Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Equipment Failures In the event of equipment failures beyond the Administrator's control, the Administrator shall take reasonable and prompt steps to minimize service interruptions but shall have no liability with respect thereto. The Administrator shall develop and maintain a plan for recovery from equipment failures which may include contractual arrangements with appropriate parties making reasonable provision for emergency use of electronic data processing equipment to the extent appropriate equipment is available.
Epidemic Failure In the event that CONTRACTUAL PRODUCTS under warranty have the same or similar functional defect during a time period of three (3) months and the number of defected CONTRACTUAL PRODUCTS exceed [***] of the quantity delivered within this time period, this [***] = CERTAIN INFORMATION ON THIS PAGE HAS BEEN OMITTED AND FILED SEPARATELY WITH THE COMMISSION. CONFIDENTIAL TREATMENT HAS BEEN REQUESTED WITH RESPECT TO THE OMITTED PORTIONS. shall be an “Epidemic Failure” as mentioned in the following. The term “Epidemic Failure” shall exclusively apply to delivered CONTRACTUAL PRODUCTS with a number of pieces of more than ten thousand (>10.000) during three (3) months. If either CONTRACTUAL PARTY learns of the existence or likely existence of an Epidemic Failure, then such CONTRACTUAL PARTY will inform the other CONTRACTUAL PARTY as soon as possible. The CONTRACTUAL PARTIES shall then work together to jointly devise a containment action plan. As soon thereafter as reasonably possible, the CONTRACTUAL PARTIES will develop a corrective action plan to remedy the Epidemic Failure. Phoenix Contact shall use its best efforts to implement such remedy as quickly as possible at Phoenix Contact’s own expense, which efforts shall include receiving all shipments of affected Product back (freight collect), repairing or replacing all such affected Products in accordance with the agreed remedy devised by the Parties, shipping the repaired or replaced Products back to ENPHASE at Phoenix Contact’s expense, and implementing the agreed remedy in all newly manufactured Products. Phoenix Contact shall be responsible for the reasonable following costs and expenses actually incurred and substantiated as a result of all aspects of implementing the agreed remedy on the affected Products: reasonable costs of the retrieval, packing, shipping and transportation of such Products, and the re-deployment of repaired or replacement Products (including all labor, consulting, contractor and the like charges, incurred by ENPHASE, only if Phoenix Contact has agreed in writing that ENPHASE is allowed to do the aforementioned activities). For the avoidance of doubt all damages defined in Article 11.4 shall be direct damages and shall be subject to Article 14.2.
Payment Failure Any Credit Party (i) fails to pay any principal when due under this Agreement or (ii) fails to pay, within three Business Days of when due, any other amount due under this Agreement or any other Credit Document, including payments of interest, fees, reimbursements, and indemnifications;
Commencement Date Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
Business Failure Any act by, against or relating to any Loan Party, or its property or assets, which act constitutes the determination by any Loan Party to initiate or acquiesce to: a program of partial or total self-liquidation; an application for, consent to, or sufferance of the appointment of a receiver, trustee, or other person, pursuant to court action or otherwise, with respect to all or any part of any Loan Party’s property; the granting of any trust mortgage or execution of an assignment for the benefit of the creditors of any Loan Party; any other voluntary or involuntary liquidation or extension of debt agreement for any Loan Party; the offering by, or entering into by, any Loan Party of any composition, extension, or any other arrangement seeking relief from or extension of the debts of any Loan Party; or the initiation of any judicial or non-judicial proceeding or agreement by, against, or including any Loan Party which seeks or intends to accomplish a reorganization or arrangement with creditors; and/or the initiation by or on behalf of any Loan Party of the liquidation or winding up of all or any part of any Loan Party’s business or operations.
Approval Delays To the Knowledge of Acquiror, there is no reason why the granting of any of the Requisite Regulatory Approvals would be denied or unduly delayed. Acquiror Bank’s most recent CRA rating was “satisfactory” or better.
Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
No Force Majeure Event There shall not have been any delay, error, failure or interruption in the conduct of the business of the Acquiror Company, or any loss, injury, delay, damage, distress, or other casualty, due to force majeure including but not limited to (a) acts of God; (b) fire or explosion; (c) war, acts of terrorism or other civil unrest; or (d) national emergency.
