Landlord Obligations Tenant Delay
Landlord Obligations Tenant Delay Sample Clauses
Related to Landlord Obligations Tenant Delay
Landlord Obligations Landlord acknowledges and agrees that certain of the information contained in the Financial Statements may be non-public financial or operational information with respect to Tenant and/or the Leased Property. Landlord further agrees (i) to maintain the confidentiality of such non-public information; provided, however, that notwithstanding the foregoing and notwithstanding anything to the contrary in Section 23.2(a) hereof or otherwise herein, Landlord shall have the right to share such information with GLP and their respective officers, employees, directors, Facility Mortgagee, agents and lenders party to material debt instruments entered into by GLP or Landlord, actual or prospective arrangers, underwriters, investors or lenders with respect to Indebtedness or Equity Interests that may be issued by GLP or Landlord, rating agencies, accountants, attorneys and other consultants (the “Landlord Representatives”), provided that such Landlord Representative is advised of the confidential nature of such information and agrees, to the extent such information is not publicly available, to maintain the confidentiality thereof pursuant to Section 23.2(a) or pursuant to confidentiality provisions substantially similar thereto and to comply with all federal, state and other securities laws applicable with respect to such information and (ii) that neither it nor any Landlord Representative shall be permitted to engage in any transactions with respect to the stock or other equity or debt securities or syndicated loans of Tenant or Tenant’s Parent based on any such non-public information provided by or on behalf of Landlord or GLP (provided that this provision shall not govern the provision of information by Tenant or Tenant’s Parent). In addition to the foregoing, Landlord agrees that, upon request of Tenant, it shall from time to time provide such information as may be reasonably requested by Tenant with respect to Landlord’s capital structure and/or any financing secured by this Master Lease or the Leased Property in connection with Tenant’s review of the treatment of this Master Lease under GAAP. In connection therewith, Tenant agrees to maintain the confidentiality of any such non-public information; provided, however, Tenant shall have the right to share such information with Tenant’s Parent and their respective officers, employees, directors, Permitted Leasehold Mortgagees, agents and lenders party to material debt instruments entered into by Tenant or Tenant’s Parent, actual or prospective arrangers, underwriters, investors or lenders with respect to Indebtedness or Equity Interests that may be issued by Tenant or Tenant’s Parent, rating agencies, accountants, attorneys and other consultants (the “Tenant Representatives”) so long as such Tenant Representative is advised of the confidential nature of such information and agrees, to the extent such information is not publicly available, (i) to maintain the confidentiality thereof pursuant to Section 23.2(a) or pursuant to confidentiality provisions substantially similar thereto and to comply with all federal, state and other securities laws applicable with respect to such information and (ii) not to engage in any transactions with respect to the stock or other equity or debt securities or syndicated loans of GLP or Landlord based on any such non-public information provided by or on behalf of Tenant or Tenant’s Parent (provided that this provision shall not govern the provision of information by Landlord or GLP).
Landlord Delay Landlord’s (a) failure to comply with any time requirements expressly set forth in Paragraph 2.d. above with respect to Landlord’s obligation to provide notice of approval or disapproval of the Space Plan, Working Drawings or Change Orders, or (b) Landlord’s unreasonable interference with the completion of Tenant Improvements, including any failure or refusal of Landlord or Landlord’s agents or contractors to permit Tenant, its agents or contractors, access to and use of the Building or any Building facilities or services (including hoists, elevators, and loading docks) which access or use is reasonably required for the orderly and continuous performance of the work necessary to complete Tenant Improvements, are referred to collectively herein as “Landlord Delay” (provided that no Landlord Delay as described in clause (b) above will be deemed to have occurred unless and until Tenant has notified Landlord of the event which Tenant claims constitutes a Landlord Delay and Landlord has failed to cure such event within five (5) Business Days thereafter). Tenant will use commercially reasonable efforts to mitigate its damages and/or construction delays in the event of an alleged Landlord Delay. Notwithstanding anything to the contrary in this Paragraph 2, if and to the extent Tenant reasonably incurs a net increased cost (taking into account any cost saving Landlord might have facilitated by its actions, including any Landlord Delay) of design or construction of the Tenant Improvements as a direct result of any Landlord Delay (as reasonably evidenced by Tenant, with supporting documentation), Landlord will be responsible for such reasonable increased costs and Landlord’s Allowance will be increased by the amount of such reasonable increased cost. Further, when determining whether a particular Landlord Delay delayed Substantial Completion of the Tenant Improvements, the subject Landlord Delay shall be offset by any action or response by Landlord that achieved a reduction in Tenant’s construction schedule (each day saved in Tenant’s construction schedule being a “Schedule Saving Day”) and any aggregate Landlord Delay as described in this Paragraph 2.f. shall first be offset against, and reduced on a day-for-day basis by, the aggregate number of Schedule Saving Days. In the event of a disagreement between Landlord and Tenant as to whether a Landlord Delay has occurred and/or as to the application of this grammatical paragraph, either party may submit the issue to the dispute resolution procedure set forth in Paragraph 2.j. below. This Paragraph 2.f. is inapplicable to delays in Delivery, whether caused by Landlord, Landlord’s Contractor or otherwise (such delays being expressly covered by Paragraph 2.a. above) and this Paragraph 2.f. only applies to delays in the commencement or Substantial Completion of the Tenant Improvements following Delivery.
Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Landlord Work In accordance with the mutually acceptable space plan dated January 4, 2012 prepared by Xxxxxxxx Xxxx Xxxxxxx Architects (the “Approved Plan”) attached hereto, Landlord shall perform the following work (collectively, the “Landlord Work”): · Build out 4 offices · Install a door to connect Suites 205 and 230 · Provide appropriate surfaces and air handling · Investigate the addition of an 8’ hood in lab Landlord shall cause the Landlord Landlord shall use commercially reasonable efforts to cause the Landlord Work to be constructed in a good and workmanlike manner, substantially in accordance with the Approved Plan and in compliance with applicable laws and covenants, conditions and restrictions in effect as of the date of such completion, and in good condition and working order. The Landlord Work shall be performed by Landlord, at Landlord’s sole cost and expense. Tenant shall have the right, on not less than two (2) business days’ advance written notice to Landlord, and, if specified by Landlord at Landlord’s option, accompanied by a representative of Landlord, to inspect the construction of the Landlord Work; provided that no such inspections shall interfere with or otherwise delay Landlord’s completion of the Landlord Work. Tenant shall have the right to submit to Landlord a list of incomplete or defective items within sixty (60) days after Substantial Completion, and Landlord shall diligently repair or replace such items at Landlord’s sole cost and expense. Landlord shall use commercially reasonable efforts to cause its construction contract for the Landlord Work to contain a minimum one (1) year warranty period. EXHIBIT C ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE THIS ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE is entered into as of [ ], 2012, with reference to that certain Lease dated as of August 24, 2007, as amended by that certain First Amendment to Lease dated as of March 30, 2008, that certain Second Amendment to Lease (“Second Amendment”) dated as of May 11, 2009, which Second Amendment was amended and restated pursuant to that certain Amended and Restated Second Amendment to Lease dated as of September 15, 2009, and that certain Third Amendment to Lease dated as of December [ ], 2011 (“Third Amendment”) (collectively, and as the same may have been further amended, amended and restated, supplemented or modified from time to time, the “Lease”), by RECEPTOS, INC., a Delaware corporation (“Tenant”), in favor of BMR-10835 ROAD TO THE CURE LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease. Tenant hereby confirms the following:
Landlord’s Repair Obligations If this Lease does not terminate with respect to the entire Premises under Section 12.1, and if the Taking includes a portion of the Premises, then this Lease shall automatically terminate as to the portion of the Premises taken as of the date the Condemning Authority takes possession of the portion taken and Landlord will, at its sole cost and expense, restore the remaining portion of the Premises to a complete architectural unit with all commercially reasonable diligence and speed and will reduce the Basic Rent for the period after the date the Condemning Authority takes possession of the portion of the Premises taken to a sum equal to the product of the Basic Rent provided for in this Lease multiplied by a fraction, the numerator of which is the rentable area of the Premises after the Taking and after Landlord restores the Premises to a complete architectural unit, and the denominator of which is the rentable area of the Premises prior to the Taking. Landlord will also equitably adjust Tenant's Share of Expenses Percentage for the same period, subject to Section 3.7, to account for the reduction in the rentable area of the Premises or the Building resulting from the Taking. Tenant's obligation to pay Basic Rent and Tenant's Share of Expenses will xxxxx on a proportionate basis with respect to that portion of the Premises remaining after the Taking that Tenant is unable to use during Landlord's restoration for the period of time that Tenant is unable to use such portion of the Premises.
Tenant’s Repair Obligations Tenant shall keep the Premises in good condition and repair, ordinary wear and tear excepted. Tenant’s repair obligations include, without limitation, repairs to: (1) floor covering and/or raised flooring; (2) interior partitions; (3) doors; (4) the interior side of demising walls; (5) electronic, phone and data cabling and related equipment (collectively, “Cable”) that is installed by or for the benefit of Tenant whether located in the Premises or in other portions of the Building; (6) supplemental air conditioning units, private showers and kitchens, including hot water heaters, plumbing, dishwashers, ice machines and similar facilities serving Tenant exclusively; (7) phone rooms used exclusively by Tenant; (8) Alterations (defined below) performed by contractors retained by Tenant, including related HVAC balancing; and (9) all of Tenant’s furnishings, trade fixtures, equipment and inventory. Prior to performing any such repair obligation, Tenant shall give written notice to Landlord describing the necessary maintenance or repair. Upon receipt of such notice, Landlord may elect either to perform any of the maintenance or repair obligations specified in such notice, or require that Tenant perform such obligations by using contractors approved by Landlord. All work that is Tenant’s responsibility hereunder shall be performed by Tenant (except as otherwise provided herein) at Tenant’s expense in accordance with the rules and procedures described in Section 9.C below. If Tenant fails to make any repairs to the Premises for more than 15 days after notice from Landlord (although notice shall not be required if there is an emergency), Landlord may, in addition to any other remedy available to Landlord, make the repairs, and Tenant shall pay to Landlord the reasonable cost of the repairs within 30 days after receipt of an invoice, together with an administrative charge in an amount equal to 15% of the cost of the repairs.
Landlord’s Default Subject to Landlord's right to dispute its obligation in accordance with Section 5.1.5(b), if Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement, and any such default shall continue for a period of ten (10) days after Notice thereof with respect to monetary defaults, and thirty (30) days after Notice thereof with respect to non-monetary defaults, from Tenant to Landlord and, subject to Section 19.3, any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct such non-monetary defaults, Tenant may declare the occurrence of a "Landlord Default" under this Agreement by giving Notice of such declaration to Landlord and to such Facility Mortgagee. Thereafter, Tenant may (but shall have no obligation to) cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys' fees, paralegals' fees and court costs) incurred by Tenant in curing the same. If any such costs and expenses have not been reimbursed to Tenant as of the fifth (5th) day after the Landlord receives Tenant's Notice therefor, Landlord shall pay to Tenant, a late charge computed at the Overdue Rate on the amount of such reimbursement from the expiration of the applicable cure period to the date of payment thereof. Except as otherwise expressly provided herein to the contrary, Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder or under the Other Leases and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof; provided, however, that in the event of any such adverse determination, Landlord shall pay to Tenant interest on any disputed funds at the Disbursement Rate, from the date demand for such funds was made by Tenant until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. During the term of the Operating Agreement, Landlord shall indemnify and hold Tenant harmless against all claims, costs and expenses (including reasonable attorneys' fees and paralegals' fees) arising from a Landlord Default under the terms and conditions of this Agreement which shall cause an Event of Default under Section 16.01 of the Operating Agreement or a breach by Landlord of its obligations under the Owner Agreement or the Pooling Agreement. The provisions of this Section 14.2 shall survive the termination, expiration or cancellation of this Agreement for a period of five (5) years.
Landlord’s Work Landlord shall construct the base-building elements of the Building (the "Base Building Work"), the sitework on the Land, and the parking structure and surface parking areas on the Land, all in accordance with the Design Specifications attached hereto as Schedule I (collectively, "Landlord's Work"). All of Landlord's Work shall be performed in a good and workmanlike manner, in accordance with plans and specifications ("Landlord's Plans") mutually approved by Landlord and Tenant. Tenant's approval of Landlord's Plans shall not be unreasonably withheld, conditioned or delayed, and Tenant shall not be entitled to condition its approval of Landlord's Plans upon the inclusion therein of any design specifications that are inconsistent with the Design Specifications attached hereto as Schedule I (including requiring a higher performance standard than any performance standard expressly set forth in Schedule I). Tenant shall respond to any request for approval of Landlord's Plans, or any portion or progress set thereof, or any modifications thereto, as promptly as reasonably possible and in any event within ten (10) business days in the case of the original complete set of Landlord's Plans and any structural modifications thereto and within two (2) business days in the case of any nonstructural modifications to Landlord's Plans, and Tenant's failure to respond within such time periods shall be referred to herein and in the Lease as a "Tenant Delay." In the event Tenant disapproves Landlord's Plans or any portion thereof or any modifications thereto, Tenant's notice of disapproval shall specify in detail the reasonable basis for such disapproval. Landlord shall promptly make such revisions to Landlord's Plans as may be necessary to address Tenant's reasonable objections, and shall resubmit Landlord's Plans to Tenant for Tenant's approval. Tenant shall review such revised plans as promptly as reasonably possible and notify Landlord whether Tenant approves or reasonably disapproves Landlord's Plans as modified. This process shall be repeated, if necessary, until Tenant's reasonable objections to Landlord's Plans have been addressed and Tenant has approved Landlord's Plans. After approval of Landlord's Plans, Tenant shall have the right to initiate changes to Landlord's Plans or Landlord's Work, subject to (i) Landlord's approval of any such proposed change, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) Landlord's and Tenant's mutual agreement concerning (and execution of a change order or other written confirmation of) (A) any net increase in design or construction costs resulting from such change, all of which increased costs shall be borne solely by Tenant, and (B) any delay such change will cause in the completion of Landlord's Work or the achievement of any milestone date(s), which delay shall not extend the Lease Commencement Date or the commencement of Tenant's rental obligations under the Lease (but shall appropriately extend any affected milestone date(s)) and shall be deemed a "Tenant Delay" for purposes hereof and of the Lease. Landlord shall be responsible for causing Landlord's Work to comply with all applicable legal requirements, including (without limitation) requirements of building codes, environmental laws and the Americans with Disabilities Act, and Landlord shall indemnify Tenant and hold it harmless with respect to any loss, cost, damage or liability resulting from Landlord's breach of this obligation (which indemnification shall survive the expiration or termination of the Lease). In constructing the Base Building Work, Landlord shall perform and install all work and materials designated "Base Building" in Schedule II attached hereto. In performing the Base Building Work, Landlord shall use best efforts to achieve the milestone dates set forth in Schedule III attached hereto. In the event Landlord fails to achieve any of said milestone dates, except to the extent such failure is caused by any Tenant Delay, the December 29, 1995 date set forth in Section 3.2 of the Lease shall be extended by one (1) day for each day of delay in achieving the milestone date; provided, however, that such extension shall not occur if (and then only to the extent) Landlord and Tenant mutually agree and acknowledge in writing that the completion of the Tenant Work (as defined below) was not delayed by reason of the delay in achieving Landlord's milestone date. Tenant agrees to use good faith reasonable efforts to counter the effect of any delay by Landlord in achieving any milestone date; however, Tenant shall not be obligated to expend any additional amounts in such efforts (e.g., by employing overtime labor) unless Landlord agrees in advance to bear any incremental cost associated with such efforts (whether or not such efforts are ultimately successful).
Tenant’s Lease Default Notwithstanding any provision to the contrary contained in the Lease, if an event of default by Tenant as described in Section 12.01 of the Lease or any default by Tenant under this Work Letter (which, for purposes hereof, shall include, without limitation, the delivery by Tenant to Landlord of any oral or written, including electronic, notice instructing Landlord to cease the design and/or construction of the Tenant Improvements and/or that Tenant does not intend to occupy the Premises, and/or any other anticipatory breach of the Lease) has occurred at any time on or before the Substantial Completion of the Premises, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to withhold payment of all or any portion of the Tenant Improvement Allowance and/or Landlord may cause Contractor to cease the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as a Tenant Delay as set forth in Section 5.01 above), and (ii) all other obligations of Landlord under the terms of this Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such inaction by Landlord as a Tenant Delay). In addition, if the Lease is terminated prior to the Lease Commencement Date, for any reason due to an event of default by Tenant as described in Section 12.01 of the Lease or under this Work Letter (including, without limitation, any anticipatory breach described above in this Section 6.05), then (A) Tenant shall be liable to Landlord for all damages available to Landlord pursuant to the Lease and otherwise available to Landlord at law and/or in equity by reason of a default by Tenant under the Lease or this Work Letter, and (B) Tenant shall pay to Landlord, as Additional Rent under the Lease, within five (5) Business Days after Tenant’s receipt of a statement therefor, any and all costs incurred by Landlord (including any portion of the Tenant Improvement Allowance disbursed by Landlord) and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant Improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto.
