord is not required to perform any work to prepare the Subleased Premises for Subtenant’s intended use. If (i) for any reason Sublandlord has not received Prime Landlord’s written consent to this Sublease in form required by Section 15(i) below by the date which is sixty (60) days from the date hereof, or (ii) Prime Landlord elects to terminate the Prime Lease in respect of the Subleased Premises pursuant to Prime Landlord’s recapture right set forth in Section 16.5 of the Prime Lease, then in the case of (i), then Sublandlord and Subtenant each may elect at any time thereafter to terminate this Sublease by written notice to the other, whereupon the parties shall deem this Sublease to be null and void and of no effect (except for those provisions expressly stated herein to survive a termination), and in the case of (ii) the Sublease will be deemed terminated in accordance with Section 16.5 of the Prime Lease.
Expansion Premises In addition to the Original Premises, commencing on the Expansion Premises Commencement Date (as defined below), Landlord leases to Tenant, and Tenant leases from Landlord, the Expansion Premises.
Lease Provisions (a) No later than four (4) months prior to the date rehabilitation of the Development is projected to be complete, Borrower shall submit to the County for approval Borrower’s proposed form of lease agreement for the County's review and approval. When leasing Units within the Development, Borrower shall use the form of lease approved by the County. Borrower may not permit the lease to contain any provision that is prohibited by 24 C.F.R. Section 92.253(b) and any amendments thereto. Borrower’s form of lease must include any provisions necessary to comply with the requirements of the Violence Against Women Reauthorization Act of 2013 (Pub. L. 113–4, 127 Stat. 54) applicable to HUD-funded programs. The form of lease must comply with all requirements of this HOME Regulatory Agreement, the other Loan Documents and must, among other matters: (1) provide for termination of the lease for failure to: (i) provide any information required under this HOME Regulatory Agreement or reasonably requested by Borrower to establish or recertify the Tenant's qualification, or the qualification of the Tenant's household, for occupancy in the Development in accordance with the standards set forth in this HOME Regulatory Agreement, or (ii) qualify as a Very Low Income Household as a result of any material misrepresentation made by such Tenant with respect to the income computation; (2) be for an initial term of not less than one (1) year, unless by mutual agreement between the Tenant and Borrower, and provide for no increase in Rent during such year. After the initial year of tenancy, the lease may be month-to-month by mutual agreement of Borrower and the Tenant. Notwithstanding the above, any rent increases are subject to the requirements of Section 2.3 above; and (3) include a provision that requires a Tenant who is residing in a Unit required to be accessible pursuant to Section 3.9(b) of the Loan Agreement, and who is not in need of an accessible Unit to move to a non-accessible Unit when a non-accessible Unit becomes available and another Tenant or prospective Tenant is in need of an accessible Unit. (b) During the HOME Term, Borrower shall comply with the Marking Plan and Tenant Selection Plan approved by the County.
Use of the Leased Premises (a) Lessor, in consideration of the rents to be paid and covenants herein contained, hereby leases to Lessee the Leased Premises. (b) Lessee may use the Leased Premises for the operation of the station, and, in connection therewith, for the installation, repair, maintenance, operation, housing and removal of its Improvements and other related broadcasting equipment (together comprising the “Installations”). Lessee is fully familiar with the physical condition of the Land and has received the same in good order and condition, and agrees that the Land complies in all respects with all requirements of this Agreement. Lessee shall use the Land exclusively for purposes associated with the operation of the station. (c) Lessee shall have the right from time to time to substitute Installations of similar kind and character for those hereinabove specified, including without limitation, the rebuilding and reconfiguring of the towers on the Real Property, provided such changes shall be approved in advance by Lessor, and Lessor shall not unreasonably delay or withhold its approval. In the event Lessee submits any such changes for Lessor’s approval and Lessor does not respond within thirty (30) days after Lessor’s receipt thereof, then such changes shall be deemed approved by Lessor, so long as such changes otherwise comply with this Agreement. (d) Lessee shall have access to the Leased Premises twenty-four (24) hours per day, seven (7) days per week, for the purpose of installing, maintaining and repairing its Installations, provided that the contractors performing such work are reasonably acceptable to Lessor. (e) Lessor shall not be responsible for repairs or maintenance to the Installations, except for repairs occasioned by the negligence of Lessor, its agents, employees or contractors. (f) Lessee shall not use or permit the Leased Premises to be used by any dangerous, toxic, noxious or offensive trade or business, or for any unlawful purpose. (g) Lessee shall not directly or indirectly create or permit to be created or to remain, and will discharge any mortgage, lien, security interest, encumbrance or charge on, pledge of or conditional sale or other title retention agreement with respect to the Real Property or any part thereof or Lessee’s interest therein other than (i) this Agreement, (ii) any lien, including a mortgage on the leasehold interest of Lessee, which may be approved by the Lessor in writing, which approval shall not be unreasonably withheld, (iii) liens for impositions not yet payable, or payable without the addition of any fine, penalty, interest or cost for non-payment, or being contested as permitted by Paragraph 3(d), below, and (iv) liens of mechanics, materialmen, suppliers or vendors, or rights thereto, incurred in the ordinary course of business for sums which under the terms of the related contracts are not at the time due, provided that adequate provision for the payment thereof shall have been made.
Lease of Premises Landlord hereby demises and leases to Tenant for the Term of this Lease and upon the terms and conditions hereinafter set forth, and Tenant hereby accepts from Landlord, the Premises.
Expansion of Premises (a) Effective as of the Expansion Date the Premises (and the definition of the “Premises”) shall be modified to mean and include both the Initial Premises and the Expansion Premises. As a result of such expansion, effective upon the Expansion Date, the deemed square footage of the Premises shall be and become 31,684 square feet and Tenant’s Prorata Share and Tenant’s Share of Expenses and Real Estate Taxes shall be one hundred percent (100.00%). (b) If Landlord, for any reason whatsoever, cannot deliver possession of the Expansion Premises to Tenant on before August 1, 2012 for the purpose specified in Section 3(c), this Amendment shall not be void or voidable, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and Tenant shall have no obligation to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises until the day following the date on which possession of the Expansion Premises is delivered to Tenant (such date thereupon becoming the “Expansion Date” for purposes of this Amendment). Notwithstanding the foregoing, if Landlord is unable to deliver the Expansion Premises by August 1, 2012 (as extended day-for-day for each day of Force Majeure Delay) (the “Expansion Premises Outside Delivery Date”), then Tenant shall have the right, as its sole remedy, to terminate this Amendment to Lease by providing written notice to Landlord within fifteen (15) business days following the Expansion Premises Outside Delivery Date, in which event the Lease shall continue in full force and effect as if the parties had not entered into this Amendment and Landlord shall promptly return to Tenant the August, 2012 Base Rent for the Expansion Premises paid by Tenant pursuant to the provisions of Section 6(d). For purposes hereof, the failure of the existing tenant of the Expansion Premises to vacate the Expansion Premises shall not be an event of Force Majeure Delay. (c) Notwithstanding the above, Tenant shall be entitled to early occupancy of the Expansion Premises at any time after the Expansion Premises Delivery Date for the sole purposes of (1) installing Tenant’s furniture and telephone and other communications cabling and (2) performing Tenant’s Expansion Work (defined below), provided that (i) Tenant covenants and agrees that Tenant and Tenant’s employees, agents or contractors will cooperate with Landlord to coordinate the performance and completion of the Landlord’s Expansion Work concurrently with Tenant’s Expansion Work, (ii) Landlord shall have no liability to Tenant for delays in completing the Landlord’s Expansion Work which result from, are caused by or arise out of the interference by Tenant or Tenant’s employees, agents or contractors in the performance of the Landlord’s Expansion Work, (iii) Tenant and Tenant’s employees, agents and contractors shall promptly comply with any and all requests made by Landlord or Landlord’s contractor(s) that Tenant remove its property from those areas in or around which Landlord is performing the Landlord’s Expansion Work, and (iv) Landlord shall not be liable for, Tenant hereby waives all claims which Tenant may have against the Landlord Parties, and Tenant shall indemnify and hold harmless Landlord from and defend Landlord against any and all claims or liability for any injury or damage to any person or property in or about the Expansion Premises resulting from or arising out of or in connection with the performance of Tenant’s Expansion Work (except to the extent arising from the negligence or willful misconduct of Landlord). Tenant’s early occupancy of the Expansion Premises for the sole purpose provided in this Section shall be subject to all of the terms and conditions of the Lease, provided that (x) the Premises shall not include the Expansion Premises until the Expansion Date, and (y) Tenant shall not be obligated to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises for the period from the Expansion Premises Delivery Date until the Expansion Date. (d) Within five (5) business days after the Expansion Date, the parties shall execute a letter confirming the Expansion Date and certifying that Tenant has accepted delivery of the Premises, in form substantially similar to EXHIBIT “D” attached to the Lease (the “Expansion Date Memorandum”). Either party’s failure to request execution of, or to execute, the Expansion Date Memorandum shall not in any way alter the Expansion Date.
Lease Terms 8.1. The Tenant must observe and perform all conditions and covenants that apply to the Allotment Site contained in any lease under which the Council hold the Allotment Site.
Use of Premises Tenant shall not use the premises or any part thereof, or permit the premises or any part thereof to be used, for any purpose other than the use hereinabove specifically mentioned, subject, however, to all the covenants, agreements, terms, provisions and conditions of this Lease. Those portions, if any, of the premises which on the plan(s) attached hereto are shown as toilets and utility areas shall be used by Tenant only for the purposes for which they are designed. Tenant will not at any time use or occupy the premises or any part thereof, or permit the premises or any part thereof to be used or occupied, in violation of the certificate of occupancy (temporary or final) issued for the Building and/or the premises. Tenant shall not xxx or permit the use of the premises or any part thereof in any way which would violate any of the covenants, agreements, terms, provisions and conditions of this Lease or for any unlawful purposes or in any unlawful manner and Tenant shall not suffer or permit the premises or any part thereof to be used in any manner or anything to be done therein or suffer or permit anything to be brought into or kept in the premises which, in the judgment of Landlord, shall in any way impair or tend to impair the character, reputation or appearance of the Building as a first-class office building, impair or interfere with or tend to impair or interfere with any of the Building services or the proper and economic heating, cleaning, air conditioning or other servicing of the Building or the premises, or impair or interfere with or tend to impair or interfere with the use of any of the other areas of the Building by, or occasion discomfort, inconvenience or annoyance to, any of the other tenants or occupants of the Building. Tenant shall not install any electrical or other equipment of any kind which, in the judgment of Landlord, might cause any such impairment, interference, discomfort, inconvenience or annoyance. Except as set forth in Article 1 hereof, Tenant will not, and will not permit anyone to, sell or traffic in any spirituous liquors, wine, ale or beer in or from the premises or carry on any manufacturing in the premises. If any governmental license or permit shall be required for the proper and lawful conduct of Tenant's business or other activity carried on it the premises, Tenant, at Tenant's expense, shall duly procure and thereafter maintain such license or permit and submit the same to inspection by Landlord. Tenant, at Tenant's expense, shall, at all times, comply with the terms and conditions of each license or permit.
USE OF LEASED PREMISES The Lessor is leasing the Premises to the Lessee and the Lessee is hereby agreeing to lease the Premises for the following use and purpose: Any change in use or purpose the Premises other than as described above shall be upon prior written consent of Lessor only.
