Limitation on Acceleration Costs; Delay and Disruption Damages Sample Clauses

Limitation on Acceleration Costs; Delay and Disruption Damages. Limitations on Acceleration Costs, Delay and Disruption Damages, and other limitations include the following: Acceleration Costs; Delay and Disruption Damages: Acceleration Costs shall be compensable hereunder only with respect to Change Orders issued by the District as an alternative to allowing an extension of a Completion Deadline as contemplated by Section 14. Delay and disruption damages shall be compensable hereunder only in the case of a delay pursuant to Section 14 to the extent that it entitles the DB Contractor to an extension of a Completion Deadline. Costs of rearranging the DB Contractor’s work plan not associated with an extension of a Completion Deadline shall not be compensable hereunder. Other Limitations: Delay and disruption damages shall be limited to direct costs directly attributable to the delays described in this Section and overhead and profit thereon, in accordance with Section 15.7.6, and any additional field office and jobsite overhead costs incurred by the DB Contractor directly attributable to such delays and allowable under Section 17.5.1. In addition, before the DB Contractor may obtain any increase in the Contract Price to compensate for any delay and disruption damages or Acceleration Costs, the DB Contractor shall have demonstrated to the District’s satisfaction that:
Sample 1Sample 2
AutoNDA by SimpleDocs
Limitation on Acceleration Costs; Delay and Disruption Damages. ‌ Limitations on Acceleration Costs, Delay and Disruption Damages, and other limitations include the following: Acceleration Costs; Delay and Disruption Damages: Acceleration Costs shall be compensable hereunder only with respect to Change Orders issued by the District as an alternative to allowing an extension of a Completion Date as contemplated by Section 14. Costs of rearranging the DB Contractor’s work plan not associated with an extension of a Completion Date shall not be compensable hereunder. Other Limitations: Delay and disruption damages shall be limited to direct costs directly attributable to the delays described in this Section incurred by the DB Contractor directly attributable to such delays. In addition, before the DB Contractor may obtain any increase in the Contract Price to compensate for any delay and disruption damages or Acceleration Costs, the DB Contractor shall have demonstrated to the District’s satisfaction that:
Sample 1

Related to Limitation on Acceleration Costs; Delay and Disruption Damages

  • Limitation on Damages IN NO EVENT SHALL ANY PARTY BE LIABLE TO ANY OTHER PARTY FOR ANY LOST PROFITS OR SPECIAL, CONSEQUENTIAL OR PUNITIVE DAMAGES, EVEN IF INFORMED OF THE POSSIBILITY OF SUCH DAMAGES. THE FOREGOING SHALL BE INTERPRETED AND HAVE EFFECT TO THE MAXIMUM EXTENT PERMITTED BY APPLICABLE LAW, RULE OR REGULATION.

  • Limitation on Damage In the event of a breach of any provision of this contract by the State, the liability of the State shall be limited to return of the unused initial deposit and unapplied payments to the Purchaser. The State shall not be liable for any damages, whether direct, incidental, or consequential.

  • Limitation on Direct Damages RSA’S AND ITS SUPPLIERS’ TOTAL LIABILITY AND CUSTOMER’S SOLE AND EXCLUSIVE REMEDY FOR ANY CLAIM OF ANY TYPE WHATSOEVER, ARISING OUT OF HARDWARE, SOFTWARE OR SERVICE PROVIDED HEREUNDER, SHALL BE LIMITED TO PROVEN DIRECT DAMAGES CAUSED BY RSA’S SOLE NEGLIGENCE IN AN AMOUNT NOT TO EXCEED (i) NZ$2,000,000, FOR DAMAGE TO REAL OR TANGIBLE PERSONAL PROPERTY; AND (ii) THE PRICE PAID BY CUSTOMER TO RSA FOR THE SPECIFIC SERVICE (CALCULATED ON AN ANNUAL BASIS, WHEN APPLICABLE) HARDWARE OR SOFTWARE FROM WHICH SUCH CLAIM ARISES, FOR DAMAGE OF ANY TYPE NOT IDENTIFIED IN (i) ABOVE OR OTHERWISE EXCLUDED HEREUNDER.

  • Limitation of Damages NOTWITHSTANDING ANYTHING CONTAINED HEREIN TO THE CONTRARY, THE PARTIES AGREE THAT NEITHER PARTY SHALL BE LIABLE TO THE OTHER FOR ANY PUNITIVE DAMAGES WHATSOEVER, WHETHER IN CONTRACT, TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY OR ANY OTHER LEGAL OR EQUITABLE PRINCIPLE, PROVIDED, HOWEVER, THAT SUCH LIMITATION SHALL NOT BE APPLICABLE WITH RESPECT TO THIRD PARTY CLAIMS MADE AGAINST A PARTY.

  • Limitation of Remedies, Liability and Damages EXCEPT AS EXPRESSLY SET FORTH HEREIN, THERE IS NO WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE, AND ANY AND ALL IMPLIED WARRANTIES ARE DISCLAIMED. THE PARTIES CONFIRM THAT THE EXPRESS REMEDIES AND MEASURES OF DAMAGES PROVIDED IN THIS AGREEMENT SATISFY THE ESSENTIAL PURPOSES HEREOF. FOR BREACH OF ANY PROVISION FOR WHICH AN EXPRESS REMEDY OR MEASURE OF DAMAGES IS PROVIDED, SUCH EXPRESS REMEDY OR MEASURE OF DAMAGES SHALL BE THE SOLE AND EXCLUSIVE REMEDY, THE OBLIGOR’S LIABILITY SHALL BE LIMITED AS SET FORTH IN SUCH PROVISION AND ALL OTHER REMEDIES OR DAMAGES AT LAW OR IN EQUITY ARE WAIVED. IF NO REMEDY OR MEASURE OF DAMAGES IS EXPRESSLY PROVIDED HEREIN, THE OBLIGOR’S LIABILITY SHALL BE LIMITED TO DIRECT ACTUAL DAMAGES ONLY, SUCH DIRECT ACTUAL DAMAGES SHALL BE THE SOLE AND EXCLUSIVE REMEDY, AND ALL OTHER REMEDIES OR DAMAGES AT LAW OR IN EQUITY ARE WAIVED. UNLESS EXPRESSLY HEREIN PROVIDED, NEITHER PARTY SHALL BE LIABLE FOR CONSEQUENTIAL, INCIDENTAL, PUNITIVE, EXEMPLARY OR INDIRECT DAMAGES, LOST PROFITS OR OTHER BUSINESS INTERRUPTION DAMAGES, BY STATUTE, IN TORT OR CONTRACT, UNDER ANY INDEMNITY PROVISION OR OTHERWISE. TO THE EXTENT ANY DAMAGES REQUIRED TO BE PAID HEREUNDER ARE LIQUIDATED, THE PARTIES ACKNOWLEDGE THAT THE DAMAGES ARE DIFFICULT OR IMPOSSIBLE TO DETERMINE, OR OTHERWISE OBTAINING AN ADEQUATE REMEDY IS INCONVENIENT AND THE DAMAGES CALCULATED HEREUNDER CONSTITUTE A REASONABLE APPROXIMATION OF THE HARM OR LOSS.

  • O LIMITATION OF LIABILITY FOR DAMAGES FOR PERSONAL INJURY OR PROPERTY DAMAGE ARE PERMITTED OR AGREED BY TIPS/ESC REGION 8. Per Texas Education Code §44.032(f), and pursuant to its requirements only, reasonable Attorney’s fees are recoverable by the prevailing party in any dispute resulting in litigation. State of Texas Franchise Tax By signature hereon, the Vendor hereby certifies that he/she is not currently delinquent in the payment of any franchise taxes owed the State of Texas under Chapter 171, Tax Code.

  • Waiver of Consequential Damages, Etc To the fullest extent permitted by applicable law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document or any agreement or instrument contemplated hereby, the transactions contemplated hereby or thereby, any Loan or Letter of Credit or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed to such unintended recipients by such Indemnitee through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.

  • Additional Fee on Late Payments For any payments thirty (30) calendar days or more overdue under this Agreement, Registry Operator shall pay an additional fee on late payments at the rate of 1.5% per month or, if less, the maximum rate permitted by applicable law.

  • Default Remedies Termination A. [Sec. 400]

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2

Time is Money Join Law Insider Premium to draft better contracts faster.