Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
Liability for Deficiency If any sale or other disposition of Collateral by Secured Party or any other action of Secured Party hereunder results in reduction of the Obligations, such action will not release Debtor from its liability to Secured Party for any unpaid Obligations, including costs, charges and expenses incurred in the liquidation of Collateral, together with interest thereon, and the same shall be immediately due and payable to Secured Party at Secured Party's address set forth in the opening paragraph hereof.
Liability for Damages Nothing in this Section shall preclude the Borrower or any Lender from asserting against any LC Issuing Bank any claim for direct (but not consequential) damages suffered by the Borrower or such Lender to the extent, but only to the extent, caused by (A) the willful misconduct or gross negligence of such LC Issuing Bank in determining whether a request presented under any Letter of Credit issued by it complied with the terms thereof or (B) such LC Issuing Bank's failure to pay under any such Letter of Credit after the presentation to it of a request strictly complying with the terms and conditions thereof.
Landlord Liability Tenant, its successors, and assigns shall not assert nor seek to enforce any claim for breach of this Lease against any of Landlord’s assets other than Landlord’s interest in the Industrial Center. Tenant agrees to look solely to such interest for the satisfaction of any liability or claim against Landlord under this Lease. In no event whatsoever shall Landlord (which term shall include, without limitation, any general or limited partner, trustees, beneficiaries, officers, directors, or stockholders of Landlord) ever be personally liable for any such liability.
Liability for Specific Obligations The Administrator will be liable only for its specific obligations under this Agreement. All other liability is expressly waived and released as a condition of, and consideration for, the execution of this Agreement by the Administrator. The Administrator will be liable for its willful misconduct, bad faith or negligence in performing its obligations under this Agreement.
Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord’s reasonable control, and subject to all other terms of this Article 11, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Upon the occurrence of any damage to the Premises, upon notice (the “Landlord Repair Notice”) to Tenant from Landlord, Tenant shall assign to Landlord (or to any party designated by Landlord) all insurance proceeds payable to Tenant under Tenant’s insurance required under Section 10.3 of this Lease, and Landlord shall repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original condition; provided that if the cost of such repair by Landlord exceeds the amount of insurance proceeds received by Landlord from Tenant’s insurance carrier, as assigned by Tenant, the cost of such repairs shall be paid by Tenant to Landlord prior to Landlord’s commencement of repair of the damage. In the event that Landlord does not deliver the Landlord Repair Notice within sixty (60) days following the date the casualty becomes known to Landlord, Tenant shall, at its sole cost and expense, repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original condition. Whether or not Landlord delivers a Landlord Repair Notice, prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord’s review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant’s business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant’s occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises. In the event that Landlord shall not deliver the Landlord Repair Notice, Tenant’s right to rent abatement pursuant to the preceding sentence shall terminate as of the date which is reasonably determined by Landlord to be the date Tenant should have completed repairs to the Premises assuming Tenant used reasonable due diligence in connection therewith.
Landlord’s Retention of Contractor Landlord shall independently retain the Contractor to perform the Tenant Improvement Work in accordance with the Approved Construction Drawings.
Processor’s Liability for Nonperformance In performing the Services, Processor will exercise ordinary care and act in good faith. Processor shall be deemed to have exercised ordinary care if its action or failure to act is in conformity with general information technology processing standards. Processor’s liability relating to its or its employees’, officers’ or agents’ performance or failure to perform hereunder, or for any other action or inaction of Processor, or its employees, officers or agents, shall be limited exclusively to the lesser of (i) any direct losses which are caused by the failure of Processor, its employees, officers or agents to exercise reasonable care and/or act in good faith, and (ii) the face amount of any item, check, payment or other funds lost or mishandled by the action or inaction of Processor. Under no circumstances will Processor be liable for any general, indirect, special, incidental, punitive or consequential damages or for damages caused, in whole or in part, by the action or inaction of AmeriCredit or the Trustee, whether or not such action or inaction constitutes negligence. Processor will not be liable for any damage, loss, liability or delay caused by accidents, strikes, fire, flood, war, riot, equipment breakdown, electrical or mechanical failure, acts of God or any cause which is reasonably unavoidable or beyond its reasonable control. AmeriCredit agrees that the fees charged by Processor for the performance of this Service shall be deemed to have been established in contemplation of these limitations on Processor’s liability. In addition, AmeriCredit agrees to indemnify and hold Processor harmless from all liability on the part of Processor under this Section 13 except such liability as is attributable to the gross negligence of Processor.
LANDLORD'S LIABILITY 21. This lease and the obligations of Tenant hereunder shall in no way be affected because Landlord is unable to fulfill any of its obligations or to supply any service, by reason of strike or other cause not within Landlord's control. Landlord shall have the right, without incurring any liability to Tenant, to stop any service because of accident or emergency, or for repairs, alterations or improvements, necessary or desirable in the judgment of Landlord, until such repairs, alterations or improvements shall have been completed. Landlord shall not be liable to Tenant or anyone else, for any loss or damage to person, property or business, unless due to the negligence of Landlord nor shall Landlord be liable for any latent defect in the premises or the building. Tenant, during the term of this lease, shall carry public liability and property damage insurance, from a company authorized to do business in New York, with limitations acceptable to Landlord, which policy or policies shall name the Landlord and its designees as additional insureds. Evidence of the policies, and of their timely renewal, shall be delivered to Landlord. All such insurance shall contain an agreement by the insurance company that the policy or policies will not be cancelled or the coverage changed, without thirty (30) days' prior written notice to the Landlord. Tenant agrees to look solely to Landlord's estate and interest in the land and building, or the lease of the building or of the land and building, and the demised premises, for the satisfaction of any right or remedy of Tenant for the collection of a judgment (or other judicial process) requiring the payment of money by Landlord, in the event of any liability by Landlord, and no other property or assets of Landlord shall be subject to levy, execution or other enforcement procedure for the satisfaction of Tenant's remedies under or with respect to this lease, the relationship of landlord and tenant hereunder, or Tenant's use and occupancy of the demised premises or any other liability of Landlord to Tenant (except for negligence).
Construction of Tenant Improvements by Tenants Agents Construction Contract; Cost Budget. Prior to Tenant's execution of ---------------------------------- the construction contract and general conditions with Contractor (the "Contract"), Tenant shall submit the Contract to Landlord for its approval, which approval shall not be unreasonably withheld or delayed. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, of the final costs to be incurred, or which have been incurred, as set forth more particularly in Sections 2.2.1.1 through ---------------- 2.2.1.8 above, in connection with the design and construction of the Tenant ------- Improvements to be performed by or at the direction of Tenant or the Contractor (which costs form a basis for the amount of the Contract, if any (the "Final Costs"). Prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with a completion bond in an amount equal to the Final Costs to ensure Landlord of the completion of the Tenant Improvements.
