LIMITATION ON MUNICIPAL INDEMNITY Sample Clauses

LIMITATION ON MUNICIPAL INDEMNITY. To the extent that the Contract calls for the Town to indemnify any party thereto, the following sentence shall be appended to the indemnity and shall control the indemnity as if set forth therein, as follows:
Sample 1
AutoNDA by SimpleDocs
LIMITATION ON MUNICIPAL INDEMNITY. To the extent that any of the Contract Documents call for Owner to indemnify Design-Builder, or any party, or to the extent that any transaction made in the course of construction of the Skate Park Project requires the Owner to indemnify any third-party, the following sentence shall be appended to the indemnity and shall control the indemnity as if set forth therein: “provided, however, that regardless of whether any such obligations incurred hereunder are based on tort, contract, statute, strict liability, negligence, product liability or otherwise, the obligations of the Owner under this indemnification provision shall be limited in the same manner that would have applied if such obligations were based on, or arose out of, an action at law to recover damages in tort and were subject to section 768.28, Florida Statutes, as that section existed at the inception of the Agreement between Owner and Design-Builder dated May, 2019.” The addition of this language pursuant to this Agreement shall not be construed to create Owner indemnifications where none are expressly made in the terms and conditions of the Contract Documents, nor shall it create indemnifications where none are expressly made in the terms and conditions of any transaction made in the course of construction of the Skate Park Project, whether implied or otherwise. Provided however that such language is not intended to exclude and does not exclude any liability in contract that the Owner may have to Design-Builder under this Agreement.
Sample 1

Related to LIMITATION ON MUNICIPAL INDEMNITY

  • Limitations on Indemnification No payments pursuant to this Agreement shall be made by the Company:

  • Limitation on Out of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree (Yes) Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes Does Vendor agree? Yes, Vendor agrees (Yes) No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees (Yes)

  • Mutual Indemnity Each party will defend and indemnify the other party against any third party claim or action for personal bodily injury, including death, to the extent directly caused by the indemnifying party’s gross negligence or willful misconduct in the course of performing its obligations under the Agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.