Responsibility for Property Except as expressly set forth in Section 3.25, Contractor shall limit its operations to the Stage 2 Site. Contractor shall plan and conduct its operations so that neither Contractor nor any of its Subcontractors or Sub-subcontractors shall (i) enter upon lands (other than the Stage 2 Site and Off-Site Rights of Way and Easements) or waterbodies in their natural state unless authorized by the appropriate owner or entity; (ii) close or obstruct any utility installation, highway, waterway, harbor, road or other property unless Permits are obtained and authorized by the appropriate entity or authority; or (iii) disrupt or otherwise interfere with the operation of any portion of any pipeline, telephone, conduit or electric transmission line, ditch, navigational aid, dock or structure unless otherwise specifically authorized by the appropriate entity or authority. The foregoing includes damage arising from performance of the Work through operation of Construction Equipment or stockpiling of materials. If damage occurs to Subproject 1 or Subproject 2 prior to substantial completion of such applicable Subproject 1 or Subproject 2, liability for such damage shall be governed by the Stage 1 EPC Agreement.
INDEMNIFICATION AND CONSULTANT’S RESPONSIBILITIES Consultant shall indemnify, defend with counsel reasonably acceptable to the City, and hold harmless the City and its officials, officers, employees, agents, contractors, consultants, and volunteers from and against any and all losses, liability, claims, suits, actions, damages, and causes of action arising out of any personal injury, bodily injury, loss of life, or damage to property, or any violation of any federal, state, or municipal law or ordinance, to the extent caused, in whole or in part, by the willful misconduct or negligent acts or omissions of Consultant or its employees, subcontractors, or agents, by acts for which they could be held strictly liable, or by the quality or character of their work. The foregoing obligation of Consultant shall not apply when (1) the injury, loss of life, damage to property, or violation of law arises wholly from the negligence or willful misconduct of the City or its officers, employees, agents, contractors, consultants, or volunteers and (2) the actions of Consultant or its employees, subcontractor, or agents have contributed in no part to the injury, loss of life, damage to property, or violation of law. It is understood that the duty of Consultant to indemnify and hold harmless includes the duty to defend as set forth in Section 2778 of the California Civil Code. Acceptance by City of insurance certificates and endorsements required under this Agreement does not relieve Consultant from liability under this indemnification and hold harmless clause. This indemnification and hold harmless clause shall apply to any damages or claims for damages whether or not such insurance policies shall have been determined to apply. By execution of this Agreement, Consultant acknowledges and agrees to the provisions of this Section and that it is a material element of consideration. In the event that Consultant or any employee, agent, or subcontractor of Consultant providing services under this Agreement is determined by a court of competent jurisdiction or the California Public Employees Retirement System (PERS) to be eligible for enrollment in PERS as an employee of City, Consultant shall indemnify, defend, and hold harmless City for the payment of any employee and/or employer contributions for PERS benefits on behalf of Consultant or its employees, agents, or subcontractors, as well as for the payment of any penalties and interest on such contributions, which would otherwise be the responsibility of City.
Liability for Acts and Omissions As between any Loan Party and the Issuing Lender, or the Issuing Lender’s Affiliates, such Loan Party assumes all risks of the acts and omissions of, or misuse of the Letters of Credit by, the respective beneficiaries of such Letters of Credit. In furtherance and not in limitation of the foregoing, the Issuing Lender shall not be responsible for any of the following, including any losses or damages to any Loan Party or other Person or property relating therefrom: (i) the form, validity, sufficiency, accuracy, genuineness or legal effect of any document submitted by any party in connection with the application for an issuance of any such Letter of Credit, even if it should in fact prove to be in any or all respects invalid, insufficient, inaccurate, fraudulent or forged (even if the Issuing Lender or its Affiliates shall have been notified thereof); (ii) the validity or sufficiency of any instrument transferring or assigning or purporting to transfer or assign any such Letter of Credit or the rights or benefits thereunder or proceeds thereof, in whole or in part, which may prove to be invalid or ineffective for any reason; (iii) the failure of the beneficiary of any such Letter of Credit, or any other party to which such Letter of Credit may be transferred, to comply fully with any conditions required in order to draw upon such Letter of Credit or any other claim of any Loan Party against any beneficiary of such Letter of Credit, or any such transferee, or any dispute between or among any Loan Party and any beneficiary of any Letter of Credit or any such transferee; (iv) errors, omissions, interruptions or delays in transmission or delivery of any messages, by mail, cable, telegraph, telex or otherwise, whether or not they be in cipher; (v) errors in interpretation of technical terms; (vi) any loss or delay in the transmission or otherwise of any document required in order to make a drawing under any such Letter of Credit or of the proceeds thereof; (vii) the misapplication by the beneficiary of any such Letter of Credit of the proceeds of any drawing under such Letter of Credit; or (viii) any consequences arising from causes beyond the control of the Issuing Lender or its Affiliates, as applicable, including any act or omission of any Official Body, and none of the above shall affect or impair, or prevent the vesting of, any of the Issuing Lender’s or its Affiliates rights or powers hereunder. Nothing in the preceding sentence shall relieve the Issuing Lender from liability for the Issuing Lender’s gross negligence or willful misconduct in connection with actions or omissions described in such clauses (i) through (viii) of such sentence. In no event shall the Issuing Lender or its Affiliates be liable to any Loan Party for any indirect, consequential, incidental, punitive, exemplary or special damages or expenses (including without limitation attorneys’ fees), or for any damages resulting from any change in the value of any property relating to a Letter of Credit. Without limiting the generality of the foregoing, the Issuing Lender and each of its Affiliates (i) may rely on any oral or other communication believed in good faith by the Issuing Lender or such Affiliate to have been authorized or given by or on behalf of the applicant for a Letter of Credit, (ii) may honor any presentation if the documents presented appear on their face substantially to comply with the terms and conditions of the relevant Letter of Credit; (iii) may honor a previously dishonored presentation under a Letter of Credit, whether such dishonor was pursuant to a court order, to settle or compromise any claim of wrongful dishonor, or otherwise, and shall be entitled to reimbursement to the same extent as if such presentation had initially been honored, together with any interest paid by the Issuing Lender or its Affiliate; (iv) may honor any drawing that is payable upon presentation of a statement advising negotiation or payment, upon receipt of such statement (even if such statement indicates that a draft or other document is being delivered separately), and shall not be liable for any failure of any such draft or other document to arrive, or to conform in any way with the relevant Letter of Credit; (v) may pay any paying or negotiating bank claiming that it rightfully honored under the laws or practices of the place where such bank is located; and (vi) may settle or adjust any claim or demand made on the Issuing Lender or its Affiliate in any way related to any order issued at the applicant’s request to an air carrier, a letter of guarantee or of indemnity issued to a carrier or any similar document (each an “Order”) and honor any drawing in connection with any Letter of Credit that is the subject of such Order, notwithstanding that any drafts or other documents presented in connection with such Letter of Credit fail to conform in any way with such Letter of Credit. In furtherance and extension and not in limitation of the specific provisions set forth above, any action taken or omitted by the Issuing Lender or its Affiliates under or in connection with the Letters of Credit issued by it or any documents and certificates delivered thereunder, if taken or omitted in good faith, shall not put the Issuing Lender or its Affiliates under any resulting liability to the Borrower or any Lender.
Indemnification of the Company, its Directors and Officers Each Underwriter agrees, severally and not jointly, to indemnify and hold harmless the Company, and its directors, each officer of the Company who signed the Registration Statement and each person, if any, who controls the Company within the meaning of Section 15 of the Securities Act or Section 20 of the Exchange Act, against any and all loss, liability, claim, damage and expense described in the indemnity contained in Section 5.1.1, as incurred, but only with respect to untrue statements or omissions, or alleged untrue statements or omissions, made in the Registration Statement, any preliminary prospectus, the Statutory Prospectus, any Testing-the-Waters Communication or the Prospectus (or any amendment or supplement to the foregoing), solely in reliance upon and in conformity with the Underwriters’ Information.
Liability of Consultant In furnishing the Company with management advice and other services as herein provided, Consultant shall not be liable to the Company or its creditors for errors of judgment or for anything except malfeasance or gross negligence in the performance of his duties or reckless disregard of the obligations and duties under the terms of this Agreement. It is further understood and agreed that Consultant may rely upon information furnished to it reasonably believed to be accurate and reliable and that, except as set forth herein in the first paragraph of this Section 12, Consultant shall not be accountable for any loss suffered by the Company by reason of the Company's action or non-action on the basis of any advice, recommendation or approval of Consultant. The parties further acknowledge that Consultant undertakes no responsibility for the accuracy of any statements to be made by management contained in press releases or other communications, including, but not limited to, filings with the Securities and Exchange Commission and the National Association of Securities Dealers, Inc.
OBLIGATIONS AND ACTIVITIES OF CONTRACTOR AS BUSINESS ASSOCIATE 1. CONTRACTOR agrees not to use or further disclose PHI COUNTY discloses to CONTRACTOR other than as permitted or required by this Business Associate Contract or as required by law.
2. XXXXXXXXXX agrees to use appropriate safeguards, as provided for in this Business Associate Contract and the Agreement, to prevent use or disclosure of PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY other than as provided for by this Business Associate Contract.
3. XXXXXXXXXX agrees to comply with the HIPAA Security Rule at Subpart C of 45 CFR Part 164 with respect to electronic PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY.
4. CONTRACTOR agrees to mitigate, to the extent practicable, any harmful effect that is known to CONTRACTOR of a Use or Disclosure of PHI by CONTRACTOR in violation of the requirements of this Business Associate Contract.
5. XXXXXXXXXX agrees to report to COUNTY immediately any Use or Disclosure of PHI not provided for by this Business Associate Contract of which CONTRACTOR becomes aware. CONTRACTOR must report Breaches of Unsecured PHI in accordance with Paragraph E below and as required by 45 CFR § 164.410.
6. CONTRACTOR agrees to ensure that any Subcontractors that create, receive, maintain, or transmit PHI on behalf of CONTRACTOR agree to the same restrictions and conditions that apply through this Business Associate Contract to CONTRACTOR with respect to such information.
7. CONTRACTOR agrees to provide access, within fifteen (15) calendar days of receipt of a written request by COUNTY, to PHI in a Designated Record Set, to COUNTY or, as directed by COUNTY, to an Individual in order to meet the requirements under 45 CFR § 164.524. If CONTRACTOR maintains an Electronic Health Record with PHI, and an individual requests a copy of such information in an electronic format, CONTRACTOR shall provide such information in an electronic format.
8. CONTRACTOR agrees to make any amendment(s) to PHI in a Designated Record Set that COUNTY directs or agrees to pursuant to 45 CFR § 164.526 at the request of COUNTY or an Individual, within thirty (30) calendar days of receipt of said request by COUNTY. XXXXXXXXXX agrees to notify COUNTY in writing no later than ten (10) calendar days after said amendment is completed.
9. CONTRACTOR agrees to make internal practices, books, and records, including policies and procedures, relating to the use and disclosure of PHI received from, or created or received by CONTRACTOR on behalf of, COUNTY available to COUNTY and the Secretary in a time and manner as determined by COUNTY or as designated by the Secretary for purposes of the Secretary determining COUNTY’S compliance with the HIPAA Privacy Rule.
10. CONTRACTOR agrees to document any Disclosures of PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY, and to make information related to such Disclosures available as would be required for COUNTY to respond to a request by an Individual for an accounting of Disclosures of PHI in accordance with 45 CFR § 164.528.
11. CONTRACTOR agrees to provide COUNTY or an Individual, as directed by COUNTY, in a time and manner to be determined by COUNTY, that information collected in accordance with the Agreement, in order to permit COUNTY to respond to a request by an Individual for an accounting of Disclosures of PHI in accordance with 45 CFR § 164.528.
12. XXXXXXXXXX agrees that to the extent CONTRACTOR carries out COUNTY’s obligation under the HIPAA Privacy and/or Security rules CONTRACTOR will comply with the requirements of 45 CFR Part 164 that apply to COUNTY in the performance of such obligation.
13. If CONTRACTOR receives Social Security data from COUNTY provided to COUNTY by a state agency, upon request by COUNTY, CONTRACTOR shall provide COUNTY with a list of all employees, subcontractors and agents who have access to the Social Security data, including employees, agents, subcontractors and agents of its subcontractors.
14. CONTRACTOR will notify COUNTY if CONTRACTOR is named as a defendant in a criminal proceeding for a violation of HIPAA. COUNTY may terminate the Agreement, if CONTRACTOR is found guilty of a criminal violation in connection with HIPAA. COUNTY may terminate the Agreement, if a finding or stipulation that CONTRACTOR has violated any standard or requirement of the privacy or security provisions of HIPAA, or other security or privacy laws are made in any administrative or civil proceeding in which CONTRACTOR is a party or has been joined. COUNTY will consider the nature and seriousness of the violation in deciding whether or not to terminate the Agreement.
Liability Waiver The tenant waives and releases the landlord from any liability whatsoever in connection with: the use or occupation by an occupant or guest of the tenant of the rental unit or the residential property or the use of any services, furnishings, equipment and facilities supplied by the landlord; and any damage to or loss of any personal property of an occupant or guest of the tenant. The tenant is advised to carry adequate insurance covering personal property and third party liability claims. Subject to an order of the director, the landlord will not be liable for damages, direct or indirect, for personal discomfort or illness arising from the lack of heat, or hot and cold water, or electricity or air conditioning, or inoperable appliance, or from alterations or repairs to the rental unit or services to the rental unit. During repairs to the heating facilities, the landlord will not be obliged to furnish heat.
LIABILITY FOR FAILURE TO COMPLETE TRANSACTIONS If We do not
Liability for Certain Acts The Manager shall perform the Manager’s duties in good faith, in a manner it reasonably believes to be in the best interests of the Company, and with such care as an ordinarily prudent person in a like position would use under similar circumstances. No Manager shall have any liability by reason of being or having been the Manager of the Company. No Manager in any way guarantees the return of the Members’ Capital Contributions or a profit for the Members from the operations of the Company. No Manager shall be liable to the Company or to any Member for any loss or damage sustained by the Company or any Member, unless the loss or damage shall have been the result of fraud, deceit, gross negligence, willful misconduct, breach of this Agreement or a wrongful taking by the Manager.
Liability for Specific Obligations The Administrator will be liable only for its specific obligations under this Agreement. All other liability is expressly waived and released as a condition of, and consideration for, the execution of this Agreement by the Administrator. The Administrator will be liable for its willful misconduct, bad faith or negligence in performing its obligations under this Agreement.
