Common use of Legal Clause in Contracts

Legal. 11.1 We may assign or transfer all or any part of our rights and subcontract any of our obligations under this Agreement without your consent provided that the transferee holds the applicable industry registration where necessary. Your rights under this Agreement will not be affected. 11.2 We will always communicate with you (including our terms and conditions) in English. 11.3 We may vary the terms and conditions of this Agreement at any time. 11.4 Any delay on your or our part in enforcing any term of this Agreement will not prevent either of us from enforcing that term later. 11.5 Notices required under this Agreement will be in writing and delivered by hand, sent by post or e-mail (where provided and permitted). We will send notices to your billing address or your e-mail address. We will assume you have received the notice 3 Business Days after we have sent it unless we receive evidence to the contrary. Unless otherwise stated in this Agreement, please send postal notice(s) to: OVO (S) Home Services Limited, Grampian House, 000 Xxxxxxx Xxxx, Perth, PH1 3GH or email Us at xxxx.xxxxxxxx@xxxxxxxxxxxxxxxxx.xxx 11.6 If any part of this Agreement is not permitted or is held to be ineffective by any court of law or other regulatory or competent body this will not affect any other part of this Agreement. 11.7 If your boiler, appliance or System is covered by a third party warranty, it’s your responsibility to make sure that any work we do doesn’t affect that warranty. 11.8 If our supply of the Products is delayed by an event outside our control then we will contact you as soon as possible to let you know and we will take steps to minimise the effect of the delay. Provided we do this we will not be liable for delays caused by the event, but if there is a risk of substantial delay you may contact us to end this Agreement and receive a refund for any Products you have paid for but not received. 11.9 We are under a legal duty to supply Products that are in conformity with this Agreement. Nothing in this Agreement will affect your statutory legal rights. 11.10 This Agreement and any disputes arising from it shall be governed by either the laws of England and Wales in the exclusive jurisdiction of the Courts of England and Wales if the Property is in England or Wales; or the laws of Scotland in the exclusive jurisdiction of the Scottish Courts if the Property is in Scotland.

Legal. 11.1 We may assign or transfer all or any part of our rights and subcontract any of our obligations under this Agreement without your consent provided that the transferee holds the applicable industry registration where necessary. Your rights under this Agreement will not be affected. 11.2 We will always communicate with you (including our terms and conditions) in English. 11.3 We may vary the terms and conditions of this Agreement at any time. 11.4 Any delay on your or our part in enforcing any term of this Agreement will not prevent either of us from enforcing that term later. 11.5 Notices required under this Agreement will be in writing and delivered by hand, sent by post or e-mail (where provided and permitted). We will send notices to your billing address or your e-mail address. We will assume you have received the notice 3 Business Days after we have sent it unless we receive evidence to the contrary. Unless otherwise stated in this Agreement, please send postal notice(s) to: OVO (S) Home Services Limited, Grampian House, 000 Xxxxxxx Xxxx, Perth, PH1 3GH or email Us at xxxx.xxxxxxxx@xxxxxxxxxxxxxxxxx.xxxxxxx.xxxxxxxx@xxx.xxx 11.6 If any part of this Agreement is not permitted or is held to be ineffective by any court of law or other regulatory or competent body this will not affect any other part of this Agreement. 11.7 If your boiler, appliance or System is covered by a third party warranty, it’s your responsibility to make sure that any work we do doesn’t affect that warranty. 11.8 If our supply of the Products is delayed by an event outside our control then we will contact you as soon as possible to let you know and we will take steps to minimise the effect of the delay. Provided we do this we will not be liable for delays caused by the event, but if there is a risk of substantial delay you may contact us to end this Agreement and receive a refund for any Products you have paid for but not received. 11.9 We are under a legal duty to supply Products that are in conformity with this Agreement. Nothing in this Agreement will affect your statutory legal rights. 11.10 This Agreement and any disputes arising from it shall be governed by either the laws of England and Wales in the exclusive jurisdiction of the Courts of England and Wales if the Property is in England or Wales; or the laws of Scotland in the exclusive jurisdiction of the Scottish Courts if the Property is in Scotland.

Legal. 11.1 We may assign or transfer all or any part of our rights and subcontract any of our obligations under this Agreement without your consent provided that the transferee holds the applicable industry registration where necessary. Your rights under this Agreement will not be affected. 11.2 We will always communicate with you (including our terms and conditions) in English. 11.3 We may vary the terms and conditions of this Agreement at any time. 11.4 Any delay on your or our part in enforcing any term of this Agreement will not prevent either of us from enforcing that term later. 11.5 Notices required under this Agreement will be in writing and delivered by hand, sent by post or e-mail (where provided and permitted). We will send notices to your billing address or your e-mail address. We will assume you have received the notice 3 Business Days after we have sent it unless we receive evidence to the contrary. Unless otherwise stated in this Agreement, please send postal notice(s) to: OVO (S) SSE Home Services Limited, Grampian Inveralmond House, 000 Xxxxxxx Xxxx, Perth, PH1 3GH 3AQ or email Us at xxxx.xxxxxxxx@xxxxxxxxxxxxxxxxx.xxxxxxx.xxxxxxxx@xxx.xxx 11.6 If any part of this Agreement is not permitted or is held to be ineffective by any court of law or other regulatory or competent body this will not affect any other part of this Agreement. 11.7 If your boiler, appliance or System is covered by a third party warranty, it’s your responsibility to make sure that any work we do doesn’t affect that warranty. 11.8 If our supply of the Products is delayed by an event outside our control then we will contact you as soon as possible to let you know and we will take steps to minimise the effect of the delay. Provided we do this we will not be liable for delays caused by the event, but if there is a risk of substantial delay you may contact us to end this Agreement and receive a refund for any Products you have paid for but not received. 11.9 We are under a legal duty to supply Products that are in conformity with this Agreement. Nothing in this Agreement will affect your statutory legal rights. 11.10 This Agreement and any disputes arising from it shall be governed by either the laws of England and Wales in the exclusive jurisdiction of the Courts of England and Wales if the Property is in England or Wales; or the laws of Scotland in the exclusive jurisdiction of the Scottish Courts if the Property is in Scotland.

Legal. 11.1 3.6.1. We shall exercise the reasonable skill and care of a competent service provider. 3.6.2. We may assign or transfer all or any part of our rights and subcontract any of our obligations under this Agreement agreement without your consent provided that the transferee holds the applicable industry registration where necessary. Your rights under this Agreement agreement will not be affected. 11.2 We will always communicate 3.6.3. You may only transfer this agreement between persons with you (including our terms and conditions) in Englishprior approval. 11.3 3.6.4. We may vary the terms and conditions of this Agreement at any timeagreement. If we vary the terms and conditions to your material disadvantage we will notify you of such variations and the date on which they will start in advance. If you notify us that you are cancelling this agreement then such variations shall not be effective in respect of this agreement. You will not have to pay a cancellation charge and we will refund your payments you have made in advance. Otherwise the new terms and conditions will apply commencing on the notified date. 11.4 3.6.5. Any delay on your or our part in enforcing any term of this Agreement agreement will not prevent either of us from enforcing that term later. 11.5 3.6.6. We do not limit our liability for death or personal injury caused by our negligence. This is a consumer contract so we are not responsible for any business losses. Otherwise we will only be responsible for any loss or damage which is a foreseeable result of our breaching this agreement or our failing to use reasonable care and skill. Our maximum liability arising out of this Agreement is up to £100,000 in any calendar year. Loss or damage is foreseeable if either it is obvious that it will happen or if, at the time the Agreement was made, both we and you knew it might happen, for example, if you discussed it with us during the sales process. 3.6.7. Notices required under this Agreement agreement will be in writing and delivered by hand, sent by post or e-mail (where provided and permitted). We will send notices to your billing address or your e-mail address. We will assume you have received the notice 3 Business Days 5 working days after we have sent it unless we receive evidence to the contrary. Unless otherwise stated in this Agreement, please send postal notice(s) to: OVO (S) SSE Home Services Limited, Grampian Inveralmond House, 000 Xxxxxxx Xxxx, PerthXxxxx, PH1 3GH XX0 0XX, or email Us us at xxxx.xxxxxxxx@xxxxxxxxxxxxxxxxx.xxxxxxx.xxxxxxxx@xxx.xxx 11.6 3.6.8. If any part of this Agreement agreement is not permitted or is held to be ineffective by any court of law or other regulatory or competent body this will not affect any other part of this Agreementagreement. 11.7 If your boiler, appliance or System is covered by a third party warranty, it’s your responsibility to make sure that any work we do doesn’t affect that warranty. 11.8 If our supply of the Products is delayed by an event outside our control then we will contact you as soon as possible to let you know and we will take steps to minimise the effect of the delay3.6.9. Provided we do this we will not be liable for delays caused by the event, but if there is a risk of substantial delay you may contact us to end this Agreement and receive a refund for any Products you have paid for but not received. 11.9 We are under a legal duty to supply Products that are in conformity with this Agreement. Nothing in this Agreement will affect your statutory legal rights. 11.10 This Agreement agreement and any disputes arising from it shall be governed by either the laws of England and Wales in the exclusive jurisdiction of the Courts of England and Wales if the Property property is in England or Wales; or the laws of Scotland in the exclusive jurisdiction of the Scottish Courts if the Property property is in Scotland. 3.6.10. The headings in these terms and conditions are for your guidance only and do not affect the interpretation.