EXCLUSION OF THIRD PARTY RIGHTS A person who is not a party to this Agreement has no right under the Contracts (Rights of Third Parties) Xxx 0000 to enforce any term of this Agreement, but this does not affect any right or remedy of a third party which exists or is available apart from that Act.
Limitation on Out-of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
Infringement of Third Party Rights Each Party shall promptly notify the other in writing of any allegation by a Third Party that the activity of either of the Parties hereunder infringes or may infringe the intellectual property rights of such Third Party. Genentech shall have the first right but not the obligation to control any defense of any such claim involving alleged infringement of Third Party rights by Genentech’s activities under this Agreement at its own expense and by counsel of its own choice, and Curis shall have the right but not the obligation, at its own expense, to be represented in any such action by counsel of its own choice. If Genentech fails to proceed in a timely fashion with regard to such defense, Curis shall have the right but not the obligation to control any such defense of such claim at its own expense and by counsel of its own choice, and Genentech shall have the right but not the obligation, at its own expense, to be represented in any such action by counsel of its own choice. Curis shall have the first right but not the obligation to control any defense of any such claim involving alleged infringement of Third Party rights by Curis’ activities under this Agreement at its own expense and by counsel of its own choice, and Genentech shall have the right but not the obligation, at its own expense, to be represented in any such action by counsel of its own choice. If Curis fails to proceed in a timely fashion with regard to such defense, Genentech shall have the right but not the obligation to control any such defense of such claim at its own expense and by counsel of its own choice, and Curis shall have the right but not the obligation, at its own expense, to be represented in any such action by counsel of its own choice. Neither Party shall have the right to settle any infringement action under this Section 10.5 in a manner that diminishes the rights or interests of the other Party hereunder without the consent of such Party.
Marking of Licensed Products To the extent commercially feasible and consistent with prevailing business practices, Company shall xxxx, and shall cause its Affiliates and Sublicensees to xxxx, all Licensed Products that are manufactured or sold under this Agreement with the number of each issued patent under the Patent Rights that applies to such Licensed Product.
INDEMNIFICATION RELATING TO THIRD PARTY RIGHTS The Contractor will also indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs that may be finally assessed against the Authorized Users in any action for infringement of a United States Letter Patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims arise from the Authorized Users gross negligence or willful misconduct, provided that the State shall give Contractor: (i) prompt written notice of any action, claim or threat of infringement suit, or other suit, (ii) the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and (iii) assistance in the defense of any such action at the expense of Contractor. If usage shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue Usage (ii) to modify the service or Product so that Usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace said service or Product or part(s) thereof, as applicable, with non-infringing service or Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided the Authorized User is given a refund for any amounts paid for the period during which Usage was not feasible. The foregoing provisions as to protection from third party rights shall not apply to any infringement occasioned by modification by the Authorized User of any Product without Contractor’s approval. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the service or Product under the Contract infringes any patent, copyright or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract. Contractor shall in such event protect the interests of the Authorized User and secure a continuance to permit the Authorized User to appear and defend its interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
Rights Protection Mechanisms and Abuse Mitigation ‐ Registry Operator commits to implementing and performing the following protections for the TLD:
i. In order to help registrars and registrants identify inaccurate data in the Whois database, Registry Operator will audit Whois data for accuracy on a statistically significant basis (this commitment will be considered satisfied by virtue of and for so long as ICANN conducts such audits).
ii. Work with registrars and registrants to remediate inaccurate Whois data to help ensure a more accurate Whois database. Registry Operator reserves the right to cancel a domain name registration on the basis of inaccurate data, if necessary.
iii. Establish and maintain a Domains Protected Marks List (DPML), a trademark protection service that allows rights holders to reserve registration of exact match trademark terms and terms that contain their trademarks across all gTLDs administered by Registry Operator under certain terms and conditions.
iv. At no cost to trademark holders, establish and maintain a Claims Plus service, which is a notice protection mechanism that begins at the end of ICANN’s mandated Trademark Claims period.
v. Bind registrants to terms of use that define and prohibit illegal or abusive activity.
vi. Limit the use of proxy and privacy registration services in cases of malfeasance.
vii. Consistent with the terms of this Registry Agreement, reserve the right to exclude from distribution any registrars with a history of non-‐compliance with the terms of the Registrar Accreditation Agreement.
viii. Registry Operator will be properly resourced to perform these protections.
Country and Territory Names The country and territory names (including their IDN variants, where applicable) contained in the following internationally recognized lists shall be withheld from registration or allocated to Registry Operator at All Levels: the short form (in English) of all country and territory names contained on the ISO 3166-1 list, as updated from time to time, including the European Union, which is exceptionally reserved on the ISO 3166-1 list, and its scope extended in August 1999 to any application needing to represent the name European Union <xxxx://xxx.xxx.xxx/iso/support/country_codes/iso_3166_code_lists/iso-3166-1_decoding_table.htm>; the United Nations Group of Experts on Geographical Names, Technical Reference Manual for the Standardization of Geographical Names, Part III Names of Countries of the World; and the list of United Nations member states in 6 official United Nations languages prepared by the Working Group on Country Names of the United Nations Conference on the Standardization of Geographical Names; provided, that the reservation of specific country and territory names (including their IDN variants according to the registry operator IDN registration policy, where applicable) may be released to the extent that Registry Operator reaches agreement with the applicable government(s). Registry Operator must not activate such names in the DNS; provided, that Registry Operator may propose the release of these reservations, subject to review by ICANN’s Governmental Advisory Committee and approval by ICANN. Upon conclusion of Registry Operator’s designation as operator of the registry for the TLD, all such names that remain withheld from registration or allocated to Registry Operator shall be transferred as specified by ICANN. Registry Operator may self-allocate and renew such names without use of an ICANN accredited registrar, which will not be considered Transactions for purposes of Section 6.1 of the Agreement.
Xxxxx of License; Limitations The Engineer is granted a limited revocable non-exclusive license to use the registered TxDOT trademark logo (TxDOT Flying “T”) on any deliverables prepared under this contract that are the property of the State. The Engineer may not make any use of the registered TxDOT trademark logo on any other materials or documents unless it first submits that request in writing to the State and receives approval for the proposed use. The Engineer agrees that it shall not alter, modify, dilute, or otherwise misuse the registered TxDOT trademark logo or bring it into disrepute.
Exclusive Negotiations The State will not bargain collectively or meet with any employee organization other than MSEA-SEIU with reference to terms and conditions of employment of employees covered by this Agreement. If any such organizations request meetings they will be advised by the State to transmit their requests concerning terms and conditions of employment to MSEA-SEIU.
Conduct of Third Party Claims If the matter or circumstance that may give rise to a Claim other than a Tax Claim is a result of or in connection with a claim by a third party (a “Third Party Claim”) then:
11.4.1 the Purchaser shall, to the extent reasonably practicable and subject to Applicable Law, consult with the Seller in relation to the conduct of the Third Party Claim and shall take reasonable account of the views of the Seller before taking any action in relation to the Third Party Claim;
11.4.2 no admissions in relation to the Third Party Claim shall be made by or on behalf of the Purchaser or any member of the Purchaser’s Group and the Third Party Claim shall not be compromised, disposed of or settled without the written consent of the Seller, such consent not to be unreasonably withheld or delayed;
11.4.3 subject to the Seller indemnifying the Purchaser or member of the Purchaser’s Group concerned against all reasonable costs and expenses (including legal and professional costs and expenses) that may be incurred thereby, the Purchaser shall, or the Purchaser shall procure that the members of the Purchaser’s Group shall, take such action as the Seller may reasonably request to avoid, dispute, deny, defend, resist, appeal, compromise or contest the Third Party Claim;
11.4.4 the Seller shall, subject in each case to being paid all reasonable out-of-pocket costs and expenses:
(i) make available to the Purchaser and the relevant Group Company such persons and all such information as the Purchaser may reasonably request for assessing, contesting, disputing, defending, compromising or appealing the Third Party Claim; and
(ii) shall give the Purchaser and the relevant Group Company reasonable access to its premises and to its books and records for such purpose during normal business hours on any Business Day following reasonable notice being given to the Seller;
11.4.5 subject to 11.4.3, the Seller shall be entitled at its own expense and in its absolute discretion, by notice in writing to the Purchaser, to assume conduct of any Third Party Claim and to have the conduct of any related proceedings, negotiations or appeals;
11.4.6 if the Seller sends a notice to the Purchaser pursuant to Clause 11.4.5 and until such time as any final compromise, agreement, expert determination or non-appealable decision of a court or tribunal of competent jurisdiction is made in respect of that Third Party Claim or that Third Party Claim is otherwise finally disposed of:
(i) the Purchaser shall, and the Purchaser shall procure that any member of the Purchaser’s Group shall:
(a) give, subject to being paid all reasonable costs and expenses, all such information and assistance including access to premises and personnel, and the right to examine and copy or photograph any assets, accounts, documents and records (excluding, in each case, information or documents which are protected by legal professional privilege but including, in each case, information or documents that are subject to common interest privilege), as the Seller may reasonably request, including instructing such professional or legal advisers as the Seller may nominate to act on behalf of the Purchaser or other member of the Purchaser’s Group concerned but in accordance with the Seller’s instructions, provided that the appointment of such adviser or advisers shall have been approved in writing by the Purchaser (such approval not to be unreasonably withheld, conditioned or delayed); and
(b) not make any admission of liability, agreement or compromise in relation to that Third Party Claim without the prior written approval of the Seller (such approval not to be unreasonably withheld, conditioned or delayed);
(ii) the Seller shall:
(a) consult with the Purchaser and take reasonable account of the views of the Purchaser before taking any action in relation to the Third Party Claim;
(b) without prejudice to its ability to defend the Third Party Claim, conduct the Third Party Claim with a view to minimising any material harm to the goodwill and reputation of the Wider Group or the Purchaser’s Group;
(c) keep the Purchaser informed of all relevant matters relating to the Third Party Claim and shall promptly forward or procure to be forwarded to the Purchaser copies of all correspondence and other written communications with such other information, including non-written records (except information or documents which are protected by legal professional privilege), relating to the Third Party Claim;
(d) not make any admission of liability, settlement or compromise of the Third Party Claim without the written consent of the Purchaser, such consent not to be unreasonably withheld, conditioned or delayed. If the Purchaser or member of the Purchaser’s Group fails to consent to a settlement or compromise, the maximum liability of the Seller shall (without prejudice to Clause 10) not exceed the full amount of the proposed settlement or compromise and the Purchaser or member of the Purchaser’s Group shall be liable for any damages awarded in excess of the proposed settlement or compromise and costs incurred from (and including) the date the Seller notified the Purchaser of the settlement or compromise; and
(e) indemnify, save as set out in Clause 11.4.6(ii)(d), the Purchaser or other member of the Purchaser’s Group concerned against all reasonable costs and expenses (including legal and professional costs and expenses) that may be incurred as a result of the Seller assuming conduct of the Third Party Claim.
11.4.7 The covenants in this Clause 11.4 may be enforced:
(i) by any Group Company against the Seller; and
(ii) by any member of the Seller’s Group against the Purchaser or a Group Company, under the Contracts (Rights of Third Parties) Xxx 0000.
11.4.8 The provisions of this Clause 11.4 may be varied or terminated by agreement between the Seller and the Purchaser (and the Purchaser may also release or compromise in whole or in part any liability in respect of rights or claims contemplated by this Clause 11.4) without the consent of any Group Company.
