OPERATION OF PROPERTY DURING AGREEMENT PERIOD The Seller will continue to operate the Property and any business conducted on the Property in the manner operated prior to the Agreement and will take no action that would adversely impact the Property, tenants, lender, or business, if any. Any changes, such as renting vacant space, that materially affects the Property or the Buyer's intended use will be permitted only with the Buyer's consent.
Maintenance during Construction Period (i) During the Construction Period, the Contractor shall maintain, at its cost, the existing lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at no time materially inferior as compared to their condition on Appointed Date, and shall undertake the necessary repair and maintenance works for this purpose; provided that the Contractor may, at its cost, interrupt and divert the flow of traffic if such interruption and diversion is necessary for the efficient progress of Works and conforms to Good Industry Practice; provided further that such interruption and diversion shall be undertaken by the Contractor only with the prior written approval of the Authority’s Engineer which approval shall not be unreasonably withheld. For the avoidance of doubt, it is agreed that the Contractor shall at all times be responsible for ensuring safe operation of the Project Highway. It is further agreed that in the event the Project includes construction of a bypass or tunnel and realignment of the existing carriageway, the Contractor shall maintain the existing highway in such sections until the new Works are open to traffic.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Delays during construction Without prejudice to the provisions of Clause 10.3 (ii), in the event the Contractor does not achieve any of the Project Milestones or the Authority’s Engineer shall have reasonably determined that the rate of progress of Works is such that Completion of the Project Highway is not likely to be achieved by the end of the Scheduled Completion Date, it shall notify the same to the Contractor, and the Contractor shall, within 15 (fifteen) days of such notice, by a communication inform the Authority’s Engineer in reasonable detail about the steps it proposes to take to expedite progress and the period within which it shall achieve the Project Completion Date.
C4 Contract Price During Extension of the Initial Contract Period C4.1 Subject to the Pricing Schedule and the provision in clause F6 (Variation), the Contract Price shall apply for the Initial Contract Period and following an extension pursuant to clause F8 (Extension of Initial Contract Period), to the date of expiry of the extended period, or such earlier date of termination or partial termination of the agreement in accordance with the Law or the provisions of the Contract. C5 Euro
Refinancing Preparation Advance; Capitalizing Front-end Fee and Interest (a) If the Loan Agreement provides for the repayment out of the proceeds of the Loan of an advance made by the Bank or the Association (“Preparation Advance”), the Bank shall, on behalf of such Loan Party, withdraw from the Loan Account on or after the Effective Date the amount required to repay the withdrawn and outstanding balance of the advance as at the date of such withdrawal from the Loan Account and to pay all accrued and unpaid charges, if any, on the advance as at such date. The Bank shall pay the amount so withdrawn to itself or the Association, as the case may be, and shall cancel the remaining unwithdrawn amount of the advance.”
ADDITIONAL SPECIAL CONTRACT CONDITIONS A. Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:
MAINTENANCE OF CONCESSION PREMISES A. Concessionaire shall preserve and maintain the Concession Premises in good and clean condition, reasonable wear and tear excepted. Concessionaire is solely responsible for the maintenance and cleanliness of the Concession Premises.
INTERIM MAINTENANCE PERIOD During the interim maintenance period between obtaining of the completion certificate of Project and formation and operationalization of the Association the Promoter shall through itself or through a facility management company constitute a committee to run, operate, manage and maintain the Common Areas.
Construction Liens Tenant shall have no power to do any act or make any contract that may create or be the foundation of any lien, mortgage or other encumbrance upon the reversionary or other estate of Landlord, or any interest of Landlord in the Property or Facility Premises. NO CONSTRUCTION LIENS OR OTHER LIENS FOR ANY LABOR, SERVICES OR MATERIALS FURNISHED TO THE PREMISES SHALL ATTACH TO OR AFFECT THE INTEREST OF LANDLORD IN AND TO THE PROPERTY OR FACILITY PREMISES. Tenant shall keep the Property and Facility Premises free from any liens arising out of any work performed, materials furnished, or obligations incurred by or on behalf of Tenant. Should any lien or claim of lien be filed against the Property or Facility Premises by reason of any act or omission of Tenant or any of Tenant’s agents, employees, contractors or representatives, then Tenant shall cause the same to be canceled and discharged of record by bond or otherwise within thirty (30) days after the filing thereof. Should Tenant fail to discharge the lien within thirty (30) days, then Landlord may discharge the lien. The amount paid by Landlord to discharge the lien (whether directly or by bond), plus all administrative and legal costs incurred by Landlord, shall be additional rent payable on demand. The remedies provided herein shall be in addition to all other remedies available to Landlord under this Lease or otherwise. The parties hereto agree that in no event shall the interest of Landlord be subject to the liens for improvements made by Tenant, and this expressly prohibits such liability. Pursuant to Section 713.10, Florida Statutes, this provision specifically provides that no interest of Landlord shall be subject to liens for improvements made by the Tenant at or under Tenant’s direction. This provision shall serve as notice to all potential construction lienors that Landlord shall not be liable for and the Facility Premises shall not be subject to liens for work performed or materials supplied at Tenant’s request or at the request of anyone claiming an interest by, through or under Tenant. Further, any contractor, vendor, supplier or other party providing work or services to and for the Premises that is entitled to a mechanic’s lien pursuant to Chapter 713, Florida Statutes, shall look solely to the leasehold interest of the Tenant in the Lease and may not encumber the fee title to the Premises owned by the Landlord. Tenant shall provide notice of this provision to all contractors, vendors, suppliers, and other parties providing work or materials at the Premises. The foregoing provision shall be included in any recorded notice under Section 713.10, Florida Statutes, or memorandum of this Lease.
