Lease of Premises and Term Thereof
Lease of Premises and Term Thereof Sample Clauses
Related to Lease of Premises and Term Thereof
Lease of Premises Landlord hereby demises and leases to Tenant for the Term of this Lease and upon the terms and conditions hereinafter set forth, and Tenant hereby accepts from Landlord, the Premises.
Premises and Term a. Landlord, in consideration of the Rent hereinafter reserved to be paid and of the covenants, conditions and agreements to be kept and performed by Tenant, hereby leases, lets and demises to Tenant, and Tenant hereby leases and hires from Landlord, the Project. Upon the Commencement Date for Phase 1, Tenant shall be entitled to the exclusive use and occupancy of Phase 1 and that portion of the Parking Area allocated for Phase 1 plus such spaces in addition to the spaces allocated for Phase 1, if any, that may be constructed by Landlord at the time, so long as Tenant’s use of such spaces in addition to the spaces allocated for Phase 1 does not interfere with the construction of the remainder of the Project by Landlord. Upon the Commencement Date for Phase 2, Tenant shall be entitled to the exclusive use and occupancy of Phase 2 and the entire Parking Area, and at which time Tenant will have the exclusive use and occupancy of the entire Project. b. Promptly after the actual Commencement Date for each Phase, the parties shall execute an instrument in which the Commencement Date and expiration date for such Phase will be specified, as well as any adjustments to the Rentable Area of the Premises as described above and any corresponding adjustments to the Base Rent. c. Notwithstanding anything to the contrary contained in this Lease, although Landlord has estimated a completion date for Phase 1 of October 1, 1999, the parties agree that if Landlord has not achieved Substantial Completion of Phase 1 on or before November 1, 1999 (the “Phase 1 Completion Date”) (subject to any Tenant Delays and Force Majeure events, as hereinafter defined), then, commencing on November 1, 1999, Tenant shall receive a credit against the Base Rent to become due under this Lease in connection with Phase 1, such credit to be equal to one (1) day’s Base Rent for Phase 1 for each day of Landlord’s delay beyond the Phase 1 Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. d. If Landlord has not achieved Substantial Completion of Phase 1 on or before November 15, 1999 (the “Phase 1 Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on November 16, 1999, the Base Rent credit available to Tenant for Phase 1 shall be increased to two (2) days’ Base Rent for each day of Landlord’s delay beyond the Phase 1 Extended Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. e. If Landlord has not achieved Substantial Completion of Phase 1 on or before December 17, 1999 (the “Phase 1 Second Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on December 18, 1999, (x) the Base Rent credit available to Tenant for Phase 1 shall be decreased back to one (1) day’s Base Rent for each day of Landlord’s delay beyond the Phase 1 Second Extended Completion Date that Landlord has not achieved Substantial Completion, plus (y) Tenant shall be entitled to receive, as liquidated damages and not as a penalty, the sum of Ten Thousand and No/100 ($10,000.00) Dollars per day, subject to the limitations thereon pursuant to subsection (m), below. f. If Landlord has not achieved Substantial Completion of Phase 1 on or before January 17, 2000 (the “Phase 1 Outside Completion Date”) (subject to any Tenant Delays and Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 1 Outside Completion Date, whereupon (i) Landlord shall return to Tenant the Prepaid Rent and Security Deposit, and (ii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 1 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 1 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder; provided, however, that if Landlord achieves Substantial Completion of Phase 1 within fifteen (15) days after receipt of Tenant’s termination notice, then the termination notice will be deemed to be void and rescinded, and the Lease shall continue in full force and effect. g. If Tenant does not elect to terminate the Lease as provided above, and Landlord has not achieved Substantial Completion of Phase 1 on or before May 17, 2000 (the “Phase 1 Extended Outside Completion Date”) (subject to any Tenant Delays but regardless of Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 1 Extended Outside Completion Date, whereupon (i) Landlord shall return to Tenant the Prepaid Rent and Security Deposit, and (ii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 1 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 1 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder. If Tenant intends to exercise its termination right under this paragraph, then Tenant will use its best efforts to notify Landlord in writing between April 1, 2000 and May 1, 2000 of such intent, but Tenant’s failure to so notify Landlord shall not constitute a waiver of Tenant’s termination right. h. Although Landlord has estimated a completion date for Phase 2 of October 1, 2001, the parties agree that if Landlord has not achieved Substantial Completion of Phase 2 on or before November 1, 2001 (the “Phase 2 Completion Date”) (subject to any Tenant Delays and Force Majeure events, as hereinafter defined), then, commencing on November 1, 2001, Tenant shall receive a credit against the Base Rent to become due under this Lease in connection with Phase 2, such credit to be equal to one (1) day’s Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. i. If Landlord has not achieved Substantial Completion of Phase 2 on or before November 15, 2001 (the “Phase 2 Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on November 16, 2001, the Base Rent credit available to Tenant for Phase 2 shall be increased to two (2) days’ Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Extended Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. j. If Landlord has not achieved Substantial Completion of Phase 2 on or before December 17, 2001 (the “Phase 2 Second Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on December 18, 2001, (x) the Base Rent credit available to Tenant shall be decreased back to one (1) day’s Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Second Extended Completion Date that Landlord has not achieved Substantial Completion, plus (y) Tenant shall be entitled to receive, as liquidated damages and not as a penalty, the sum of Ten Thousand and No/100 ($10,000.00) Dollars per day, subject to the limitations thereon pursuant to subsection (m), below. k. If Landlord has not achieved Substantial Completion of Phase 2 on or before January 17, 2002 (the “Phase 2 Outside Completion Date”) (subject to any Tenant Delays and Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 2 Outside Completion Date, whereupon (i) Tenant shall vacate and surrender the Premises to Landlord in the manner required by this Lease, (ii) Landlord shall return to Tenant the Security Deposit, (iii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 2 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 2 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease between the Commencement Date for Phase 1 and the date of Tenant’s termination notice, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder; provided, however, that if Landlord achieves Substantial Completion of Phase 2 within fifteen (15) days after receipt of Tenant’s termination notice, then the termination notice will be deemed to be void and rescinded, and the Lease shall continue in full force and effect. Within ninety (90) days after Tenant’s termination notice, Tenant shall notify Landlord of the exact date that Tenant will vacate and surrender Phase 1, which date shall be (a) no earlier than ninety (90) days after the date of Tenant’s notification of such exact date, and (b) no later than one (1) year after the date of Tenant’s termination notice. Rent for Phase 1 shall be prorated through the date that Tenant so vacates and surrenders Phase 1 to Landlord. l. If Tenant does not elect to terminate the Lease as provided above, and Landlord has not achieved Substantial Completion of Phase 2 on or before May 17, 2002 (the “Phase 2 Extended Outside Completion Date”) (subject to any Tenant Delays but regardless of Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 2 Extended Outside Completion Date, whereupon (i) Tenant shall vacate and surrender the Premises to Landlord in the manner required by this Lease, (ii) Landlord shall return to Tenant the Security Deposit, (iii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 2 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 2 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease between the Commencement Date for Phase 1 and the date of Tenant’s termination notice, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder. Within ninety (90) days after Tenant’s termination notice, Tenant shall notify Landlord of the exact date that Tenant will vacate and surrender Phase 1, which date shall be (a) no earlier than ninety (90) days after the date of Tenant’s notification of such exact date, and (b) no later than one (1) year after the date of Tenant’s termination notice. Rent for Phase 1 shall be prorated through the date that Tenant so vacates and surrenders Phase 1 to Landlord. If Tenant intends to exercise its termination right under this paragraph, then Tenant will use its best efforts to notify Landlord in writing between April 1, 2002 and May 1, 2002 of such intent, but Tenant’s failure to so notify Landlord shall not constitute a waiver of Tenant’s termination right. m. The abatements, liquidated damages and termination rights in favor of Tenant as described above shall be Tenant’s sole and exclusive remedies in the event of any late delivery of the Buildings by Landlord, and notwithstanding anything to the contrary contained in this Lease, in no event shall the entire liability of Landlord in connection with the total aggregate amounts of the Base Rent credits, plus the $10,000.00 per day damages, plus the out-of-pocket costs incurred by Tenant exceed a total amount of Seven Hundred Fifty Thousand and No/100 ($750,000.00) Dollars in the aggregate, regardless of the length of time such rent credits, and/or liquidated damages and/or out-of-pocket costs actually accrue and regardless of whether Tenant terminates this Lease. n. Although the completion date for Phase 2 is intended to be October 1, 2001, Tenant may notify Landlord in writing of Tenant’s election to have the Commencement Date for Phase 2 be on October 1, 2000. Tenant must provide such notice no later than April 1, 1999. If Tenant timely provides such notice, then the anticipated Commencement Date for Phase 2 will be deemed to be October 1, 2000, and subparagraphs 2.h through 2.I above will be deemed to be modified as follows: All references to the year “2001” in such subparagraphs will be deemed to be “2000,” and all references to the year “2002” in such subparagraphs will be deemed to be “2001.”
Sale of Premises by Landlord In the event of any sale of the Building, Landlord shall be and is hereby entirely freed and relieved of all liability under any and all of its covenants and obligations contained in or derived from this Lease arising out of any act, occurrence or omission occurring after the consummation of such sale; and the purchaser, at such sale or any subsequent sale of the Premises shall be deemed, without any further agreement between the parties or their successors in interest or between the parties and any such purchaser, to have assumed and agreed to carry out any and all of the covenants and obligations of the Landlord under this Lease.
Restoration of Premises Lessee shall conduct all operations on the Leased Premises in such a manner as not to unreasonably damage the portion of the Leased Premises where there will be no mining operations. Lessee shall conduct all operations in such a manner as to observe and comply with all Laws applicable to the Leased Premises and all Laws applicable to the conduct of Lessee’s operations. Lessee expressly agrees to dispose of all tailings and other mining wastes in accordance with all applicable Laws and shall reclaim all of disturbed perimeter portions of any lakes created by mining such that those perimeter portions shall be left at a slope no steeper than four feet horizontal to one foot vertical within three (3) months of termination of the Lease Agreement. By the expiration or earlier termination of the term of this Lease Agreement, Lessee shall grade that portion of the Leased Premises which has been excavated by Lessee or on which Lessee has conducted operations so as to eliminate all unreasonable irregularities therein and so that such portion of the Leased Premises which has been excavated by Lessee conforms to the drawing set forth on Exhibit C attached hereto. Upon completion of the required grading, Lessee shall cover such area with sand, clay, or topsoil, or a mixture of any of the foregoing, from the resources then existing on the Leased Premises, and shall thereafter reseed the surface with a seed mixture approved by Lessor. Notwithstanding the foregoing, in no event shall Lessee be required to import any Materials, including but not limited to, sand, clay, or topsoil from off-site for purposes of complying with its restoration obligations in this Section 15. Should this obligation not be met by the end of the term of this Lease Agreement, it shall nevertheless survive and continue beyond the term of this Lease Agreement and shall be an obligation owed by Lessee to Lessor. This obligation is owed by Lessee in addition to any other obligation imposed upon Lessee by this Lease Agreement.
CONSTRUCTION OF PREMISES A. Lessor agrees that it will supply, at its own expense, its standard office space, as more particularly described and set forth on Exhibit “B” annexed hereto and made a part hereof (“Lessor’s Work”). /s/ Lessor /s/ Lessee B. Lessee agrees to perform, at its own cost and expense, all work other than Lessor’s Work, including without limitation that work, as particularly described in Exhibit “E” annexed hereto (“Lessee’s Work”), which is necessary to make the Premises conform with Lessee’s plans as approved by Lessor. Within thirty (30) days after the execution of this Lease, Lessee shall furnish to Lessor, for Lessor’s written approval, plans and specifications for the Lessee’s Work, showing a layout, lighting plan, fixturing plan, interior finish and material samples, and any work or equipment to be done or installed by Lessee affecting any structural, mechanical or electrical part of the Premises or the Building. Failure to provide same within said thirty (30) day period shall constitute a default by Lessee under this Lease. Lessor’s failure to disapprove of Lessee’s plans within fifteen (15) days of receipt shall constitute acceptance by Lessor of such plans. Design elements as aforesaid will be displayed in color renderings in such detail as may be sufficient for Lessor’s needs. It is the purpose of this requirement that Lessee’s Premises be fixtured, designed and laid out so as not to be a detriment to the other tenants in the Building and that Lessee’s Work shall not be detrimental to the Building or other tenants therein, and Lessor’s approval of the plans and specifications as aforesaid for Lessee’s Work shall be at the Lessor’s sole discretion. Lessee agrees and acknowledges that all Lessee’s Work, improvements, alterations or additions performed by Lessee (hereinafter collectively “Alterations”) whether pursuant to this Section or otherwise, shall be carried out in compliance with all Requirements and is performed and accomplished solely for the benefit and convenience of Lessee, and not for the benefit of Lessor, such Alterations being nevertheless subject to each and every of the provisions of this Lease,.
Condition of Premises Lessor makes no warranty or representation as to the Premises. Lessee acknowledges and agrees that it has occupied and familiarized itself with the Premises and has had adequate opportunity to investigate and inspect the condition of the Premises, and enters into this Lease upon the basis of its own review, and is leasing the Premises in their “AS IS, WHERE IS” CONDITION WITH ALL FAULTS, WHETHER PREVIOUSLY EXISTING OR ARISING FROM OR PERTAINING TO ANY CONSTRUCTION, RENOVATION, RELOCATION OR IMPROVEMENT OF ANY PORTION OF THE PREMISES PERFORMED BY LESSOR OR OTHERS, INCLUDING BUT NOT LIMITED TO BOTH LATENT AND PATENT DEFECTS. EXCEPT AS EXPRESSLY SET FORTH TO THE CONTRARY IN THIS LEASE, NO WARRANTIES, EXPRESS OR IMPLIED, ARE MADE BY LESSOR OR ANY OF ITS AFFILIATES CONCERNING SUCH ITEMS, INCLUDING BUT NOT LIMITED TO, WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE. LESSEE HEREBY WAIVES AND DISCLAIMS ANY WARRANTIES THAT MAY ARISE BY OPERATION OF LAW. Lessee further acknowledges and agrees that it has had an opportunity to review and to discuss with various agents and/or representatives of Lessor the environmental condition of the Premises. Lessee has investigated and has knowledge of operative or proposed governmental laws and regulations including, without limitation, environmental laws and regulations to which the Premises are or may be subject and enters into this Lease upon the basis of its review and determination of the applicability and effect of such laws and regulations. Lessee acknowledges that Lessor expressly disclaims any representations or warranties of any kind or nature, express or implied, as to the condition (financial or otherwise), value or quality of the products, assets or properties of the Premises. Lessee hereby accepts the Premises in their condition existing as of the date hereof, subject to all applicable zoning, municipal, county and state laws, ordinances and regulations governing and regulating the use of the Premises, and accepts this Lease subject thereto and to all matters disclosed thereby and by any exhibits attached hereto. Lessee hereby agrees that all furniture, equipment, machinery and all other personal property, excepting any computers, that are located on or in the Premises as of the date hereof shall remain on the Premises as and when Lessee evacuates the Premises on the Termination Date or any extension thereof.
Expansion of Premises (a) Effective as of the Expansion Date the Premises (and the definition of the “Premises”) shall be modified to mean and include both the Initial Premises and the Expansion Premises. As a result of such expansion, effective upon the Expansion Date, the deemed square footage of the Premises shall be and become 31,684 square feet and Tenant’s Prorata Share and Tenant’s Share of Expenses and Real Estate Taxes shall be one hundred percent (100.00%). (b) If Landlord, for any reason whatsoever, cannot deliver possession of the Expansion Premises to Tenant on before August 1, 2012 for the purpose specified in Section 3(c), this Amendment shall not be void or voidable, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and Tenant shall have no obligation to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises until the day following the date on which possession of the Expansion Premises is delivered to Tenant (such date thereupon becoming the “Expansion Date” for purposes of this Amendment). Notwithstanding the foregoing, if Landlord is unable to deliver the Expansion Premises by August 1, 2012 (as extended day-for-day for each day of Force Majeure Delay) (the “Expansion Premises Outside Delivery Date”), then Tenant shall have the right, as its sole remedy, to terminate this Amendment to Lease by providing written notice to Landlord within fifteen (15) business days following the Expansion Premises Outside Delivery Date, in which event the Lease shall continue in full force and effect as if the parties had not entered into this Amendment and Landlord shall promptly return to Tenant the August, 2012 Base Rent for the Expansion Premises paid by Tenant pursuant to the provisions of Section 6(d). For purposes hereof, the failure of the existing tenant of the Expansion Premises to vacate the Expansion Premises shall not be an event of Force Majeure Delay. (c) Notwithstanding the above, Tenant shall be entitled to early occupancy of the Expansion Premises at any time after the Expansion Premises Delivery Date for the sole purposes of (1) installing Tenant’s furniture and telephone and other communications cabling and (2) performing Tenant’s Expansion Work (defined below), provided that (i) Tenant covenants and agrees that Tenant and Tenant’s employees, agents or contractors will cooperate with Landlord to coordinate the performance and completion of the Landlord’s Expansion Work concurrently with Tenant’s Expansion Work, (ii) Landlord shall have no liability to Tenant for delays in completing the Landlord’s Expansion Work which result from, are caused by or arise out of the interference by Tenant or Tenant’s employees, agents or contractors in the performance of the Landlord’s Expansion Work, (iii) Tenant and Tenant’s employees, agents and contractors shall promptly comply with any and all requests made by Landlord or Landlord’s contractor(s) that Tenant remove its property from those areas in or around which Landlord is performing the Landlord’s Expansion Work, and (iv) Landlord shall not be liable for, Tenant hereby waives all claims which Tenant may have against the Landlord Parties, and Tenant shall indemnify and hold harmless Landlord from and defend Landlord against any and all claims or liability for any injury or damage to any person or property in or about the Expansion Premises resulting from or arising out of or in connection with the performance of Tenant’s Expansion Work (except to the extent arising from the negligence or willful misconduct of Landlord). Tenant’s early occupancy of the Expansion Premises for the sole purpose provided in this Section shall be subject to all of the terms and conditions of the Lease, provided that (x) the Premises shall not include the Expansion Premises until the Expansion Date, and (y) Tenant shall not be obligated to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises for the period from the Expansion Premises Delivery Date until the Expansion Date. (d) Within five (5) business days after the Expansion Date, the parties shall execute a letter confirming the Expansion Date and certifying that Tenant has accepted delivery of the Premises, in form substantially similar to EXHIBIT “D” attached to the Lease (the “Expansion Date Memorandum”). Either party’s failure to request execution of, or to execute, the Expansion Date Memorandum shall not in any way alter the Expansion Date.
Use of Premises Tenant shall not use the premises or any part thereof, or permit the premises or any part thereof to be used, for any purpose other than the use hereinabove specifically mentioned, subject, however, to all the covenants, agreements, terms, provisions and conditions of this Lease. Those portions, if any, of the premises which on the plan(s) attached hereto are shown as toilets and utility areas shall be used by Tenant only for the purposes for which they are designed. Tenant will not at any time use or occupy the premises or any part thereof, or permit the premises or any part thereof to be used or occupied, in violation of the certificate of occupancy (temporary or final) issued for the Building and/or the premises. Tenant shall not xxx or permit the use of the premises or any part thereof in any way which would violate any of the covenants, agreements, terms, provisions and conditions of this Lease or for any unlawful purposes or in any unlawful manner and Tenant shall not suffer or permit the premises or any part thereof to be used in any manner or anything to be done therein or suffer or permit anything to be brought into or kept in the premises which, in the judgment of Landlord, shall in any way impair or tend to impair the character, reputation or appearance of the Building as a first-class office building, impair or interfere with or tend to impair or interfere with any of the Building services or the proper and economic heating, cleaning, air conditioning or other servicing of the Building or the premises, or impair or interfere with or tend to impair or interfere with the use of any of the other areas of the Building by, or occasion discomfort, inconvenience or annoyance to, any of the other tenants or occupants of the Building. Tenant shall not install any electrical or other equipment of any kind which, in the judgment of Landlord, might cause any such impairment, interference, discomfort, inconvenience or annoyance. Except as set forth in Article 1 hereof, Tenant will not, and will not permit anyone to, sell or traffic in any spirituous liquors, wine, ale or beer in or from the premises or carry on any manufacturing in the premises. If any governmental license or permit shall be required for the proper and lawful conduct of Tenant's business or other activity carried on it the premises, Tenant, at Tenant's expense, shall duly procure and thereafter maintain such license or permit and submit the same to inspection by Landlord. Tenant, at Tenant's expense, shall, at all times, comply with the terms and conditions of each license or permit.
RELOCATION OF PREMISES Landlord shall have the right to relocate the Premises to another part of the Building in accordance with the following: (a) The new premises shall be substantially the same in size, dimensions, configuration, decor and nature as the Premises described in this Lease, and if the relocation occurs after the Commencement Date, shall be placed in that condition by Landlord at its cost. (b) Landlord shall give Tenant at least thirty (30) days written notice of Landlord’s intention to relocate the Premises. (c) As nearly as practicable, the physical relocation of the Premises shall take place on a weekend and shall be completed before the following Monday. If the physical relocation has not been completed in that time, Base Rent shall axxxx in full from the time the physical relocation commences to the time it is completed. Upon completion of such relocation, the new premises shall become the “Premises” under this Lease. (d) All reasonable costs incurred by Tenant as a result of the relocation shall be paid by Landlord. (e) If the new premises are smaller than the Premises as it existed before the relocation, Base Rent shall be reduced proportionately or Tenant has the option to terminate the Lease Agreement. (f) The parties hereto shall immediately execute an amendment to this Lease setting forth the relocation of the Premises and the reduction of Base Rent, if any.
Abandonment of Premises If the property becomes vacant during the term of this lease, and if at the time of the vacancy Tenant are in default in the payment of any installment of rent, then the rent for the entire term shall become at once due and payable and Landlord may proceed to collect rent for said entire premises, with or without process of law, to take possession thereof, to remove any and all property there from and store as required by law, to lease the premises as agent of Tenant, and to apply the proceeds received from such letting toward the payment of Tenant' rent under this lease; such re-entry and re-letting shall not discharge Tenant from liability for rent, nor from any other obligation under the terms of this lease.
