Lease Commencement Date The earlier to occur of (i) the date upon which Tenant first commences to conduct business in the Premises, and (ii) the later to occur of (A) November 1, 2018 and (B) the date upon which the Premises are Ready for Occupancy (as that term is defined in Section 5.1 of the Tenant Work Letter attached hereto as Exhibit B (the “Tenant Work Letter”)).
Effective Date; Termination Section 6.01. The following events are specified as additional conditions to the effectiveness of the Development Credit Agreement within the meaning of Section 12.01
Termination Date, Etc “Termination Date” shall mean in the case of the Executive’s death, his date of death, or in all other cases, the date specified in the Notice of Termination subject to the following:
Effective Date; Term This Agreement shall become effective on the date first written above and shall remain in force for a period of time of two years from such date, and from year to year thereafter but only so long as such continuance is specifically approved at least annually by the vote of a majority of the Trustees who are not interested persons of the Fund, the Adviser or the Sub-Adviser, cast in person at a meeting called for the purpose of voting on such approval, and by a vote of the Board of Trustees or of a majority of the outstanding voting securities of the Series. The aforesaid requirement that this Agreement may be continued "annually" shall be construed in a manner consistent with the 1940 Act and the rules and regulations thereunder.
COMMENCEMENT/EXPIRATION DATE This agreement is executed as of the date of the last signature and is effective through at which time it will expire. The expiration date is the final date for completion of all work activities under this agreement.
Commencement Date The Subcontractor shall be permitted to begin the Services on ______________________, 20____ (“Commencement Date”).
Rent Commencement Date The "Rent Commencement Date" shall be the date that Tenant first uses the Premises or any portion thereof for any purpose permitted under this lease. In the event this lease pertains to a building or building interior finish to be constructed, the "Rent Commencement Date" shall be the date upon which the buildings and other improvements erected and to be erected upon the premises shall have been substantially completed in accordance with the plans and specifications described on Exhibit "C" attached hereto and incorporated herein by reference, provided however, that if Landlord shall be delayed in such substantial completion as a result of: (i) Tenant's failure to agree to plans, specifications, and cost estimates, within a reasonable period of time; (ii) Tenant's request for materials, finishes or installations other than Landlord's standard; (iii) Tenant's changes in plans; the commencement date and the payment of rent hereunder shall be accelerated by the number of days of such delay, and provided further that if Landlord cannot substantially complete the premises as a result of any events (i) through (iii) above, Landlord may as its election complete so much of Landlord's work as may be practical under the circumstances and, by written notice to Tenant, establish the commencement date as the date of such partial completion, subject to any applicable accelerations due to delays resulting from events (i) through (iii) above. Taking possession by Tenant shall be deemed conclusively to establish that said buildings and other improvements have been completed in accordance with the plans and specifications and that the premises are in good and satisfactory condition, as of when possession was so taken. Tenant acknowledges that no representations as to the repair of the premises have been made by Landlord, unless such are expressly set forth in the lease. After such "Rent Commencement Date" Tenant shall, upon demand, execute and deliver to Landlord a letter of acceptance of delivery of the premises. In the event of any dispute as to substantial completion of work performed, execute or required to be performed by Landlord, the certificate of Landlord's architect or general contractor shall be conclusive.
Effective Date of Agreement; Termination This Agreement shall become effective when the parties hereto have executed and delivered this Agreement. The obligations of the several Underwriters hereunder shall be subject to termination in the absolute discretion of the Representative, if (1) since the time of execution of this Agreement or the earlier respective dates as of which information is given in the Registration Statement, the Pre-Pricing Prospectuses, the Prospectus and the Permitted Free Writing Prospectuses, if any, there has been any change or any development involving a prospective change in the business, properties, management, financial condition or results of operations of the Company and its subsidiaries taken as a whole, the effect of which change or development is, in the sole judgment of the Representative, so material and adverse as to make it impractical or inadvisable to proceed with the public offering or the delivery of the Securities on the terms and in the manner contemplated in the Registration Statement, the Pre-Pricing Prospectuses, the Prospectus and the Permitted Free Writing Prospectuses, if any, or (2) since the time of execution of this Agreement, there shall have occurred: (A) a suspension or material limitation in trading in securities generally on the NYSE, the American Stock Exchange or the NASDAQ Stock Market; (B) a suspension or material limitation in trading in the Company’s common stock on the NYSE; (C) a general moratorium on commercial banking activities declared by either federal or New York State authorities or a material disruption in commercial banking or securities settlement or clearance services in the United States; (D) an outbreak or escalation of hostilities or acts of terrorism involving the United States or a declaration by the United States of a national emergency or war; or (E) any other calamity or crisis or any change in financial, political or economic conditions in the United States or elsewhere, if the effect of any such event specified in clause (D) or (E), in your sole judgment, makes it impractical or inadvisable to proceed with the public offering or the delivery of the Securities on the terms and in the manner contemplated in the Registration Statement, the Pre-Pricing Prospectuses, the Prospectus and the Permitted Free Writing Prospectuses, if any, or (3) since the time of execution of this Agreement, there shall have occurred any downgrading, or any notice or announcement shall have been given or made of: (A) any intended or potential downgrading or (B) any watch, review or possible change that does not indicate an affirmation or improvement in the rating accorded any securities of or guaranteed by the Company or any Significant Subsidiary by any “nationally recognized statistical rating organization,” as that term is defined in Rule 436(g)(2) under the Act. If the Representative elects to terminate this Agreement as provided in this Section 7, the Company and each other Underwriter shall be notified promptly in writing. If the sale to the Underwriters of the Securities, as contemplated by this Agreement, is not carried out by the Underwriters for any reason permitted under this Agreement, or if such sale is not carried out because the Company shall be unable to comply with any of the terms of this Agreement, the Company shall not be under any obligation or liability under this Agreement (except to the extent provided in Sections 4(o), 5 and 9 hereof), and the Underwriters shall be under no obligation or liability to the Company under this Agreement (except to the extent provided in Section 9 hereof) or to one another hereunder.
Term Commencement Date The date that the Premises are Ready For Occupancy (as defined in Exhibit D attached hereto), which Term Commencement Date is anticipated to be August 1, 2015. In the event Landlord fails to deliver the Premises to Tenant with the Tenant Improvements Substantially Complete on or before November 1, 2015 ("First Outside Date") as such First Outside Date shall be extended due to Force Majeure delays and Tenant Delays, Tenant will be entitled to one day of free Monthly Base Rent, to be applied after the Term Commencement Date, for each day after such First Outside Date that the Premises are not delivered to Tenant as required hereunder. In the event fails to deliver the Premises to Tenant with the Tenant Improvements Substantially Complete on or before December 1, 2015 ("Second Outside Date"), as such Second Outside Date shall be deemed extended due to Force Majeure delays and Tenant Delays, Tenant may terminate this Lease by delivery of written notice to Landlord no later than that date which is five (5) business days after such Second Outside Date, in which case Landlord will immediately refund all amounts paid by Tenant pursuant to this Lease and Tenant shall have no further obligations to Landlord pursuant to this Lease except for those obligations which expressly survive the expiration or sooner termination of this Lease.
Vesting Commencement Date Exercise Price per Share: Total Number of Shares Subject to the Option: Total Exercise Price: Expiration Date:
