Claim Notice A Party that seeks indemnity under this Article X (an “Indemnified Party”) will give written notice (a “Claim Notice”) to the Party from whom indemnification is sought (an “Indemnifying Party”), whether the Damages sought arise from matters solely between the Parties or from Third Party Claims. The Claim Notice must contain (i) a description and, if known, estimated amount (the “Claimed Amount”) of any Damages incurred or reasonably expected to be incurred by the Indemnified Party, (ii) a reasonable explanation of the basis for the Claim Notice to the extent of facts then known by the Indemnified Party, and (iii) a demand for payment of those Damages. No delay or deficiency on the part of the Indemnified Party in so notifying the Indemnifying Party will relieve the Indemnifying Party of any liability for Damages or obligation hereunder except to the extent of any Damages caused by or arising out of such failure.
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Legal Action Notice A prompt report of any legal actions pending or threatened in writing against Borrower or any of its Subsidiaries that could result in damages or costs to Borrower or any of its Subsidiaries of, individually or in the aggregate, One Hundred Thousand Dollars ($100,000) or more; and
Notice of Overpayment If the Contractor receives a vendor overpayment notice or a letter communicating the existence of an overpayment from DSHS, the Contractor may protest the overpayment determination by requesting an adjudicative proceeding. The Contractor’s request for an adjudicative proceeding must: a. Be received by the Office of Financial Recovery (OFR) at Post Office Box 9501, Olympia, Washington 98507-9501, within twenty-eight (28) calendar days of service of the notice; b. Be sent by certified mail (return receipt) or other manner that proves OFR received the request; c. Include a statement as to why the Contractor thinks the notice is incorrect; and d. Include a copy of the overpayment notice. Timely and complete requests will be scheduled for a formal hearing by the Office of Administrative Hearings. The Contractor may be offered a pre-hearing or alternative dispute resolution conference in an attempt to resolve the overpayment dispute prior to the hearing. Failure to provide OFR with a written request for a hearing within twenty-eight (28) days of service of a vendor overpayment notice or other overpayment letter will result in an overpayment debt against the Contractor. DSHS may charge the Contractor interest and any costs associated with the collection of this overpayment. DSHS may collect an overpayment debt through lien, foreclosure, seizure and sale of the Contractor’s real or personal property; order to withhold and deliver; or any other collection action available to DSHS to satisfy the overpayment debt.
Notice of Claimed Default Promptly upon becoming aware that the holder of any material obligation or of any other evidence of material Indebtedness of Borrower or Guarantor has given notice or taken any other action with respect to a claimed default or event of default thereunder, a written notice specifying the notice given or action taken by such holder and the nature of the claimed default or event of default and what action the Borrower or Guarantor are taking or proposes to take with respect thereto.
Statement of Actual Direct Expenses and Payment by Tenant Landlord shall give to Tenant within five (5) months following the end of each Expense Year, a statement (the “Statement”) which shall state the Direct Expenses incurred or accrued for such preceding Expense Year, and which shall indicate the amount of Tenant’s Share of Direct Expenses. Upon receipt of the Statement for each Expense Year commencing or ending during the Lease Term, Tenant shall pay, with its next installment of Base Rent due that is at least thirty (30) days thereafter, the full amount of Tenant’s Share of Direct Expenses for such Expense Year, less the amounts, if any, paid during such Expense Year as “Estimated Direct Expenses,” as that term is defined in Section 4.4.2, below, and if Tenant paid more as Estimated Direct Expenses than the actual Tenant’s Share of Direct Expenses, Tenant shall receive a credit in the amount of Tenant’s overpayment against Rent next due under this Lease. The failure of Landlord to timely furnish the Statement for any Expense Year shall not prejudice Landlord or Tenant from enforcing its rights under this Article 4. Even though the Lease Term has expired and Tenant has vacated the Premises, when the final determination is made of Tenant’s Share of Direct Expenses for the Expense Year in which this Lease terminates, Tenant shall immediately pay to Landlord such amount, and if Tenant paid more as Estimated Direct Expenses than the actual Tenant’s Share of Direct Expenses, Landlord shall, within thirty (30) days, deliver a check payable to Tenant in the amount of the overpayment. The provisions of this Section 4.4.1 shall survive the expiration or earlier termination of the Lease Term.
Sending a Claim Notice Before beginning a lawsuit, mediation or arbitration, you and we agree to send a written notice (a claim notice) to each party against whom a claim is asserted, in order to provide an opportunity to resolve the claim informally or through mediation. Go to xxxxxxxxxxxxxxx.xxx/ claim for a sample claim notice. The claim notice must describe the claim and state the specific relief demanded. Notice to you may be provided by your billing statement or sent to your billing address. Notice to us must include your name, address and Account number and be sent to American Express ADR c/o CT Corporation System, 00 Xxxxxxx Xxxxxx, Xxx Xxxx, Xxx Xxxx 00000. If the claim proceeds to arbitration, the amount of any relief demanded in a claim notice will not be disclosed to the arbitrator until after the arbitrator rules.
Notice of Direct Claims Any claim for indemnification or contribution under this Agreement or any Ancillary Agreement that does not result from a Third-Party Claim shall be asserted by written notice given by the Indemnitee to the applicable Indemnifying Party; provided, that the failure by an Indemnitee to so assert any such claim shall not prejudice the ability of the Indemnitee to do so at a later time except to the extent (if any) that the Indemnifying Party is prejudiced thereby. Such Indemnifying Party shall have a period of thirty (30) days after the receipt of such notice within which to respond thereto. If such Indemnifying Party does not respond within such thirty (30)-day period, such specified claim shall be conclusively deemed a Liability of the Indemnifying Party under this Section 4.6(b) or, in the case of any written notice in which the amount of the claim (or any portion thereof) is estimated, on such later date when the amount of the claim (or such portion thereof) becomes finally determined. If such Indemnifying Party does not respond within such thirty (30)-day period or rejects such claim in whole or in part, such Indemnitee shall, subject to the provisions of Article VII, be free to pursue such remedies as may be available to such party as contemplated by this Agreement and the Ancillary Agreements, as applicable, without prejudice to its continuing rights to pursue indemnification or contribution hereunder.
Notice of Events As soon as Guarantor obtains knowledge thereof, Guarantor shall give Guarantied Party written notice of any condition or event which has resulted in (a) a material adverse change in the financial condition of Guarantor or Company or (b) any Event of Default or Potential Event of Default.
Dispute Notice If there is a dispute between the parties, then either party may give a notice to the other succinctly setting out the details of the dispute and stating that it is a dispute notice given under this clause 17.1.