Landlord’s Work Landlord shall construct the base-building elements of the Building (the "Base Building Work"), the sitework on the Land, and the parking structure and surface parking areas on the Land, all in accordance with the Design Specifications attached hereto as Schedule I (collectively, "Landlord's Work"). All of Landlord's Work shall be performed in a good and workmanlike manner, in accordance with plans and specifications ("Landlord's Plans") mutually approved by Landlord and Tenant. Tenant's approval of Landlord's Plans shall not be unreasonably withheld, conditioned or delayed, and Tenant shall not be entitled to condition its approval of Landlord's Plans upon the inclusion therein of any design specifications that are inconsistent with the Design Specifications attached hereto as Schedule I (including requiring a higher performance standard than any performance standard expressly set forth in Schedule I). Tenant shall respond to any request for approval of Landlord's Plans, or any portion or progress set thereof, or any modifications thereto, as promptly as reasonably possible and in any event within ten (10) business days in the case of the original complete set of Landlord's Plans and any structural modifications thereto and within two (2) business days in the case of any nonstructural modifications to Landlord's Plans, and Tenant's failure to respond within such time periods shall be referred to herein and in the Lease as a "Tenant Delay." In the event Tenant disapproves Landlord's Plans or any portion thereof or any modifications thereto, Tenant's notice of disapproval shall specify in detail the reasonable basis for such disapproval. Landlord shall promptly make such revisions to Landlord's Plans as may be necessary to address Tenant's reasonable objections, and shall resubmit Landlord's Plans to Tenant for Tenant's approval. Tenant shall review such revised plans as promptly as reasonably possible and notify Landlord whether Tenant approves or reasonably disapproves Landlord's Plans as modified. This process shall be repeated, if necessary, until Tenant's reasonable objections to Landlord's Plans have been addressed and Tenant has approved Landlord's Plans. After approval of Landlord's Plans, Tenant shall have the right to initiate changes to Landlord's Plans or Landlord's Work, subject to (i) Landlord's approval of any such proposed change, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) Landlord's and Tenant's mutual agreement concerning (and execution of a change order or other written confirmation of) (A) any net increase in design or construction costs resulting from such change, all of which increased costs shall be borne solely by Tenant, and (B) any delay such change will cause in the completion of Landlord's Work or the achievement of any milestone date(s), which delay shall not extend the Lease Commencement Date or the commencement of Tenant's rental obligations under the Lease (but shall appropriately extend any affected milestone date(s)) and shall be deemed a "Tenant Delay" for purposes hereof and of the Lease. Landlord shall be responsible for causing Landlord's Work to comply with all applicable legal requirements, including (without limitation) requirements of building codes, environmental laws and the Americans with Disabilities Act, and Landlord shall indemnify Tenant and hold it harmless with respect to any loss, cost, damage or liability resulting from Landlord's breach of this obligation (which indemnification shall survive the expiration or termination of the Lease). In constructing the Base Building Work, Landlord shall perform and install all work and materials designated "Base Building" in Schedule II attached hereto. In performing the Base Building Work, Landlord shall use best efforts to achieve the milestone dates set forth in Schedule III attached hereto. In the event Landlord fails to achieve any of said milestone dates, except to the extent such failure is caused by any Tenant Delay, the December 29, 1995 date set forth in Section 3.2 of the Lease shall be extended by one (1) day for each day of delay in achieving the milestone date; provided, however, that such extension shall not occur if (and then only to the extent) Landlord and Tenant mutually agree and acknowledge in writing that the completion of the Tenant Work (as defined below) was not delayed by reason of the delay in achieving Landlord's milestone date. Tenant agrees to use good faith reasonable efforts to counter the effect of any delay by Landlord in achieving any milestone date; however, Tenant shall not be obligated to expend any additional amounts in such efforts (e.g., by employing overtime labor) unless Landlord agrees in advance to bear any incremental cost associated with such efforts (whether or not such efforts are ultimately successful).
Landlord Work In accordance with the mutually acceptable space plan dated January 4, 2012 prepared by Xxxxxxxx Xxxx Xxxxxxx Architects (the “Approved Plan”) attached hereto, Landlord shall perform the following work (collectively, the “Landlord Work”): · Build out 4 offices · Install a door to connect Suites 205 and 230 · Provide appropriate surfaces and air handling · Investigate the addition of an 8’ hood in lab Landlord shall cause the Landlord Landlord shall use commercially reasonable efforts to cause the Landlord Work to be constructed in a good and workmanlike manner, substantially in accordance with the Approved Plan and in compliance with applicable laws and covenants, conditions and restrictions in effect as of the date of such completion, and in good condition and working order. The Landlord Work shall be performed by Landlord, at Landlord’s sole cost and expense. Tenant shall have the right, on not less than two (2) business days’ advance written notice to Landlord, and, if specified by Landlord at Landlord’s option, accompanied by a representative of Landlord, to inspect the construction of the Landlord Work; provided that no such inspections shall interfere with or otherwise delay Landlord’s completion of the Landlord Work. Tenant shall have the right to submit to Landlord a list of incomplete or defective items within sixty (60) days after Substantial Completion, and Landlord shall diligently repair or replace such items at Landlord’s sole cost and expense. Landlord shall use commercially reasonable efforts to cause its construction contract for the Landlord Work to contain a minimum one (1) year warranty period. EXHIBIT C ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE THIS ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE is entered into as of [ ], 2012, with reference to that certain Lease dated as of August 24, 2007, as amended by that certain First Amendment to Lease dated as of March 30, 2008, that certain Second Amendment to Lease (“Second Amendment”) dated as of May 11, 2009, which Second Amendment was amended and restated pursuant to that certain Amended and Restated Second Amendment to Lease dated as of September 15, 2009, and that certain Third Amendment to Lease dated as of December [ ], 2011 (“Third Amendment”) (collectively, and as the same may have been further amended, amended and restated, supplemented or modified from time to time, the “Lease”), by RECEPTOS, INC., a Delaware corporation (“Tenant”), in favor of BMR-10835 ROAD TO THE CURE LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease. Tenant hereby confirms the following:
Tenant Improvements Subject to this Section 4, Tenant shall accept the Suite 110 Premises in its “as is” condition (subject to Landlord's continuing repair and maintenance obligations, as outlined in Section 10 of the Lease (as may be amended)), and Landlord shall have no obligation to make any alterations or improvements thereto whatsoever (provided that Landlord shall deliver same in good and tenantable condition, broom clean, with all systems serving same in good working order). Any alterations that Tenant desires to make in the Suite 110 Premises shall be subject to all the terms and conditions set forth in Section 11 of the Lease. Notwithstanding anything in the Lease to the contrary, Landlord hereby agrees to grant Tenant an allowance in the amount of $10,000 to be applied toward the cost (including architectural and engineering fees) of alterations performed by Tenant in the Suite 110 Premises (the “Granted Allowance”) in conjunction with Tenant’s initial occupancy of Suite 110 Premises. Provided no Event of Default then exists under the Lease, the Granted Allowance (or portions thereof) shall be disbursed to Tenant within thirty (30) days following Tenant's submission to Landlord of paid invoices for work related to alterations performed by Tenant in the Suite 110 Premises, accompanied by waivers of liens executed by all contractors employed by Tenant for the performance of such work. If the cost of Tenant's alterations in the Suite 110 Premises exceeds the amount of the Granted Allowance, the excess shall be paid by Tenant after the Granted Allowance is fully exhausted. Any portion of the Granted Allowance that has not been applied (or contracted to be applied) in the manner set forth above by the date which is twelve (12) months following the Eighth Amendment Commencement Date shall revert to Landlord, and Tenant shall have no further rights with respect thereto.
Tenant’s Work During the Term Tenant may not perform any work, alterations, installations, additions, improvements, structural repairs or restorations to the Property (“Tenant’s Work”) without the prior written consent of Landlord which (i) in the case of alterations, additions, installations or improvements of a structural nature or involving the Building systems, may be granted or withheld by Landlord in its sole and absolute discretion and (ii) in the case of alterations or improvements of a non-structural nature or not involving Building systems, shall not be unreasonably withheld or delayed. In connection with such consent, Tenant shall submit to Landlord such detailed plans, specifications, drawings and other materials reasonably requested by Landlord. Tenant may make such non-structural alterations and perform work of a decorative nature without Xxxxxxxx’s prior written consent. At Tenant’s sole cost, Xxxxxxxx agrees to cooperate with Xxxxxx (including signing applications) in obtaining any necessary permits for any Tenant’s Work that Xxxxxx is permitted to make hereunder. In all cases the Tenant’s Work shall be performed at Tenant’s sole cost and expense and by contractors selected by Xxxxxx. Tenant agrees that the Tenant’s plans and specifications shall be in compliance with applicable laws, rules and regulations, that Tenant shall not commence construction until it obtains (if required) a building permit for Tenant’s Work, and that such Tenant’s Work shall be performed in accordance with the building permit, in compliance with applicable law and in accordance with the Tenant’s plans and specifications. As a condition of approving such Tenant's Work the Landlord may require the Tenant to maintain such additional insurance coverages (in addition to those required in Article 8 hereof) as the Landlord may reasonably require.
Base Building Work Landlord shall construct the Base Building Work as further set forth on Exhibit 10.03, attached.
Tenant’s Space Plans Tenant shall deliver to Landlord and the TI Architect schematic drawings and outline specifications (the “TI Design Drawings”) detailing Tenant’s requirements for the Tenant Improvements within 5 business days of the date hereof. Not more than 2 days thereafter, Landlord shall deliver to Tenant the written objections, questions or comments of Landlord and the TI Architect with regard to the TI Design Drawings. Tenant shall cause the TI Design Drawings to be revised to address such written comments and shall resubmit said drawings to Landlord for approval within 2 days thereafter. Such process shall continue until Landlord has approved the TI Design Drawings.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.
Completion of Landlord’s Work Landlord shall substantially complete or cause to be substantially completed Landlord’s Work in a good and workmanlike manner, in accordance with the TI Permit subject, in each case, to Minor Variations and normal “punch list” items of a non-material nature that do not interfere with the use of the Premises and shall obtain a certificate or temporary certificate of occupancy (or an equivalent approval) for the Premises permitting lawful occupancy of the Premises during the Term (but specifically excluding any permits, licenses or other governmental approvals required to be obtained in connection with Tenant’s operations in the Premises not relating to Landlord’s Work)(“Substantial Completion” or “Substantially Complete”). Upon Substantial Completion of Landlord’s Work, Landlord shall require the TI Architect and the general contractor to execute and deliver, for the benefit of Tenant and Landlord, a Certificate of Substantial Completion in the form of the American Institute of Architects (“AIA”) document G704. For purposes of this Work Letter, “Minor Variations” shall mean any modifications reasonably required: (i) to comply with all applicable Legal Requirements and/or to obtain or to comply with any required permit (including the TI Permit); (ii) to comply with any request by Tenant for modifications to Landlord’s Work; (iii) to comport with good design, engineering, and construction practices that are not material; or (iv) to make reasonable adjustments in accordance with good design, engineering, and construction practices for field deviations or conditions encountered during the construction of Landlord’s Work.
Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
