Landlord’s Default definition

Landlord’s Default under this Lease: Landlord’s failure to perform any obligation required to be performed by Landlord hereunder after (a) Tenant gives written notice to Landlord of such failure, (b) Landlord fails to commence and diligently prosecute the cure of such failure within thirty (30) days (or three (3) days in the event of a failure threatening the health or safety of the occupants of the Building) of such notice, (c) Tenant gives a second written notice to Landlord of such failure and (d) Landlord fails to commence and diligently prosecute the cure of such failure within ten (10) days (or three (3) days in the event of a failure threatening the health or safety of the occupants of the Building) of such second notice; provided, that if the nature of Landlord’s obligation is such that more than the designated time to cure such failure is required to effect such cure, then Landlord shall not be in default so long as Landlord is diligently pursuing such cure to completion. In the event of a Landlord’s Default, Tenant’s sole remedy shall be an action for damages or injunctive relief and the right to cure Landlord’s default at Tenant’s expense and set off against Rent coming due, subject to this Section 19; provided, however, that Tenant shall have no right to terminate or rescind this Lease upon the occurrence of a Landlord’s Default.
Sample 1Sample 2
Landlord’s Default. Landlord shall not be deemed in breach or default of this Lease unless Landlord fails within a reasonable time to perform all obligation required to be performed by Landlord hereunder. For purposes of this provision, a reasonable time shall not be less than thirty (30) days after receipt by Landlord of written notice specifying the nature of the obligation Landlord has not performed; provided, however, that if the nature of Landlord's obligation is such that more than thirty (30) days, after receipt of written notice, is reasonably necessary for its performance, then Landlord shall not be in breach or default of this Lease if performance of such obligation is commenced within such thirty (30) day period and thereafter diligently pursued to completion.
Sample 1
Landlord’s Default means a failure by Landlord to perform or comply with the Landlord’s covenants, agreements or obligations in this Lease, as more specifically set forth in Section 14.
Sample 1

Examples of Landlord’s Default in a sentence

  • In the event of any Landlord’s Default, Tenant shall give written notice thereof to Landlord and to any Interest Holder whose address shall have been furnished to Tenant, such notice to be delivered to said Interest Holder at the same time notice is delivered to Landlord.

  • After Tenant receives notice of a Mortgagee’s name and address and request for notice upon Landlord’s Default, Tenant shall provide the notice required by this paragraph to the Mortgagee at the same time Tenant gives notice to Landlord.

  • If Tenant intends to seek to terminate the Lease because of Landlord’s Default, then Tenant shall give the notices this paragraph requires.

  • Upon Landlord’s Default, Tenant may pursue any remedies given in this Lease or available at law or in equity.

  • This monitoring, together with the signaling properties of the entrepreneur’s willingness to accept such powerful incentives, also serve to reduce information asymmetries.

  • In the event of a Landlord’s Default, Tenant’s sole remedy shall be an action for damages or injunctive relief and the right to cure Landlord’s default at Tenant’s expense and set off against Rent coming due, subject to this Section 19; provided, however, that Tenant shall have no right to terminate or rescind this Lease upon the occurrence of a Landlord’s Default.

  • Subtenant shall look solely to Landlord for all such services and shall not, under any circumstances, seek nor require Sublandlord to perform any of such services, nor shall Subtenant make any claim upon Sublandlord for any damages which may arise by reason of Landlord’s Default under the Master Lease.

  • Either party may be considered in default through the following: Landlord’s Default.

  • Subtenant shall look solely to Landlord for all such services and shall not, under any circumstances, seek nor require Sublandlord to perform any of such services, not shall Subtenant make any claim upon Sublandlord for any damages which may arise by reason of Landlord’s Default under the Master Lease.

  • If Landlord cures the Landlord’s Default by paying the liquidated sum of damages to Tenant, then all of the withheld Base Rent shall be promptly remitted to Landlord.


More Definitions of Landlord’s Default

Landlord’s Default means any failure by the Landlord (or its agents, employees or contractors as the case may be):
Sample 1
Landlord’s Default shall have the meaning set forth in Section 13.6.
Sample 1

Related to Landlord’s Default

  • Landlord Default shall have the meaning given such term in Article 14.

  • Landlord Delay means a delay in the construction of the Tenant Improvements or Compliance Work resulting directly from the acts or omissions of Landlord, Landlord’s employees, agents, or contractors including, but not limited to (i) failure of Landlord to timely approve or disapprove any plans; (ii) interference by Landlord, its employees, agents or contractors with the completion of the Tenant Improvements or Compliance Work (including the impairment of Tenant’s contractors’ or vendors’ or employees’ access to the Premises for any reason (including due to the presence of Landlord’s contractors, vendors or personnel), failure to provide reasonable access to the Building’s loading docks or other facilities necessary for the construction of the Tenant Improvements or Compliance Work and/or the movement of materials and personnel to the Premises for such purpose) and (iii) delays due to the acts or failures to act of Landlord, its agents or contractors with respect to payment of the Tenant Improvement Allowance. If Tenant contends that a Force Majeure Construction Delay or a Landlord Delay has occurred, Tenant acknowledges and agrees that it has inspected the Building and the Site and in no event shall the physical character or condition of the Building and/or Site existing as of the Effective Date constitute a basis for a Landlord Delay (this agreement does not apply to the failure of any Building component to properly operate). Further, in no event shall any delay of Landlord constitute a Landlord Delay unless such delay results in a full day of delay in the construction of the Tenant Improvements or Compliance Work. Tenant shall notify Landlord in writing (the “Delay Notice”) of the event which constitutes such Force Majeure Construction Delay or Landlord Delay; such notice may be via electronic mail to Landlord’s construction representative described above. Tenant will additionally use reasonable efforts to mitigate the effects of any Force Majeure Construction Delay or Landlord Delay through the re-sequencing or re-scheduling of work, if feasible, but this sentence will not be deemed to require Tenant to incur overtime or after-hours costs unless Landlord agrees in writing to bear such costs. If the actions or inactions or circumstances described in the Delay Notice constitute a Landlord Delay, and are not cured by Landlord within one (1) business day after Landlord’s receipt of the Delay Notice, then a Landlord Delay shall be deemed to have occurred commencing as of the expiration of such one (l)-business day period. The Lease Commencement Date and the Lease Expiration Date will each be delayed on a day for day basis for each day of Force Majeure Construction Delay or Landlord Delay.

  • Lease Event of Default shall have the meaning specified in Section 17.1 of the Lease.

  • Lease Default means any event or condition which, with the lapse of time or the giving of notice, or both, would constitute a Lease Event of Default.

  • Lender Default means (a) the refusal or failure (which has not been cured) of a Lender to make available its portion of any Borrowing or to fund its portion of any Unpaid Drawing under Section 3.4 that it is required to make hereunder, (b) a Lender having notified the Administrative Agent and/or the Borrower that it does not intend to comply with its funding obligations under this Agreement or has made a public statement to that effect with respect to its funding obligations under this Agreement, (c) a Lender has failed to confirm (within one Business Day after a request for such confirmation is received by such Lender) in a manner reasonably satisfactory to the Administrative Agent, the Borrower and, in the case of a Revolving Credit Lender, each Revolving Letter of Credit Issuer that it will comply with its funding obligations under this Agreement, (d) a Lender being deemed insolvent or becoming the subject of a bankruptcy or insolvency proceeding or has admitted in writing that it is insolvent; provided that a Lender Default shall not be deemed to have occurred solely by virtue of the ownership or acquisition of any Stock in the applicable Lender or any direct or indirect parent company thereof by a Governmental Authority so long as such ownership interest does not result in or provide the applicable Lender with immunity from the jurisdiction of courts within the United States or from the enforcement of judgments or writs of attachment on its assets or permit the applicable Lender (or such Governmental Authority) to reject, repudiate, disavow or disaffirm any contracts or agreements made with the applicable Lender, or (e) a Lender that has, or has a direct or indirect parent company that has, become the subject of a Bail-In Action.

  • Minor Default means any Event of Default that is not a Major Default.

  • Tenant Delay means an actual delay in the occurrence of the Substantial Completion Date or the Final Completion Date with respect to Landlord’s Work as the result of: (1) any unreasonable delay by Tenant in approving the Plans; (2) any request by Tenant that Landlord delay the commencement or completion of Landlord’s Work for any reason; (3) any request by Tenant to change the Plans after initial approval thereof by Tenant, or the making of any changes to Landlord’s Work requested by Tenant and agreed to by Landlord after initial approval of the Plans by Tenant; (4) any failure by Tenant to respond in writing within seven (7) business days after any written request by Landlord for clarification or interpretation of the Plans or for approval of changes in the Plans deemed necessary by Landlord; or (5) any other act or omission of Tenant or its officers, agents, employees or contractors; Notwithstanding the foregoing, no event shall be deemed to be a Tenant Delay until and unless Landlord has given Tenant written notice (the “Tenant Delay Notice”) advising Tenant (i) that a Tenant Delay is occurring, (ii) of the basis on which Landlord has determined that a Tenant Delay is occurring, and (iii) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay, and Tenant has failed to correct the Tenant Delay specified in the Tenant Delay Notice within forty-eight (48) hours following receipt thereof. No period of time prior to expiration of such 48-hour period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice if Tenant corrects the Tenant Delay specified in the Tenant Delay Notice within such 48-hour period.

  • Major Default means any Event of Default occurring under Sections 4.1(a), 4.1(c), 4.1(l), or 4.1(p).

  • Default means any event which is, or after notice or passage of time or both would be, an Event of Default.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Landlord means the owner, lessor or sublessor of the dwelling unit or the building of which such

  • Additional Rents means amounts payable under any Lease for (i) the payment of additional rent based upon a percentage of the Tenant’s business during a specified annual or other period (sometimes referred to as “percentage rent”), (ii) so-called common area maintenance or “CAM” charges, and (iii) so called “escalation rent” or additional rent based upon such tenant’s allocable share of insurance, real estate taxes or operating expenses or labor costs or cost of living or xxxxxx’x wages or otherwise.

  • O & M Default means any default on the part of the Power Producer for a continuous period of ninety (90) days to (i) operate and/or (ii) maintain (in accordance with Prudent Utility Practices), the Project at all times.

  • Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.

  • Parking space leasing data means the following government data on an application for, or lease of, a parking space: residence address, home telephone number, beginning and ending work hours, place of employment, location of parking space, and work telephone number.

  • Sublandlord means the holder of sublandlord’s interest under this Sublease. In the event of any assignment or transfer of the Sublandlord’s interest under this Sublease, which assignment or transfer may occur at any time during the Term in Sublandlord’s sole discretion, Sublandlord shall be and hereby is entirely relieved of all covenants and obligations of Sublandlord hereunder accruing subsequent to the date of the transfer and it shall be deemed and construed, without further agreement between the parties hereto, that any transferee has assumed and shall carry out all covenants and obligations thereafter to be performed by Sublandlord hereunder. Sublandlord may transfer and deliver the then existing Letter of Credit to the transferee of Sublandlord’s interest under this Sublease, and thereupon Sublandlord shall be discharged from any further liability with respect thereto. In addition. Sublandlord shall comply with all of its obligations as “Tenant” under the Master Lease except to the extent that any such obligation is the obligation of Subtenant pursuant to the terms of this Sublease. Notwithstanding any other term or provision of this Sublease, the liability of Subtenant to Sublandlord for any default in Subtenant’s obligations under this Sublease shall be limited to actual, direct damages, and under no circumstances shall Sublandlord, its partners, members, shareholders, directors, agents, officers, employees, contractors, sublessees, successors and/or assigns be entitled to recover from Subtenant (or otherwise be indemnified by Subtenant) for lost revenues, lost profit or other consequential, special or punitive damages arising in connection with this Sublease for any reason, except for any breach by Subtenant under Section 12 of the Master Lease. Notwithstanding any other term or provision of this Sublease, no personal liability shall at any time be asserted or enforceable against Subtenant’s shareholders, directors, officers, or partners on account of any of Subtenant’s obligations or actions under this Sublease.

  • Master Lease This Schedule is issued pursuant to the Lease identified on page 1 of this Schedule. All of the terms and conditions of the Lease are incorporated in and made a part of this Schedule as if they were expressly set forth in this Schedule. The parties hereby reaffirm all of the terms and conditions of the Lease (including, without limitation, the representations and warranties set forth in Section 8) except as modified herein by this Schedule. This Schedule may not be amended or rescinded except by a writing signed by both parties. CHEMDEX CORPORATION COMDISCO, INC. AS LESSEE AS LESSOR By: /s/ Xxxxx X. Xxxxx By: /s/ Xxxx X. Xxxxxx ------------------- --------------------- Title: CEO Title: SR VP ----------------- ------------------- Date: Date: ----------------- ------------------- EXHIBIT 1 SUMMARY EQUIPMENT SCHEDULE -------------------------- This Summary Equipment Schedule dated XXXX is executed pursuant to Equipment Schedule No. X to the Master Lease Agreement dated XXXX between Comdisco, Inc. ("Lessor") and XXXX ("Lessee"). All of the terms, conditions, representations and warranties of the Master Lease Agreement and Equipment Schedule No. X are incorporated herein and made a part hereof, and this Summary Equipment Schedule constitutes a Schedule for the Equipment on the attached invoices.

  • Tenant means a person entitled under a rental agreement to occupy a dwelling unit to the exclusion of others.

  • Space Lease The space or occupancy lease pursuant to which any Borrower holds a leasehold interest in the related Mortgaged Property, together with any estoppels or other agreements executed and delivered by the lessor in favor of the lender under the related Mortgage Loan(s).

  • Owner Event of Default shall have the meaning set forth in Section 18.3.

  • MI Default has the meaning given to it in paragraph 6.1 of Framework Schedule 9 (Management Information);

  • Additional Rent means all amounts payable by the Tenant under this Lease except Base Rent, whether or not specifically designated as Additional Rent elsewhere in this Lease;

  • Subtenant means any Person entitled to occupy, use, or possess any Premises under a Sublease.

  • Leasehold Mortgagee means the holder of a Leasehold Mortgage.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.